REQUIRED FOR PART 2 JOC - PRICING OF Regular Hours Coefficient What is your regular hours coefficient for the RS Means Price Book? (FAILURE TO RESPOND PROHIBITS PART 2 JOC EVALUATION) Remember that this is a ceiling price proposed. You can discount lower than your proposed contract coefficient, but not higher. This is one of three pricing questions that are required for consideration for award on this solicitation. Please consider your answer carefully. An explanation of the TIPS scoring of pricing is included in the attachments for your information. The below is an Example of how pricing model works (not intended to influence your proposed coefficient, you should propose a coefficient that you determine is right for your business): To propose the exact pricing as the RS Means Unit Price Book, you would insert a 1.0 and to propose a 5% discount for the RS Means Price Book would be a .95 regular hours coefficient and so on.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Project Specific Milestones In addition to the milestones stated in Section 212.5 of the Tariff, as applicable, during the term of this ISA, Interconnection Customer shall ensure that it meets each of the following development milestones:
Technical Standards Applicable to a Wind Generating Plant i. Low Voltage Ride-Through (LVRT) Capability A wind generating plant shall be able to remain online during voltage disturbances up to the time periods and associated voltage levels set forth in the standard below. The LVRT standard provides for a transition period standard and a post-transition period standard.
Escrow Format Specification 3.1. Deposit’s Format. Registry objects, such as domains, contacts, name servers, registrars, etc. will be compiled into a file constructed as described in draft-xxxxx-xxxxxxx-registry-data-escrow, see Part A, Section 9, reference 1 of this Specification and draft-xxxxx-xxxxxxx-dnrd-objects-mapping, see Part A, Section 9, reference 2 of this Specification (collectively, the “DNDE Specification”). The DNDE Specification describes some elements as optional; Registry Operator will include those elements in the Deposits if they are available. If not already an RFC, Registry Operator will use the most recent draft version of the DNDE Specification available at the Effective Date. Registry Operator may at its election use newer versions of the DNDE Specification after the Effective Date. Once the DNDE Specification is published as an RFC, Registry Operator will implement that version of the DNDE Specification, no later than one hundred eighty (180) calendar days after. UTF-8 character encoding will be used.
Required Forms If subcontractors are used under the contract that has no stated HUB goal, Exhibits H-1, H-2, H-4 and H-6 are required. Exhibits H-1 and H-6 are required if no subcontractors are being used to perform work under this contract. State of Texas HUB Subcontracting Plan Prime Contractor Progress Assessment Report (Exhibit H-6) is required monthly even when no subcontracting activity has occurred. In addition, State of Texas HUB Subcontracting Plan Prime Contractor Progress Assessment Report (Exhibit H-6) should be submitted with the Provider’s invoice. EXHIBIT H-1 Texas Department of Transportation Subprovider Monitoring System Commitment Worksheet Contract #: Assigned Goal: % Federally Funded State Funded Prime Provider: Total Contract Amount: Prime Provider Info: DBE HUB Both Vendor ID #: DBE/HUB Expiration Date: (First 11 Digits Only) If no subproviders are used on this contract, please indicate by placing “N/A” on the 1st line under Subproviders. Subprovider(s) (List All) Type of Work Vendor ID # (First 11 Digits Only) D=DBE H=HUB Expiration Date $ Amount or % of Work * Subprovider(s) Contract or % of Work* Totals *For Work Authorization Contracts, indicate the % of work to be performed by each subprovider. Total DBE or HUB Commitment Dollars $ Total DBE or HUB Commitment Percentages of Contract % (Commitment Dollars and Percentages are for Subproviders only) EXHIBIT H-2 Texas Department of Transportation Subprovider Monitoring System Commitment Agreement This commitment agreement is subject to the award and receipt of a signed contract from the Texas Department of Transportation (TxDOT). NOTE: Exhibit H-2 is required to be attached to each contract that does not include work authorizations. Exhibit H-2 is required to be attached with each work authorization. Exhibit H-2 is also required to be attached to each supplemental work authorization. If DBE/HUB Subproviders are used, the form must be completed and signed. If no DBE/HUB Subproviders are used, indicate with “N/A” on this line: and attach with the work authorization or supplemental work authorization. Contract #: Assigned Goal: % Prime Provider: Work Authorization (WA)#: WA Amount: Date: Supplemental Work Authorization (SWA) #: to WA #: SWA Amount: Revised WA Amount: Description of Work (List by category of work or task description. Attach additional pages, if necessary.) Dollar Amount (For each category of work or task description shown.) Total Commitment Amount (Including all additional pages.) $ IMPORTANT: The signatures of the prime and the DBE/HUB and Second Tier Subprovider, if any (both DBE and Non-DBE) and the total commitment amount must always be on the same page. Provider Name: Name: (Please Print) Title: Signature Date Address: Phone # & Fax #: Email: DBE/HUB Sub Provider Name: (Please Print) Title: Signature Date Subprovider Name: VID Number: Address: Phone # & Fax #: Email: Second Tier Sub Provider: Name: (Please Print) Title: Signature Date Subprovider Name: VID Number: Address: Phone #& Fax #: Email: VID Number is the Vendor Identification Number issued by the Comptroller. If a firm does not have a VID Number, please enter the owner’s Social Security or their Federal Employee Identification Number (if incorporated). Contract No. EXHIBIT H-3 Texas Department of Transportation Subprovider Monitoring System for Federally Funded Contracts Progress Assessment Report for month of (Mo./Yr.) / Contract #: Original Contract Amount: Date of Execution: Approved Supplemental Agreements: Prime Provider: Total Contract Amount: Work Authorization No. Work Authorization Amount: If no subproviders are used on this contract, please indicate by placing “N/A” on the 1st line under Subproviders. DBE All Subproviders Category of Work Total Subprovider Amount % Total Contract Amount Amount Paid This Period Amount Paid To Date Subcontract Balance Remaining Fill out Progress Assessment Report with each estimate/invoice submitted, for all subcontracts, and forward as follows: 1 Copy with Invoice - Contract Manager/Managing Office 1 Copy – TxDOT, BOP Office, 120 X. 00xx, Xxxxxx, XX 00000, 000-000-0000, toll free 000-000-0000, or Fax to 000-000-0000 I hereby certify that the above is a true and correct statement of the amounts paid to the firms listed above. Print Name - Company Official /DBE Liaison Officer Signature Phone Date Email Fax Contract No. EXHIBIT H-4 Texas Department of Transportation Subprovider Monitoring System Final Report The Final Report Form should be filled out by the Prime Provider and submitted to the Contract Manager and the Business Opportunity Programs Office for review upon completion of the contract. The report should reflect all subcontract activity on the project. The report will aid in expediting the final estimate for payment. If the HUB or DBE goal requirements were not met, documentation supporting good faith efforts must be submitted. DBE Goal: % OR HUB Goal: % Total Contract Amount: $ Contract Number: Total Contract Amount: $ Vendor ID # Subprovider Total $ Amt Paid to Date TOTAL This is to certify that % of the work was completed by the HUB or DBE subproviders as stated above. By: Prime Provider Per: Signature Subscribed and sworn to before me, this day of , 20 Notary Public County My Commission expires: 12/06 DBE-H4.A Contract No. EXHIBIT H-5 Federal Subprovider and Supplier Information The Provider shall indicate below the name, address and phone number of all successful and unsuccessful subproviders and/or suppliers that provided proposals/quotes for this contract prior to execution. You may reproduce this form if additional space is needed. Name Address Phone Number The information must be provided and returned with the contract. Signature Date Printed Name Email Phone # Contract No. HUB Subcontracting Plan (HSP) Prime Contractor Progress Assessment Report This form must be completed and submitted to the contracting agency each month to document compliance with your HSP. Contract/Requisition Number: Contracting Agency/University Name: Contractor (Company) Name: Point of Contact: Date of Award: Object Code: (mm/dd/yyyy) State of Texas VID #: Phone #: (Agency Use Only) Reporting (Month) Period: Total Amount Paid this Reporting Period to Contractor: $ - Report HUB and Non-HUB subcontractor information *Texas Certified Total Contract $ Total $ Amount Paid Total Contract $ Subcontractor’s VID or HUB HUB? Amount from HSP This Reporting Period to Amount Paid to Date Object Code Subcontractor’s Name Certificate Number (Yes or No) with Subcontractor Subcontractor to Subcontractor (Agency Use Only) $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ $ - $ TOTALS: $ - $ - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - - $ - Signature: Title: Date: *Note: Prime contractors can verify subcontractor HUB certification status on-line at xxxx://xxx0.xxxx.xxxxx.xx.xx/cmbl/cmblhub.html HSP-PAR Rev. 9/05
Technical Specifications The Technical Specifications furnished on the CD are intended to establish the standards for quality, performance and technical requirements for all labor, workmanship, material, methods and equipment necessary to complete the Work. When specifications and drawings are provided or referenced by the County, these are to be considered part of the Scope of Work, and to be specifically documented in the Detailed Scope of Work. For convenience, the County supplied specifications, if any, and the Technical Specifications furnished on the CD.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Technical Specification As enumerated in Special Conditions of Contract/Scope of Work/attached Drawing/ Details/Schedule of Rates.
General specifications 6.1.1. A vehicle and its electrical/electronic system(s) or ESA(s) shall be so designed, constructed and fitted as to enable the vehicle, in normal conditions of use, to comply with the requirements of this Regulation.
