Aircraft Basic Price The Aircraft Basic Price is listed in Table 1 and is subject to escalation in accordance with the terms of this Purchase Agreement.
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Return of Aircraft 64 23.1 Date of Return................................................64 23.2
Use of Aircraft Employees shall not be required to use an aircraft in the course of their duties other than those of regular commercial airlines, licensed charters, or government aircraft.
AIRCRAFT CONFIGURATION The guarantees defined below (the “Guarantees”) are applicable to the A319-100 Aircraft as described in the Standard Specification Ref. J 000 01000 Issue 6 dated 1st March 2007 equipped with:
Lease of Aircraft Lessor agrees to lease the Aircraft to Lessee pursuant to the provisions of FAR Section 91.501(b)(6) and Section 91.501(c)(1) and this Agreement, and to provide a fully-qualified and credentialed flight crew for all flights to be conducted hereunder during the Term (as defined in Section 13) hereof. The parties acknowledge and agree that this Agreement did not result in any way from any direct or indirect advertising, holding out or soliciting on the part of Lessor or any person purportedly acting on behalf of Lessor. Lessor and Lessee intend that the lease of the Aircraft effected by this Agreement shall be treated as a “wet lease” pursuant to which Lessor provides transportation services to Lessee in accordance with FAR Section 91.501(b)(6) and Section 91.501(c)(1).
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Delivery Schedule The Goods specified in the List of Goods are required to be delivered within the acceptable time range (after the earliest and before the final date, both dates inclusive) specified in Section V, Schedule of Requirements. No credit will be given to deliveries before the earliest date, and Tenders offering delivery after the final date shall be treated as non-responsive. Within this acceptable period, an adjustment of [insert the adjustment factor], will be added, for evaluation purposes only, to the Tender price of Tenders offering deliveries later than the “Earliest Delivery Date” specified in Section V, Schedule of Requirements.
Agreement Xxx 0000 The Company shall not produce iron ore under this Agreement for transportation in any calendar year in excess of the approved production limit nor shall the total number of the mine workforce exceed the approved mine workforce without the prior consent in principle of the Minister and, subject to that consent, approval of detailed proposals in regard thereto in accordance with this Clause.
