Limitation of Liability Insert the following Section 15, after Section 14:
Special Damages shall have the meaning as set forth in Section 5.07.
Cover Damages means, with respect to any Delivery Shortfall, an amount equal to (a) the positive net amount, if, any, by which the Replacement Price exceeds the applicable Price that would have been paid pursuant to Section 5.1 and the Cover Sheet, multiplied by the quantity of that Delivery Shortfall, plus (b) any applicable penalties and other costs assessed by ISO-NE or any other Person against Buyer as a result of Seller’s failure to deliver such Products in accordance with the terms of this Agreement. Buyer shall provide a statement for the applicable period explaining in reasonable detail the calculation of any Cover Damages.
Punitive Damages are those damages awarded as a penalty, the amount of which is neither governed nor fixed by statute.
Actual Damages has the meaning set forth in Section 12.4(C).
Consequential Damages means Losses claimed to have resulted from any indirect, incidental, reliance, special, consequential, punitive, exemplary, multiple or any other Loss, including damages claimed to have resulted from harm to business, loss of anticipated revenues, savings, or profits, or other economic Loss claimed to have been suffered not measured by the prevailing Party’s actual damages, and any other damages typically considered consequential damages under Applicable Law, regardless of whether the Parties knew or had been advised of the possibility that such damages could result in connection with or arising from anything said, omitted, or done hereunder or related hereto, including willful acts or omissions.
Indemnified Damages shall have the meaning assigned to such term in Section 6(a).
Compensatory Damages are those amounts awarded to compensate for the actual damages sustained, and are not awarded as a penalty, nor fixed in amount by statute.
Delay Damages means the damages assessed pursuant to Section 3.2(a) hereof.
Attorneys’ Fees means the full and actual cost of any legal services actually performed in connection with the matter involved calculated on the basis of the usual fee charged by the attorney performing such services and shall not be limited to "reasonable attorneys' fees" as defined in any statute or rule of court.
Economic damages means objectively verifiable monetary losses, including medical expenses, loss of earnings, burial costs, loss of use of property, cost of replacement or repair, cost of obtaining substitute domestic services, loss of employment, and loss of business or employment opportunities.
Indemnification Obligations means each of the Debtors’ indemnification obligations in place as of the Effective Date, whether in the bylaws, certificates of incorporation or formation, limited liability company agreements, other organizational or formation documents, board resolutions, management or indemnification agreements, or employment or other contracts, for their current and former directors, officers, managers, employees, attorneys, accountants, investment bankers, and other professionals and agents of the Debtors, as applicable.
Seller Damages shall have the meaning given to such term in Section 14.3.
Indemnification Provisions means each of the Debtors’ indemnification provisions currently in place whether in the Debtors’ bylaws, certificates of incorporation, other formation documents, board resolutions, or contracts for the current and former directors, officers, managers, employees, attorneys, other professionals, and agents of the Debtors and such current and former directors’, officers’, and managers’ respective Affiliates.
Direct Damage has the meaning given to it in clause 26.2;
Indemnification Obligation means any existing or future obligation of any Debtor to indemnify current and former directors, officers, members, managers, agents or employees of any of the Debtors who served in such capacity, with respect to or based upon such service or any act or omission taken or not taken in any of such capacities, or for or on behalf of any Debtor, whether pursuant to agreement, the Debtors’ respective memoranda, articles or certificates of incorporation or formation, corporate charters, bylaws, operating agreements, limited liability company agreements, or similar corporate or organizational documents or other applicable contract or law in effect as of the Effective Date, excluding any obligation to indemnify any of the foregoing parties with respect to any act or omission for or on behalf of the Debtors arising out of any act or omission determined by a Final Order to constitute actual fraud, willful misconduct, or gross negligence.
Environmental Damages means all claims, judgments, damages, losses, penalties, fines, liabilities, encumbrances, liens, costs and expenses of investigation and defense of any claim, including, without limitation, attorney’s fees, that are incurred at any time as a result of the existence of Environmental Conditions upon, about or beneath the Project Site or migrating or threatening to migrate to or from the Site, and including, without limitation:
Damages means any loss, claim, damage, liability, costs and expenses (including, without limitation, reasonable attorney's fees and disbursements and costs and expenses of expert witnesses and investigation).
Daily Delay Damages means with respect to a Guaranteed Project Milestone, an amount equal to (a) the Project Development Security Amount posted as of the first date that Daily Delay Damages are payable under this Agreement with respect to such Guaranteed Project Milestone, divided by (b) 120.
Express warranty means an express warranty as set forth in sections 4-2-313 and 4-2.5-210, C.R.S. An express warranty shall cover every part of a new facilitative device.
Attorneys’ Fees and Expenses means such funds as may be awarded to Class Counsel by the Court to compensate them (and all other attorneys for Plaintiff or the Settlement Class) for their fees and all expenses incurred by Plaintiff or Class Counsel in connection with the Litigation.
Noneconomic damages ’ means damages for phys-
Indemnifiable Damages shall have the meaning set forth in Section 9.1 herein.
Resale Damages means, with respect to any Rejected Purchase, an amount equal to (a) the positive net amount, if any, by which the applicable Price that would have been paid pursuant to Section 4.4 hereof for such Rejected Purchase, had it been accepted, exceeds the Resale Price multiplied by the quantity of that Rejected Purchase, plus (b) any applicable penalties assessed by ISO-NE or any other Person against Seller as a result of Buyer’s failure to accept such Products. Seller shall provide a written statement explaining in reasonable detail the calculation of any Resale Damages.
Breach of Agreement provisions of Section 5(a)(ii) will apply to Party A and will not apply to Party B.