Obligations of the Authority (i) The Authority shall, at its own cost and expense, undertake, comply with and perform all its obligations set out in this Agreement or arising hereunder. (ii) The Authority shall be responsible for the correctness of the Scope of the Project, Project Facilities, Specifications and Standards and the criteria for testing of the completed Works. (iii) The Authority shall, upon submission of the Performance Security as per the RFP by the Contractor, shall provide to the Contractor: (a) No less than 90% (ninety per cent) of the required Right of Way of the Construction Zone of total length of the Project Highway within a period of 30 (thirty) days from the date of this Agreement, which shall be in contiguous stretches of length not less than 1( One) kilometre. (b) approval of the general arrangement drawings (the “GAD”) from railway authorities to enable the Contractor to construct road over- bridges/ under- bridges at level crossings on the Project Highway in accordance with the Specifications and Standards, and subject to the terms and conditions specified in such approval, within a period of 60 (sixty) days from the Appointed Date, and reimbursement of all the costs and expenses paid by the Contractor to the railway authorities for and in respect of the road over- bridges/ under bridges; and7 (c) all environmental clearances as required under Clause 4.3.8 (iv) Delay in providing the Right of Way or approval of GAD by railway authorities, as the case may be, in accordance with the provisions of Clause 3.1 (iii) shall entitle the Contractor to Damages in a sum calculated in accordance with the provisions of Clause 8.3 of this Agreement and Time Extension in accordance with the provisions of Clause 10.5 of this Agreement. For the avoidance of doubt, the Parties agree that the Damages for delay in approval of GAD by the railway authorities for a particular road over-bridge/ under-bridge shall be deemed to be equal to the Damages payable under the provisions of Clause 8.3 for delay in providing Right of Way for a length of 2 (two) kilometre for each such road over-bridge/ under-bridge.
The Authority As to the Authority, the following section shall survive discharge: Section 2.3 (right to conduct audit).
Amounts and Terms of the Advances SECTION 2.01. The A Advances. (a) Each Lender severally agrees, on the terms and conditions hereinafter set forth, to make A Advances to the Borrower from time to time on any Business Day during the period from the Closing until the Termination Date in an aggregate outstanding amount not to exceed at any time such Lender's Available Commitment, provided that the aggregate amount of the Commitments of the Lenders shall be deemed used from time to time to the extent of the aggregate amount of the B Advances then outstanding and such deemed use of the aggregate amount of the Commitments shall be applied to the Lenders ratably according to their respective Percentages (such deemed use of the aggregate amount of the Commitments being a "B Reduction"). Each A Borrowing shall be in an aggregate amount not less than $10,000,000 (or, if lower, the amount of the Available Commitments) or an integral multiple of $1,000,000 in excess thereof and shall consist of A Advances of the same Type made on the same day by the Lenders ratably according to their respective Percentages. Within the limits of each Lender's Commitment and as hereinabove and hereinafter provided, the Borrower may request Extensions of Credit hereunder, and repay or prepay Advances pursuant to Section 2.11 and utilize the resulting increase in the Available Commitments for further Extensions of Credit in accordance with the terms hereof. (b) In no event shall the Borrower be entitled to request or receive any Extensions of Credit that would cause the principal amount outstanding hereunder to exceed the Commitments.
Access to the Authority and the Authority’s Engineer (i) The Right of Way given to the Contractor hereunder shall always be subject to the right of access of the Authority and the Authority’s Engineer and their employees and agents for inspection, viewing and exercise of their rights and performance of their obligations under this Agreement. (ii) The Contractor shall ensure, subject to all relevant safety procedures, that the Authority has un-restricted access to the Site during any emergency situation, as decided by the Authority’s Engineer.
Amounts and Terms of the Advances and Letters of Credit SECTION 2.01. The Advances and Letters of Credit.
Amounts and Terms of the Purchases SECTION 2.01.
Amounts and Terms of Assignments Each Commitment, Loan or other Obligation may (a) be assigned in any amount to another Lender, or to an Affiliate of the assigning Lender or another Lender, with the giving of notice to Company and Administrative Agent or (b) be assigned in an aggregate amount of not less than $5,000,000 (or such lesser amount as shall constitute the aggregate amount of the Commitments, Loans, and other Obligations of the assigning Lender) to any other Eligible Assignee with the giving of notice to Company and with the consent of Administrative Agent and Company (which consent shall not be unreasonably withheld). Any assignment of Loans hereunder shall effect a pro rata assignment of the Notes with respect to each Financed Aircraft. To the extent of any such assignment in accordance with either clause (a) or (b) above, the assigning Lender shall be relieved of its obligations with respect to its Commitments, Loans, or other Obligations or the portion thereof so assigned. The parties to each such assignment shall execute and deliver to Administrative Agent, for its acceptance and recording in the Register, an Assignment Agreement, together with a processing and recordation fee of $3,000 and such forms, certificates or other evidence, if any, with respect to United States federal income tax withholding matters as the assignee under such Assignment Agreement may be required to deliver to Administrative Agent pursuant to subsection 2.7B(iii)(a); provided, however that such processing fee shall not be required where the assignee is an existing Lender. Upon such execution, delivery and acceptance, from and after the effective date specified in such Assignment Agreement, (y) the assignee thereunder shall be a party hereto and, to the extent that rights and obligations hereunder have been assigned to it pursuant to such Assignment Agreement, shall have the rights and obligations of a Lender hereunder and (z) the assigning Lender thereunder shall, to the extent that rights and obligations hereunder have been assigned by it pursuant to such Assignment Agreement, relinquish its rights and be released from its obligations under this Agreement (and, in the case of an Assignment Agreement covering all or the remaining portion of an assigning Lender's rights and obligations under this Agreement, such Lender shall cease to be a party hereto). The Commitments hereunder shall be modified to reflect the Commitment of such assignee and any remaining Commitment of such assigning Lender and, if any such assignment occurs after the issuance of the Notes hereunder, the assigning Lender shall, upon the effectiveness of such assignment or as promptly thereafter as practicable, surrender its applicable Notes to Administrative Agent for cancellation, and thereupon new Notes shall be issued to the assignee substantially in the form of Exhibit IIIA annexed hereto or Exhibit IIIB, as the case may be, with appropriate insertions, to reflect the new Commitments and/or outstanding Loans, as the case may be, of the assignee and/or the assigning Lender.
Amounts and Terms of the Loans 34 2.1. The Revolving Credit Loans................................................... 34 2.2. Making the Loans............................................................. 35 2.3. Fees......................................................................... 36 2.4. Reduction and Termination of the Commitments................................. 37 2.5. Repayment.................................................................... 37 2.6. Prepayments.................................................................. 38 2.7. Conversion/Continuation Option............................................... 39 2.8. Interest..................................................................... 40 2.9. Interest Rate Determination and Protection................................... 41 2.10.
Applicable Law, Entire Agreement This Agreement will be governed by and construed in accordance with the law of the State of New York. This Agreement supersedes all prior agreements and understandings relating to the subject matter hereof.
Sole and Entire Agreement The parties acknowledge that this Arbitration Agreement constitutes the complete agreement of the parties on the subject matter contained herein, and supersedes any prior or contemporaneous oral or written agreement or understanding on the subject matter contained herein.
