Owner’s Right to Perform Work. The Owner reserves the right to perform construction or operations related to the Project with Separate Contractors on the Site. If the Contractor claims that delay or additional cost is because of such action by the Owner, the Contractor shall assert such claims as provided in Section 5, Part 2 of the General Conditions.
Owner’s Right to Perform Work. The Owner reserves the right to perform construction or operations related to the Project with Separate Contractors on the Site. If the CM/GC claims that delay or additional cost is because of such action by the Owner, the CM/GC shall assert such claims as provided in Section 5, Part 2 of the General Requirements.
Owner’s Right to Perform Work. In the event Owner issues such instructions to stop Work, and in the further event that Design/Builder fails and refuses within seven (7) days of receipt of same to provide adequate assurance to Owner that the cause of such instructions will be eliminated or corrected, then Owner shall have the right to carry out the Work with its own forces, or with the forces of other contractors, and Design/Builder shall be fully responsible for the reasonable costs incurred in performing such Work. The rights set forth in Paragraph 12.12 and this Paragraph 12.13 are in addition to, and without prejudice to, any other rights or remedies Owner may have against Design/Builder, including the rights to terminate or withhold payment as provided herein.
Owner’s Right to Perform Work. 6.3.1 If the Contractor's work is stopped by the Owner under Paragraph 6.2, and the Contractor fails within seven (7) days of such stoppage to provide adequate assurance to the Owner that the cause of such stoppage will be eliminated or corrected, then the Owner may, without prejudice to any other rights or remedies the Owner may have against the Contractor, proceed to carry out the subject work. In such a situation, an appropriate Change Order shall be issued deducting from the Contract Price the cost of correcting the subject deficiencies, plus compensation for the Engineer's additional services and expenses necessitated thereby, if any. If the unpaid portion of the Contract Price is insufficient to cover the amount due the Owner, the Contractor shall pay the difference to the Owner.
Owner’s Right to Perform Work. And to Award Separate Contracts; and Cooperation with Separate Contractors
Owner’s Right to Perform Work. Owner shall have the right but not the obligation to perform, an behalf of and for the account of Tenant, subject to reimbursement of the cost thereof by Xxxxxx, any and all of the Tenant’s Work which Owner determines, in its sole discretion, should be performed immediately and on an emergency basis for the best interest of the Shopping Center, including without limitation, work which pertains to structural components, mechanical, sprinkler and general utility systems, roofing and removal of unduly accumulated construction material and debris.
Owner’s Right to Perform Work. If Construction Manager defaults or neglects to carry out all or any portion of the Work or correct any Defects in accordance with the terms and conditions of this Agreement, the Owner, without prejudice to any other right or remedy under this Agreement, upon providing five (5) Days written notice to Construction Manager, may perform the Work or correct such Defects, or any part thereof, by whatever methods or means it may deem expedient.
Owner’s Right to Perform Work. If Contractor fails, within three (3) days after written notice from Owner or Professional, to correct defective Work or to remove and replace rejected defective Work as required by Owner or Professional, or if Contractor fails to perform the Work in accordance with the Contract Documents, or if Contractor fails to comply with any of the provisions of the Contract Documents, Owner may, correct and remedy any such deficiency; provided, however, in the event that any defective or non-conforming work is deemed by Owner in its sole discretion to present an immediate threat to safety or security, Owner shall be entitled to immediately correct and fix such defective or non-conforming portions of the Work without three (3) days written notice to Contractor. To the extent necessary to complete corrective and remedial action, Owner may exclude Contractor from any or all of the Project Site, take possession of all or any part of the Work, and suspend Contractor’s services related thereto, take possession of Contractor’s tools, appliances, construction equipment and machinery at the Project Site and incorporate in the Work all materials and equipment stored at the Project site or for which Owner has paid Contractor but which are stored elsewhere. Contractor shall allow Owner, Professional and their respective representatives, agents, and employees such access to the Project Site as may be necessary to enable Owner to exercise the rights and remedies under this Section. All direct, indirect and consequential costs of Owner in exercising such rights and remedies shall be charged against Contractor, and a Change Order shall be issued, incorporating the necessary revisions to the Contract Documents, including an appropriate decrease to the Contract Price. Such direct, indirect and consequential costs shall include fees and charges of engineers, architects, attorneys and other professionals, all court and arbitration costs and all costs of repair and replacement of work of others destroyed or damaged by correction, removal or replacement of Contractor’s defective Work. Contractor shall not be allowed an extension of the Contract Time because of any delay in performance of the Work attributable to the exercise by Owner of Owner’s rights and remedies hereunder.
