Anticipated Project Schedule. The schedule will be verified upon approval of the Schematic Design and phasing plans. The following project milestones as referenced in Section 1.1.1 and Section 1.1.2 are as follows:
Anticipated Project Schedule. 1. PEC shall commence its services on the Project within 7 days after receiving Client’s notice to proceed.
2. PEC and Client anticipate that the design duration to complete construction documents will be approximately 3 months after receiving Notice to Proceed. The design schedule is dependent on the Planning requirements of the City of Xxxxxxxx.
3. Client acknowledges that directed changes, unforeseen conditions, and other delays may affect the completion of PEC’s services. PEC will not have control over or responsibility for any contractor or vendor’s performance schedule.
4. Project deliverable schedules will be impacted by untimely receipt of information.
Anticipated Project Schedule. Site Visit – Early April 2021.
Anticipated Project Schedule. 1. The fully executed copy of the contract will serve as PEC's notice to proceed with the services.
2. PEC shall commence its services on the Project within 14 days after receiving CLIENT’s notice to proceed.
3. PEC shall complete the scope of services within a mutually agreed upon schedule.
4. CLIENT acknowledges that directed changes, unforeseen conditions, and other delays may affect the completion of PEC’s services. PEC will not have control over or responsibility for any contractor or vendor’s performance schedule.
Anticipated Project Schedule. Anticipated timeline for completing the Project in accordance with the estimated project budget.
Anticipated Project Schedule. The anticipated time line is as follows: July 5, 2018 Issuance of RFQ/SOI July 31, 2018 Last date for respondents to request a meeting with the Borough agent(s)-such a meeting is not required. August 10, 2018 Responses are due. September 10, 2018 (week of) Response conference(s) and review by the Borough. September 17, 2018 Notification of Potential Qualified Respondents October, 2018 Borough Council Review and Due Diligence The project timetable relating to authorization and/or implementation will be established at the conclusion of this step.
Anticipated Project Schedule. The following is an outline of the anticipated schedule for the proposal review and contract award. Schedule is subject to change. February 27, 2022 March 9, 2022 March 14, 2022 12:00 PM March 16, 2022 March 23, 2022 4:00 PM March 25-April 4, 2022 April 8, 2022 TBD
Anticipated Project Schedule. The schedule will be verified upon approval of the Schematic Design and phasing plans. The following project milestones as referenced in Section 1.1.1 and Section 1.1.2 are as follows: Begin design Scope-to-Budget/Program Verification 100% Schematic Design 100% Design Development 60% Construction Documents 60% Cost review 100% Construction Documents 100% Cost review Obtain permit; revise documents after permitting and HISD review; issue Bid Documents Obtain pricing; negotiate and execute contract; issue Notice to Proceed Substantial Completion / Obtain C-of-O Complete punch list Texas Department of Licensing and Regulations (TDLR) inspection, resolution of issues, and approval
Anticipated Project Schedule. 1. Develop an anticipated Project Schedule, including durations for design and subsequent construction.
Anticipated Project Schedule. The anticipated project schedule, included as Attachment 2, assumes approval of an Interlocal Agreement between the City and TCRPC in October, with project initiation in October 2020 and completion in May 2021. The schedule identifies tasks, lead entity (e.g., TCRPC, City staff), and anticipated timeframe for completion of work.
