Completion of Service Following Receipt of Objection Notice Sample Clauses

Completion of Service Following Receipt of Objection Notice. In the event of receipt by the Service Provider of an Objection Notice in accordance with Clause 7.5, the Service Provider shall:
Sample 1Sample 2Sample 3See All (10)
AutoNDA by SimpleDocs
Completion of Service Following Receipt of Objection Notice. In the event of receipt by the Service Provider of an Objection Notice in accordance with Clause 7.6, the Service Provider shall: take due account of all Defects, irrespective of their extent or nature, and other matters raised in the Objection Notice; as soon as reasonably practicable, correct such Defects and deficiencies, irrespective of their extent or nature, and complete the Works indicated in the Objection Notice so as to comply in all material respects with the requirements of this Agreement; and issue to the Principal a second Provisional Completion Certificate substantially in the form of Annex G (Provisional Completion Certificate). The second Provisional Completion Certificate issued in accordance with Clause 7.7(c) shall include the Deliverable and adequate supporting documentation relevant to the Service Milestone attained and/or Deliverable completed. In the event no reasons for objection to the second Provisional Completion Certificate exist, the Principal shall, within reasonable time following receipt of the second Provisional Completion Certificate, issue a Certificate of Provisional Acceptance in the form of Annex H (Provisional Acceptance Certificate) and, subject to the provisions of Clauses 3.6 and 8.1(b) of this Agreement, the date of the Provisional Acceptance Certificate shall constitute “Completion Date” with respect to the relevant Service Milestone and/or Deliverable. In the event the Principal objects to the issuance of a Provisional Completion Certificate, it shall give second Objection Notice to the Service Provider setting out in reasonable detail Defects or reasons for the objection within reasonable time following receipt of the second Provisional Completion Certificate. For the avoidance of any doubt, the giving by the Principal of any Objection Notice under Clause 7.6 or second Objection Notice under this Clause 7.7 shall be without prejudice to and shall not relieve the Service Provider from the obligation to pay any contractual penalty in accordance with the provisions of Clause 17.2 or to pay Damages in accordance with the provisions Clause 17.3 of this Agreement.
Sample 1

Related to Completion of Service Following Receipt of Objection Notice

  • Notice of Objection Contractor may object to any action taken by NYSERDA pursuant to this Exhibit that prevents the commencement of the time in which interest will be paid by submitting a written notice of objection to NYSERDA. Such notice shall be signed and dated and concisely and clearly set forth the basis for the objection and be addressed to the Vice President, New York State Energy Research and Development Authority, at the notice address set forth in Exhibit B to this Agreement. The Vice President of NYSERDA, or his or her designee, shall review the objection for purposes of affirming or modifying NYSERDA‘s action. Within fifteen (15) working days of the receipt of the objection, the Vice President, or his or her designee, shall notify the Contractor either that NYSERDA‘s action is affirmed or that it is modified or that, due to the complexity of the issue, additional time is needed to conduct the review; provided, however, in no event shall the extended review period exceed thirty (30) working days.

  • Response to Objections Each Party retains the right to respond to any objection raised by a Participating Class Member, including the right to file responsive documents in Court no later than five court days prior to the Final Approval Hearing, or as otherwise ordered or accepted by the Court.

  • Additional Wet Weather Procedure 14.15.1 Remaining On Site Where, because of wet weather, the employees are prevented from working:

  • Completion of Evaluation Cycle 1. The summative evaluation rating shall be based upon a preponderance of the evidence, assessed in a holistic manner, that is aligned to the Ohio Educator Standards. Only evidence gathered during the walkthroughs and formal observations that are conducted for the current school year may be used.

  • SUBMISSION OF THE MONTHLY MI REPORT 4.1 The completed MI Report shall be completed electronically and returned to the Authority by uploading the electronic MI Report computer file to MISO in accordance with the instructions provided in MISO.

  • Dispute Notice If there is a dispute between the parties, then either party may give a notice to the other succinctly setting out the details of the dispute and stating that it is a dispute notice given under this clause 17.1.

  • Completion of Services (a) The Customer must:

  • Payment for Material Completion The Contractor may request payment of the remaining contract balance, including retainage, less amounts credited the Owner or incurred as liquidated damages, and less amounts withheld for the Punchlist by reason of Minor Items or Permitted Incomplete Work (See Paragraph 6.5.3.2). Payment for Material Completion shall be made by a check payable jointly to the Contractor and Surety and shall be mailed to the Surety.

  • Renewal Notice; Notification of Changes Subject to governing law, XOOM can renew this Agreement with new or revised Terms. XOOM will send you written notice at least (30) days before the end of the Term. The notice will specify the date by which you must advise XOOM if you do not want to renew your Agreement. If you do not advise XOOM by the specified date, this Agreement will automatically renew at the fixed rate or variable rate then in effect in accordance with the notice. XOOM reserves the right, with fifteen (15) days’ notice, to amend this Agreement to adjust its service to accommodate any change in regulations, law, tariff or other change in procedure required by any third party that may affect XOOM’s ability to continue to serve you under this Agreement.

  • EFFECTIVE DATE/COMPLETION OF SERVICES 3.1 Notwithstanding any provision of this Agreement to the contrary, and subject to the approval of the Governor and Executive Council of the State of New Hampshire, if applicable, this Agreement, and all obligations of the parties hereunder, shall become effective on the date the Governor and Executive Council approve this Agreement as indicated in block 1.17, unless no such approval is required, in which case the Agreement shall become effective on the date the Agreement is signed by the State Agency as shown in block 1.13 (“Effective Date”).

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!