Project Fund (a) All proceeds of the Governmental Lender Notes provided by the Funding Lender shall be deposited to the Note Proceeds Account or Capitalized Interest Account of the Project Fund and disbursed as herein provided. The Fiscal Agent shall disburse moneys in the Note Proceeds Account of Project Fund for the acquisition, construction and equipping of the Project, to pay other Qualified Project Costs and to pay other costs related to the Project as provided herein as requested by the Borrower pursuant to a Written Requisition in the form attached hereto as Exhibit C. All funds deposited by or on behalf of the Borrower for credit to the Borrower Equity Account Project Fund shall be disbursed as requested by the Borrower pursuant to a Written Requisition in the form attached hereto as Exhibit C. Before any payment shall be made from the Project Fund, the Regulatory Agreement shall have been executed and submitted to a title company for recordation in the official records of Travis County, Texas, and there shall be filed with the Fiscal Agent a Written Requisition of the Borrower substantially in the form attached hereto as Exhibit C and approved by the Funding Lender pursuant to the terms, conditions and provisions of the Construction Funding Agreement. In addition to the above, in connection with a Written Requisition:
(1) Only the signature of an Authorized Representative of the Funding Lender shall be required on a Written Requisition during any period in which Borrower Loan Agreement Default has occurred and is then continuing under the Borrower Loan Documents (Written Notice of which default has been given by an Authorized Representative of the Funding Lender to the Fiscal Agent and the Governmental Lender, and the Fiscal Agent shall be entitled to conclusively rely on any such Written Notice as to the occurrence and continuation of such a default).
(2) The Fiscal Agent shall disburse amounts in the Project Fund for the payment of interest due on the Governmental Lender Note upon receipt from the Funding Lender of a statement detailing the amount due (and without the need for a Written Requisition signed by the Funding Lender or any approval by an Authorized Representative of the Borrower).
(3) The Fiscal Agent may conclusively rely on all Written Requisitions, the execution of the Written Requisitions by the Authorized Representative of the Borrower and the approval of all Written Requisitions by the Authorized Representative of the Funding Lender, as required by this Section, as conditions of payment from the Project Fund, which Written Requisitions constitute, as to the Fiscal Agent, irrevocable determinations that all conditions to payment of the specified amounts from the Project Fund have been satisfied. These documents shall be retained by the Fiscal Agent, subject at all reasonable times to examination by the Borrower, the Governmental Lender, the Funding Lender and the agents and representatives thereof upon reasonable notice to the Fiscal Agent. The Fiscal Agent is not required to inspect the Project or the construction work or to make any independent investigation with respect to the matters set forth in any Written Requisition or other statements, orders, certifications and approvals received by the Fiscal Agent. The Fiscal Agent is not required to obtain completion bonds, lien releases or otherwise supervise the acquisition, construction, renovation, equipping, improvement and installation of the Project.
(b) Upon receipt of each Written Requisition submitted by the Borrower and Approved in Writing by the Funding Lender, the Fiscal Agent shall promptly, but in any case within three Business Days, make payment from the appropriate account within the Project Fund in accordance with such Written Requisition. The Fiscal Agent shall have no duty to determine whether any requested disbursement from the Note Proceeds Account of the Project Fund complies with the terms, conditions and provisions of the Funding Loan Documents, constitutes payment of Qualified Project Costs or complies with the other representations in the Written Requisition. The Approval in Writing of a Written Requisition by the Funding Lender shall be deemed a certification and, insofar as the Fiscal Agent is concerned, shall constitute conclusive evidence that all of the terms, conditions and requirements of the Funding Loan Documents applicable to such disbursement have been fully satisfied or waived and the Written Requisition from the Borrower shall, insofar as the Fiscal Agent is concerned, constitute conclusive evidence that the costs described in the Written Requisition constitute Qualified Project Costs or other permitted Project costs.
(c) Moneys on deposit in the Capitalized Interest Account of the Project Fund, together with investment earnings thereon, which shall be retained therein, shall be transferred to the Governmental Lender Note Payment Fund and applied pursuant to Section 7.4 on each Borrower Loan Payment Date to the extent necessary to enable the Fiscal Agent to pay interest due on the Funding Loan on such date; provided that, upon receipt of a Written Direction of the Borrower, moneys on deposit in the Capitalized Interest Account of the Project Fund shall be transferred to the Servicer on the date when due under the Borrower Note in an amount as set forth in such Written Direction, which amount shall represent the Borrower Loan Payment due at such time. Upon the request of the Fiscal Agent, the Servicer shall provide the Fiscal Agent with a schedule of the Borrower Loan Payment Dates and corresponding Borrower Loan Payment amounts. The transfer of moneys from the Capitalized Interest Account of the Project Fund to the Governmental Lender Note Payment Fund or the Servicer as set forth above shall occur automatically without the need for a Written Requisition of the Borrower, or consent of the Funding Lender. After the Closing Date, the Borrower, with the written consent of the Funding Lender, may deposit additional funds into the Capitalized Interest Account.
(d) Immediately prior to any mandatory prepayment of the Governmental Lender Notes pursuant to the terms hereof, any amounts then remaining in the Project Fund shall, at the Written Direction of the Funding Lender, be transferred to the Governmental Lender Note Payment Fund to be applied to the prepayment of the Governmental Lender Notes pursuant hereto.
(e) Amounts on deposit in the Project Fund shall be invested in Permitted Investments at the Written Direction of the Borrower. Investment income earned on amounts on deposit in each account of the Project Fund shall be retained in and credited to and become a part of the amounts on deposit in that account of the Project Fund.
(f) Amounts on deposit in the Governmental Lender Note Payment Fund, Expense Fund and Closing Costs Fund shall be invested in Permitted Investments at the Written Direction of the Borrower. The Fiscal Agent shall have no discretion for investing funds or advising any party on investing funds. Investment income earned on amounts on deposit in each account of the Governmental Lender Note Payment Fund, Expense Fund and Closing Costs Fund shall be retained in and credited to and become a part of the amounts on deposit in that account of the Governmental Lender Note Payment Fund, Expense Fund and Closing Costs Fund. In the absence of Written Direction from the Borrower, such amounts shall be invested by the Fiscal Agent only in investments described in (e) of the definition of Permitted Investments. The Fiscal Agent is authorized to implement its automated cash investment system to assure that cash on hand is invested and to charge its normal cash management fees, which may be deducted from income earned on investments. The Fiscal Agent shall not be liable for any losses (including, specifically depreciation of value) resulting from investments made in Permitted Investments. The Fiscal Agent shall not be responsible for the Governmental Lender Notes becoming "arbitrage bonds" as defined in the Code when it makes investments pursuant to the terms hereof. The Fiscal Agent may make any and all investments permitted under this Funding Loan Agreement through its own trust or banking department or any Affiliate and may pay said department reasonable, customary fees for placing such investments. The Fiscal Agent and its Affiliates may act as principal, agent, sponsor, advisor or depository with respect to Permitted Investments under this Funding Loan Agreement. The Fiscal Agent shall have no responsibility or liability for any loss which may result from any investment or sale of investment made pursuant to this Funding Loan Agreement. The Fiscal Agent is hereby authorized in making or disposing of any investment permitted by this Funding Loan Agreement, to deal with itself (in its individual capacity) or with any one or more of its affiliates, whether it or any such affiliate is acting as agent of the Fiscal Agent or for any third person or dealing as principal for its own account. The Governmental Lender, the Funding Lender and the Borrower acknowledge that the Fiscal Agent is not providing investment supervision, recommendations, or advice. The Governmental Lender, the Funding Lender and the Borrower (by its execution of the Borrower Loan Agreement) acknowledge that to the extent regulations of the Comptroller of the Currency or other applicable regulatory entity grant the Governmental Lender or the Funding Lender the right to receive brokerage confirmations of security transactions as they occur, the Governmental Lender and the Funding Lender will not receive such confirmations to the extent permitted by law. The Fiscal Agent shall furnish the Borrower, the Funding Lender and the Governmental Lender (to the extent requested by such parties) periodic cash transaction statements which shall detail for all investment transactions, if any, made by the Fiscal Agent hereunder.
(g) Unless otherwise approved by the Governmental Lender and the Funding Lender, any amounts representing proceeds of the Funding Loan remaining on deposit in any fund or account held under this Funding Loan Agreement on the Outside Conversion Date, shall be immediately transferred to the Funding Loan Payment Account and used to prepay the Governmental Lender Notes.
Project Cost Overruns In the event that the Recipient determines that the moneys granted pursuant to Section II hereof, together with the Local Subdivision Contribution, are insufficient to pay in full the costs of the Project, the Recipient may make a request for supplemental assistance to its District Committee. The Recipient must demonstrate that such funding is necessary for the completion of the Project and the cost overrun was the result of circumstances beyond the Recipient's control, that it could not have been avoided with the exercise of due care, and that such circumstances could not have been anticipated at the time of the Recipient's initial application. Should the District Committee approve such request the action shall be recorded in the District Committee's official meeting minutes and provided to the OPWC Director for the execution of an amendment to this Agreement.
Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shall submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the general conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over-Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (i), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease.
Completion of Concrete Pours and Emergency Work (a) Except as provided in this sub-clause an Employee shall nor work or be required to work in the rain.
(b) Employees shall not be required to start a concrete pour in Inclement Weather.
(c) Where a concrete pour has been commenced prior to the commencement of a period of Inclement Weather Employees may be required to complete such concrete pour to a practical stage and for such work shall be paid at the rate of double time calculated to the next hour, and in the case of wet weather shall be provided with adequate wet weather gear.
(d) If an Employee’s clothes become wet as a result of working in the rain during a concrete pour the Employee shall, unless the Employee has a change of dry working clothes available, be allowed to go home without loss of pay.
(e) The provisions of clauses 32.7(c) and 32.7(d) hereof shall also apply in the case of emergency work where the Employees concerned and their delegates agree that the work is of an emergency nature and can start and/or proceed.
Project Costs Simultaneously with the execution of this Agreement, the Company shall disclose to the Department all of the Project Costs which the Company seeks to include for purposes of determining the limitation of the amount of the Credit pursuant to Section 5-30 of the Act and provide to the Department a Schedule of Project Costs in the form as attached hereto as Exhibit C.
Construction Budget The total amount of funds indicated by the District for the entire Project plus all other costs, including design, construction, administration, and financing.
Cost Overruns The Borrower shall ensure that all cost-overruns over the estimated construction costs of the Project as certified by a quantity surveyor or the Architect or as ascertained by the Lender as and when they occur shall be funded by the Borrower’s own equity;
Project Completion Date It is agreed between the Parties that the Project Completion Date is <END DATE, YEAR>. If the Project is not completed by such date then, subject to an amendment agreed to between the Parties, Alberta Innovates may elect to terminate this Investment Agreement. In such event, Alberta Innovates will notify the Applicant of its decision to terminate as soon as reasonably practical and shall advise the Applicant of the effective date of termination. Alberta Innovates will have no liability or obligation to reimburse the Applicant for any Project Costs incurred after the effective date of termination and may require the Applicant to return any portions of the Investment which were spent on Ineligible Expenses. Additionally, any portion of the Investment not used and accounted for in accordance with this Agreement as of the Project Completion Date or earlier termination is repayable by the Applicant to AI at AI’s request.
Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof.
(ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii).
(iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii).
(iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.
Construction Phase Part 1 –
