Completion Estimate Sample Clauses

Completion Estimate. If, as a result of fire or other casualty (each, a “Casualty”), all or any portion of the Premises becomes untenantable or inaccessible, Landlord, with reasonable promptness, shall cause a general contractor selected by Landlord to provide Landlord with a written estimate of the amount of time required, using standard working methods, to substantially complete the repair and restoration of the Premises and any Common Areas necessary to provide access to the Premises (“Completion Estimate”). Landlord shall promptly forward a copy of the Completion Estimate to Tenant. If the Completion Estimate indicates that the Premises or any Common Areas necessary to provide access to the Premises cannot be made tenantable within two hundred seventy (270) days from the date the repair is started (when such repair is made without the payment of overtime or other premiums), then either Landlord or Tenant shall have the right to terminate this Lease upon written notice delivered to the other within thirty (30) days following delivery of the Completion Estimate. In addition, Landlord, by notice delivered to Tenant within ninety (90) days after the date of the Casualty, shall have the right to terminate this Lease if the Building or Property shall be damaged by Casualty, whether or not the Premises are affected, and one or more of the following conditions is present: (i) in Landlord’s reasonable judgment, repairs cannot reasonably be completed within two hundred seventy (270) days from the date the repairs are started (when such repairs are made without the payment of overtime or other premiums); (ii) any Holder (defined below) requires that the insurance proceeds or any portion thereof be applied to the payment of the mortgage debt; (iii) the damage is not fully covered by Landlord’s insurance policies; (iv) Landlord decides to rebuild the Building or Common Areas so that they will be substantially different structurally or architecturally; or (v) the damage occurs during the last twenty-four (24) months of the Term.
Sample 1Sample 2See All (5)
AutoNDA by SimpleDocs
Completion Estimate. If all or any portion of the Premises becomes untenantable or inaccessible by fire or other casualty to the Premises or the Common Areas (collectively a “Casualty”), Landlord, with reasonable promptness, shall cause a general contractor selected by Landlord to provide Landlord with a written estimate of the amount of time required, using standard working methods, to substantially complete the repair and restoration of the Premises and any Common Areas necessary to provide access to the Premises (“Completion Estimate”). Landlord shall promptly forward a copy of the Completion Estimate to Tenant. If the Completion Estimate indicates that the Premises or any Common Areas necessary to provide access to the Premises cannot be made tenantable within two hundred seventy (270) days from the date the repair is started, then Landlord shall have the right to terminate this Lease upon written notice delivered to Tenant within thirty (30) days following delivery of the Completion Estimate. In addition, Landlord, by notice delivered to Tenant within ninety (90) days after the date of the Casualty, shall have the right to terminate this Lease if: (1) the Premises have been materially damaged and there are less than two (2) years of the Term remaining on the date of the Casualty; (2) any Holder requires that the insurance proceeds be applied to the payment of the mortgage debt; or (3) a material uninsured loss to the Building or Premises occurs.
Sample 1

Related to Completion Estimate

  • Final Completion 6.5.1 Final Completion of the Work shall be achieved within ninety (90) Days after the earlier of the actual date of Substantial Completion or the Scheduled Substantial Completion Date (the “Final Completion Date”).

  • Project Completion Within five (5) days after the delivery by Supplier to Purchaser of a Commissioning Certificate for the Project’s final Turbine, Supplier shall also deliver to Purchaser a completion certificate for all Turbines in the Project (the “Project Completion Certificate”), in the form attached hereto as Exhibit N, together with a list of any remaining Punch List Work on any Turbine, a schedule for completing the Punch List Work and an estimate of the cost of each item of Punch List Work. Supplier shall thereafter promptly complete all Punch List Work.

  • Repair Estimate If the Premises or the Building are damaged by fire or other casualty (a “Casualty”), Landlord shall use good faith efforts to deliver to Tenant within sixty (60) days after such Casualty a good faith estimate (the “Damage Notice”) of the time needed to repair the damage caused by such Casualty.

  • Substantial Completion The Tenant Improvements shall be deemed to be “Substantially Completed” on the date that (i) the Tenant Improvements are essentially and satisfactorily completed in accordance with the Final Plans to the extent that the Leased Premises may be occupied by Tenant for its Approved Use, subject only to completion of minor finishing, adjustment of equipment, and other minor construction aspects (“punch list items”) which do not, in the aggregate, cause interference (other than minor inconvenience) with the use and occupancy of the Leased Premises for the Approved Use, and (ii) a certificate of occupancy, whether conditional or final, has been issued by the proper governmental authority. Landlord shall give Tenant at least 30 days prior notice (written or oral) of Landlord’s reasonable estimate of the date of Substantial Completion of the Tenant Improvements. Tenant shall schedule with Landlord a mutually acceptable date, which will not be later than 3 business days after the date of Substantial Completion (but in no event earlier than the Landlord’s estimated date of Substantial Completion), for a walk-through inspection of the Leased Premises. In such walk-through, Landlord and Tenant will mutually and reasonably agree upon a punch list, and subject to Tenant Delay, Landlord will use reasonable efforts to cause such punch list work to be completed within 30 days after such walk-through. Landlord hereby warrants to Tenant, which warranty shall survive for one year following the date of Substantial Completion of the Tenant Improvements, that (a) the materials and equipment furnished by Landlord and Landlord’s contractors in the completion of the Tenant Improvements will be of good quality and new, and (b) such materials and equipment and the work of such contractors shall be free from defects not inherent in the quality required or permitted hereunder. This warranty shall exclude damages or defects caused by Tenant, its agents, employees or contractors, improper or insufficient maintenance, improper operation or normal wear and tear under normal usage. Landlord shall use diligent and good faith efforts to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed by November 1, 2018. Subject only to Force Majeure (as defined in §11 hereof) and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required construction permits for the Tenant Improvements (the “Construction Permits”) by not later than June 30, 2018, then in the event that Landlord fails to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed on or before December 1, 2018, (the “Fifth Floor Substantial Completion Date”), Tenant shall be entitled to a day-for-day credit of Base Rent due as of the Commencement Date, for each day after the Fifth Floor Substantial Completion Date that the Tenant Improvements for the Fifth Floor Premises are not Substantially Completed; provided, however, that, for every day of delay which results from a Tenant Delay or a Force Majeure, the Fifth Floor Substantial Completion Date shall be moved back on a day-for-day basis. Such day-for-day credit of Base Rent shall commence upon the Commencement Date and shall continue until applied in full; provided that at no time may Tenant offset more than 50% of the Base Rent amount due each month until such abatement has been completed. Landlord shall use diligent and good faith efforts to cause the Tenant Improvements for the Fourth Floor Premises to be Substantially Completed by February 1, 2019. Subject only to Force Majeure (as defined in §11 hereof) and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required construction permits for the Tenant Improvements (the “Construction Permits”) by not later than June 30, 2018, then in the event that Landlord fails to cause the Tenant Improvements for the Fourth Floor Premises to be Substantially Completed on or before March 1, 2019, (the “Fourth Floor Substantial Completion Date”), Tenant shall be entitled to a day-for-day credit of Base Rent due as of the Commencement Date, for each day after the Fourth Floor Substantial Completion Date that the Tenant Improvements for the Fourth Floor Premises are not Substantially Completed; provided, however, that, for every day of delay which results from a Tenant Delay or a Force Majeure, the Fourth Floor Substantial Completion Date shall be moved back on a day-for-day basis. Such day-for-day credit of Base Rent shall commence upon the June 1, 2019, and shall continue until applied in full; provided that at no time may Tenant offset more than 50% of the Base Rent amount due each month until such abatement has been completed. Subject only to Force Majeure and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required Construction Permits by not later than June 30, 2018, if the Tenant Improvements for the Leased Premises are not Substantially Completed on or before April 1, 2019 (“Outside Completion Date”), then Tenant shall have the one-time right by not later than 10 days after the Outside Completion Date to terminate this lease by delivering written notice to Landlord, which notice shall be hand delivered to 0000 Xxxx Xxxxx Xxxxx, Xxxxxxxx, Xxxx 00000, Attention: Xxxxxx X. Xxxxx, Xx., and upon hand delivery of such termination notice to said address, this lease shall be deemed null and void and the parties shall have no further rights or obligations hereunder, except those that specifically survive the expiration or earlier termination of this lease. Landlord and Tenant acknowledge and agree that Tenant’s damages as a result of Landlord’s failure to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed by not later than the Fifth Floor Substantial Completion Date or the Fourth Floor Premises to be Substantially Completed by not later than the Fourth Floor Substantial Completion Date are difficult to ascertain, that such amounts set forth above are a reasonable pre-estimate of Tenant’s probable loss as a result thereof and that such damages constitute reasonable liquidated damages for Tenant’s loss and not a penalty.

  • Completion Date Completion date" shall be the date on which the improvements erected and to be erected upon the leased premises shall have been completed in accordance with the plans and specifications described in article 6.00. The completion date shall constitute the commencement of the term of this Lease for all purposes, whether or not Lessee has actually taken possession. Lessor shall use its best efforts to establish the completion date as the date set forth in section 1.03. In the event that the improvements have not in fact been completed as of that date, Lessee shall notify Lessor in writing of its objections. Lessor shall have a reasonable time after delivery of the notice in which to take such corrective action as may be necessary and shall notify Lessee in writing as soon as it deems such corrective action has been completed and the improvements are ready for occupancy. Upon completion of construction, Lessee shall deliver to Lessor a letter accepting the leased premises as suitable for the purposes for which they are let and the date of such letter shall constitute the commencement of the term of this Lease. Whether or not Lessee has executed such letter of acceptance, taking possession of the leased premises by Lessee shall be deemed to establish conclusively that the improvements have been completed in accordance with the plans and specifications, are suitable for the purposes for which the leased premises are let, and that the leased premises are in good and satisfactory condition as of the date possession was so taken by Lessee, except for latent defects, if any.

  • After Completion the Seller shall at its cost execute and deliver all such further documents and/or take such other action as the Purchaser may reasonably request in order to effect (i) the release and discharge in full of the relevant member of the Purchaser’s Group from any and all Retained Liabilities and any Liabilities related to the Retained Assets and (ii) the assumption by the Seller or any member of the Seller’s Group as the primary obligor in respect of any and all Retained Liabilities or Liabilities related to the Retained Assets in substitution for the relevant member of the Purchaser’s Group (in each case on a non-recourse basis to any member of the Purchaser’s Group).

  • Completion of Repairs Borrower will commence any Repairs as soon as practicable after the date of this Loan Agreement and will diligently proceed with and complete such Repairs on or before the Completion Date. All Repairs and Capital Replacements will be completed in a good and workmanlike manner, with suitable materials, and in accordance with good building practices and all applicable laws, ordinances, rules, regulations, building setback lines and restrictions applicable to the Mortgaged Property. Borrower agrees to cause the replacement of any material or work that is defective, unworkmanlike or that does not comply with the requirements of this Loan Agreement, as determined by Lender.

  • Project Schedule Contractor shall perform the Work in accordance with the Project Schedule.

  • Pre-Estimate The parties agree that if Market Quotation applies an amount recoverable under this Section 6(e) is a reasonable pre-estimate of loss and not a penalty. Such amount is payable for the loss of bargain and the loss of protection against future risks and except as otherwise provided in this Agreement neither party will be entitled to recover any additional damages as a consequence of such losses.

  • Completion 5.1 Completion shall take place on the Completion Date:

Time is Money Join Law Insider Premium to draft better contracts faster.