Water Rights Water rights and/or water shares used in connection with the Property;
Limitation on Out-of-State Litigation - Texas Business and Commerce Code § 272 This is a requirement of the TIPS Contract and is non-negotiable. Texas Business and Commerce Code § 272 prohibits a construction contract, or an agreement collateral to or affecting the construction contract, from containing a provision making the contract or agreement, or any conflict arising under the contract or agreement, subject to another state’s law, litigation in the courts of another state, or arbitration in another state. If included in Texas construction contracts, such provisions are voidable by a party obligated by the contract or agreement to perform the work. By submission of this proposal, Vendor acknowledges this law and if Vendor enters into a construction contract with a Texas TIPS Member under this procurement, Vendor certifies compliance.
Right to Refuse to Cross Picket Lines (a) All employees covered by this Agreement shall have the right to refuse to cross a picket line arising out of a dispute as defined in the appropriate legislation. Any employees failing to report for duty shall be considered to be absent without pay. (b) Failure to cross a picket line encountered in carrying out the Employer's business shall not be considered a violation of this Agreement nor shall it be grounds for disciplinary action.
Fifth Amended and Restated Limited Liability Company Operating Agreement Dated as of November 30, 2012
International Olympic Committee; International Red Cross and Red Crescent Movement As instructed from time to time by ICANN, the names (including their IDN variants, where applicable) relating to the International Olympic Committee, International Red Cross and Red Crescent Movement listed at xxxx://xxx.xxxxx.xxx/en/resources/registries/reserved shall be withheld from registration or allocated to Registry Operator at the second level within the TLD. Additional International Olympic Committee, International Red Cross and Red Crescent Movement names (including their IDN variants) may be added to the list upon ten (10) calendar days notice from ICANN to Registry Operator. Such names may not be activated in the DNS, and may not be released for registration to any person or entity other than Registry Operator. Upon conclusion of Registry Operator’s designation as operator of the registry for the TLD, all such names withheld from registration or allocated to Registry Operator shall be transferred as specified by ICANN. Registry Operator may self-‐allocate and renew such names without use of an ICANN accredited registrar, which will not be considered Transactions for purposes of Section 6.1 of the Agreement.
Please see the current Washtenaw Community College catalog for up-to-date program requirements Conditions & Requirements
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
Requirements Pertaining Only to Federal Grants and Subrecipient Agreements If this Agreement is a grant that is funded in whole or in part by Federal funds:
RIGHT OF ALLOTTEE TO USE COMMON AREAS AND FACILITIES SUBJECT TO PAYMENT OF TOTAL MAINTENANCE CHARGES The Allottee hereby agrees to purchase the [Apartment/Plot] on the specific understanding that is/her right to the use of Common Areas shall be subject to timely payment of total maintenance charges, as determined and thereafter billed by the maintenance agency appointed or the association of allottees (or the maintenance agency appointed by it) and performance by the Allottee of all his/her obligations in respect of the terms and conditions specified by the maintenance agency or the association of allottees from time to time.
RIGHTS RESERVED TO LANDLORD Landlord may exercise at any time any of the following rights respecting the operation of the Project without liability to the Tenant of any kind: