TEAM RELATIONSHIP Sample Clauses

TEAM RELATIONSHIP. The Owner and the Contractor agree to proceed with the project on the basis of trust, good faith and fair dealing. The Contractor aggress to procure the architectural and engineering services set forth below, and to furnish construction and administration of the Work.
Sample 1
AutoNDA by SimpleDocs
TEAM RELATIONSHIP. 1.1 The Owner and the Design-Builder agree to proceed on the basis of trust, good faith and fair dealing, and shall take all actions reasonably necessary to perform this Agreement in an economical and timely manner. The Owner and the Design-Builders shall perform their obligations with integrity, ensuring at a minimum that: (a) conflicts of interest shall be avoided or disclosed promptly to the other Party; and( b) the Design-Builder and the Owner warrant that they have not and shall not pay nor receive any contingent fees or gratuities to or from the other Party, including their agents, officers and employees, Subcontractors or others for whom they may be liable, to secure preferential treatment.
Sample 1
TEAM RELATIONSHIP. The Owner and the Contractor agree to proceed with the Project on the basis of trust, good faith and fair dealing. The Contractor agrees to procure the architectural and engineering services set forth below, and to furnish construction and administration of the Work.
Sample 1
TEAM RELATIONSHIP. 1.9.1 Design/Builder and Owner recognize that the overall success of the Project may not be achieved unless the goals, needs and perspectives of both Owner and Design/Builder are understood and considered. In recognition of this, Owner and Design/Builder shall proceed with the Project on the basis of trust, good faith and fair dealing, and shall take all actions reasonably necessary to (a) perform their duties under this Agreement in a timely and efficient manner and (b) enable the other party to perform its duties in a timely and efficient manner.
Sample 1
TEAM RELATIONSHIP. The Owner and the Contractor agree to proceed with the Project on the basis of trust, good faith and fair dealing, and shall take all actions reasonably necessary to perform this Agreement in an economical and timely manner, including consideration of design modifications and alternative materials or equipment that will permit the Work to be constructed within the Guaranteed Maximum Price (“GMP”) and by the date of Substantial Completion, as established by Amendment No.1 to this Agreement. The Contractor agrees to procure all required architectural and/or engineering services set forth below, and to furnish construction and administration of the Work as set forth below.
Sample 1
TEAM RELATIONSHIP. Owner and Fluor Xxxxxx agree to proceed with the Work ----------------- on the basis of trust, good faith and fair dealing.
Sample 1
TEAM RELATIONSHIP. The Design-Builder and Engineer agree to work together on the basis of trust, good faith and fair dealing, and shall take actions reasonably necessary to enable each other to perform their obligations under this Agreement in a timely, efficient and economical manner.
Sample 1
AutoNDA by SimpleDocs
TEAM RELATIONSHIP. The Architect/Engineer and the Design-Builder agree to cooperate with each other and to exercise their skill and judgment in the performance of their duties and obligations under this Agreement. The Architect/Engineer and the Design-Builder each represent that they possess the requisite skill, expertise, and licensing to perform the required services. The Design-Builder and Architect/Engineer agree to work together on the basis of good faith and fair dealing.
Sample 1

Related to TEAM RELATIONSHIP

  • Independent Relationship This Agreement is not intended to constitute, create, give effect to or otherwise recognize a joint venture, partnership, or formal business organization, or agency agreement of any kind, and the rights and obligations of the Parties shall be only those expressly set forth herein.

  • General Relationship Executive shall be considered an employee of the Company within the meaning of all federal, state and local laws and regulations including, but not limited to, laws and regulations governing unemployment insurance, workers’ compensation, industrial accident, labor and taxes.

  • No Employment Relationship Whether or not any Options are to be granted under this Plan shall be exclusively within the discretion of the Plan Administrator, and nothing contained in this Plan shall be construed as giving any person any right to participate under this Plan. The grant of an Option shall in no way constitute any form of agreement or understanding binding on the Company or any Related Company, express or implied, that the Company or any Related Company will employ or contract with an Optionee, for any length of time, nor shall it interfere in any way with the Company’s or, where applicable, a Related Company’s right to terminate Optionee’s employment at any time, which right is hereby reserved.

  • Consulting Relationship During the term of this Agreement, Consultant will provide consulting services to the Company (the “Services”). Consultant shall use Consultant’s best efforts to perform the Services such that the results are satisfactory to the Company. Any consulting relationship between the Company and Consultant, whether commenced prior to or upon the date of this Agreement, shall be referred to herein as the “Consulting Relationship”.

  • Commercial Relationship The Employee expressly acknowledges that the Employee’s participation in the Program and the Company’s grant of the Award does not constitute an employment relationship between the Employee and the Company. The Employee has been granted the Award as a consequence of the commercial relationship between the Company and the Company’s Subsidiary in Mexico that employs the Employee, and the Company’s Subsidiary in Mexico is the Employee’s sole employer. Based on the foregoing: (a) the Employee expressly acknowledges that the Program and the benefits derived from participation in the Program do not establish any rights between the Employee and the Subsidiary in Mexico that employs the Employee; (b) the Program and the benefits derived from participation in the Program are not part of the employment conditions and/or benefits provided by the Subsidiary in Mexico that employs the Employee; and (c) any modifications or amendments of the Program or benefits granted thereunder by the Company, or a termination of the Program by the Company, shall not constitute a change or impairment of the terms and conditions of the Employee’s employment with the Subsidiary in Mexico.

  • At-Will Relationship I understand and acknowledge that my Relationship with the Company is and shall continue to be at-will, as defined under applicable law, meaning that either I or the Company may terminate the Relationship at any time for any reason or no reason, without further obligation or liability.

  • Relationship The relationship of the parties to this Agreement is determined solely by the provisions of this Agreement. The parties do not intend to create any agency, partnership, joint venture, trust, fiduciary or other relationship with duties or incidents different from those of parties to an arm’s-length contract.

  • Reporting Relationship Executive shall report to the Company’s chief executive officer.

  • Banking Relationship Borrower shall at all times maintain its primary banking relationship with Silicon.

  • Independent Contractor Relationship SELLER is an independent contractor in all its operations and activities hereunder. The employees used by SELLER to perform Work under this Contract shall be SELLER's employees exclusively without any relation whatsoever to LOCKHEED XXXXXX.

Time is Money Join Law Insider Premium to draft better contracts faster.