CONDITION OF PREMISES; DELIVERY OF POSSESSION Sample Clauses

CONDITION OF PREMISES; DELIVERY OF POSSESSION. Upon both parties having entered into this Lease, and Tenant providing Landlord (i) the Security Deposit as required under Section 5(a) below, (ii) the Letter of Credit as required by Section 5(b) below, and (iii) such documents or other information reasonably required in connection with delivering possession of the Premises, including without limitation evidence that Tenant has obtained the insurance required hereunder, Landlord shall deliver possession of the Premises (“Delivery Date”) to Tenant in its current “as is” condition (except for any latent defects within the Building or existing Hazardous Materials (as defined in Section 4(b) below)) on, within, or under the Premises and subject to Landlord’s ongoing maintenance and repair obligations set forth under the terms of this Lease. Except for the existence of latent defects or existing Hazardous Materials (if any), Tenant’s taking possession of the Premises to construct Tenant’s Work (as defined in and pursuant to Exhibit B) shall otherwise (a) be deemed acceptance of the Premises by Tenant in their current condition, “as is”; (b) conclusively establish that the Premises is in good and satisfactory condition as of the date Tenant takes possession; and (c) be deemed Tenant’s representation that (other than the foregoing latent defects or existing Hazardous Materials) it has inspected the Premises and is aware of the current condition of the Premises. Notwithstanding any provision in this Lease to the contrary, all terms and conditions of this Lease and all obligations of Tenant hereunder shall be in full force and effect from and after the Effective Date, except that Tenant’s obligation to pay Base Rent shall become effective upon the Commencement Date; and Tenant shall pay Tenant’s Share of the Expenses and Taxes as provided in Paragraph D of the Basic Lease Provisions.
Sample 1
AutoNDA by SimpleDocs

Related to CONDITION OF PREMISES; DELIVERY OF POSSESSION

  • Delivery of Premises If the Landlord shall be unable to give possession of the Premises, exclusively the Suite 200 Premises and the Suite 246 Premises, on the Fourth Expansion Premises Commencement Date by reason of (i) the Landlord work is not substantially complete, (ii) the holding over or retention of possession of any tenant, tenants or occupants, or (iii) for any other reason, then Landlord shall not be subject to any liability for the failure to give possession on said date. Under such circumstances the Base Rent to be paid herein shall not commence until the Premises (exclusively the Suite 200 Premises and the Suite 246 Premises) are made available to Tenant by Landlord, and no such failure to give possession on the Fourth Expansion Premises Commencement Date shall affect the validity of this Sixth Amendment to Office Building Lease or the obligations of the Tenant hereunder. The Base Rents due hereunder will be adjusted at the time that any or all of the Fourth Expansion Premises are delivered to Tenant substantially complete to reflect the same underlying effective rent of the rent structure specific to each suite with the lease expiration dates to remain unchanged. Notwithstanding the foregoing, if the Fourth Expansion Premises Commencement Date for the Suite 200 Premises together with the Suite 246 Premises has not occurred within ninety (90) days after the Fourth Expansion Premises Commencement Date, the Tenant, by written notice to the Landlord given within ten (10) days after the expiration of such ninety (90) day period, may terminate the Sixth Amendment to Office Building Lease without any liability to the Landlord. Separately, if the Fourth Expansion Premises Commencement Date-Suite 240 Premises has not occurred within ninety (90) days after the Fourth Expansion Premises Commencement Date-Suite 240 Premises, the Tenant, by written notice to the Landlord given within ten (10) days after the expiration of such ninety (90) day period, may terminate the terms of lease for the Suite 240 Premises in the Sixth Amendment to Office Building Lease for the Suite 240 Premises not delivered in said time frame without any liability to the Landlord. If Landlord’s failure to complete Tenant’s improvements within ninety (90) days after the Fourth Expansion Premises Commencement Date and/or Fourth Expansion Premises Commencement Date-Suite 240 Premises is result of Tenant Delay, Tenant shall not have the option to terminate the Sixth Amendment to Office Building Lease or the terms of lease for the Suite 240 Premises in the Sixth Amendment to Office Building Lease.

  • Condition of Premises Lessor makes no warranty or representation as to the Premises. Lessee acknowledges and agrees that it has occupied and familiarized itself with the Premises and has had adequate opportunity to investigate and inspect the condition of the Premises, and enters into this Lease upon the basis of its own review, and is leasing the Premises in their “AS IS, WHERE IS” CONDITION WITH ALL FAULTS, WHETHER PREVIOUSLY EXISTING OR ARISING FROM OR PERTAINING TO ANY CONSTRUCTION, RENOVATION, RELOCATION OR IMPROVEMENT OF ANY PORTION OF THE PREMISES PERFORMED BY LESSOR OR OTHERS, INCLUDING BUT NOT LIMITED TO BOTH LATENT AND PATENT DEFECTS. EXCEPT AS EXPRESSLY SET FORTH TO THE CONTRARY IN THIS LEASE, NO WARRANTIES, EXPRESS OR IMPLIED, ARE MADE BY LESSOR OR ANY OF ITS AFFILIATES CONCERNING SUCH ITEMS, INCLUDING BUT NOT LIMITED TO, WARRANTIES OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE. LESSEE HEREBY WAIVES AND DISCLAIMS ANY WARRANTIES THAT MAY ARISE BY OPERATION OF LAW. Lessee further acknowledges and agrees that it has had an opportunity to review and to discuss with various agents and/or representatives of Lessor the environmental condition of the Premises. Lessee has investigated and has knowledge of operative or proposed governmental laws and regulations including, without limitation, environmental laws and regulations to which the Premises are or may be subject and enters into this Lease upon the basis of its review and determination of the applicability and effect of such laws and regulations. Lessee acknowledges that Lessor expressly disclaims any representations or warranties of any kind or nature, express or implied, as to the condition (financial or otherwise), value or quality of the products, assets or properties of the Premises. Lessee hereby accepts the Premises in their condition existing as of the date hereof, subject to all applicable zoning, municipal, county and state laws, ordinances and regulations governing and regulating the use of the Premises, and accepts this Lease subject thereto and to all matters disclosed thereby and by any exhibits attached hereto. Lessee hereby agrees that all furniture, equipment, machinery and all other personal property, excepting any computers, that are located on or in the Premises as of the date hereof shall remain on the Premises as and when Lessee evacuates the Premises on the Termination Date or any extension thereof.

  • Inspection of Premises Landlord and Landlord's agents shall have the right at all reasonable times during the term of this Agreement and any renewal thereof to enter the Premises for the purpose of inspecting the Premises and all buildings and improvements thereon. And for the purposes of making any repairs, additions or alterations as may be deemed appropriate by Landlord for the preservation of the Premises or the building. Landlord and its agents shall further have the right to exhibit the Premises and to display the usual "for sale", "for rent" or "vacancy" signs on the Premises at any time within forty-five (45) days before the expiration of this Lease. The right of entry shall likewise exist for the purpose of removing placards, signs, fixtures, alterations or additions, that do not conform to this Agreement or to any restrictions, rules or regulations affecting the Premises.

  • Delivery of Possession Landlord shall be deemed to have delivered possession of the Premises to Tenant on the Commencement Date, as it may be adjusted pursuant to the Workletter. Landlord shall construct or install in the Premises the improvements to be constructed or installed by Landlord according to the Workletter. If no Workletter is attached to this Lease, it shall be deemed that Landlord delivered to Tenant possession of the Premises "as is" in its present condition on the Commencement Date. Tenant acknowledges that neither Landlord nor its agents or employees have made any representations or warranties as to the suitability or fitness of the Premises for the conduct of Tenant's business or for any other purpose, nor has Landlord or its agents or employees agreed to undertake any alterations or construct any Tenant improvements to the Premises except as expressly provided in this Lease and the Workletter. If for any reason Landlord cannot deliver possession of the Premises to Tenant on the Commencement Date, this Lease will not be void or voidable, Landlord will not be liable to Tenant for any resulting loss or damage and the Term of this Lease shall not be extended by a delayed delivery of possession. The preceding sentence notwithstanding, if Landlord fails to deliver possession to Tenant within sixty (60) days after the Commencement Date for any reason other than a Delay Caused by Tenant, as defined in the Workletter, Tenant, as its sole remedy, shall have the right to terminate this Lease and receive a refund of all prepaid Rent and Security Deposits provided Tenant gives written notice of termination to Landlord within three (3) days after that date. Tenant will execute the Commencement Date Certificate attached to this Lease as Exhibit E, appropriately completed, within fifteen (15) days of Landlord's request.

  • NON-DELIVERY OF POSSESSION In the event Landlord cannot deliver possession of the Premises to Tenant upon the commencement of the Lease term, through no fault of Landlord or its agents, then Landlord or its agents shall have no liability, but the rental herein provided shall xxxxx until possession is given. Landlord or its agents shall have thirty (30) days in which to give possession, and if possession is tendered within such time, Tenant agrees to accept the demised Premises and pay the rental herein provided from that date. In the event possession cannot be delivered within such time, through no fault of Landlord or its agents, then this Agreement and all rights hereunder shall terminate.

  • CONSTRUCTION OF PREMISES A. Lessor agrees that it will supply, at its own expense, its standard office space, as more particularly described and set forth on Exhibit “B” annexed hereto and made a part hereof (“Lessor’s Work”). /s/ Lessor /s/ Lessee B. Lessee agrees to perform, at its own cost and expense, all work other than Lessor’s Work, including without limitation that work, as particularly described in Exhibit “E” annexed hereto (“Lessee’s Work”), which is necessary to make the Premises conform with Lessee’s plans as approved by Lessor. Within thirty (30) days after the execution of this Lease, Lessee shall furnish to Lessor, for Lessor’s written approval, plans and specifications for the Lessee’s Work, showing a layout, lighting plan, fixturing plan, interior finish and material samples, and any work or equipment to be done or installed by Lessee affecting any structural, mechanical or electrical part of the Premises or the Building. Failure to provide same within said thirty (30) day period shall constitute a default by Lessee under this Lease. Lessor’s failure to disapprove of Lessee’s plans within fifteen (15) days of receipt shall constitute acceptance by Lessor of such plans. Design elements as aforesaid will be displayed in color renderings in such detail as may be sufficient for Lessor’s needs. It is the purpose of this requirement that Lessee’s Premises be fixtured, designed and laid out so as not to be a detriment to the other tenants in the Building and that Lessee’s Work shall not be detrimental to the Building or other tenants therein, and Lessor’s approval of the plans and specifications as aforesaid for Lessee’s Work shall be at the Lessor’s sole discretion. Lessee agrees and acknowledges that all Lessee’s Work, improvements, alterations or additions performed by Lessee (hereinafter collectively “Alterations”) whether pursuant to this Section or otherwise, shall be carried out in compliance with all Requirements and is performed and accomplished solely for the benefit and convenience of Lessee, and not for the benefit of Lessor, such Alterations being nevertheless subject to each and every of the provisions of this Lease,.

  • POSSESSION OF PREMISES Tenant shall not be entitled to possession of the premises designated for lease until the security deposit and first month’s rent (or prorated portion thereof), less any applicable promotional discount, is paid in full and the premises designated for lease is vacated by the prior tenant.

  • Expansion of Premises (a) Effective as of the Expansion Date the Premises (and the definition of the “Premises”) shall be modified to mean and include both the Initial Premises and the Expansion Premises. As a result of such expansion, effective upon the Expansion Date, the deemed square footage of the Premises shall be and become 31,684 square feet and Tenant’s Prorata Share and Tenant’s Share of Expenses and Real Estate Taxes shall be one hundred percent (100.00%). (b) If Landlord, for any reason whatsoever, cannot deliver possession of the Expansion Premises to Tenant on before August 1, 2012 for the purpose specified in Section 3(c), this Amendment shall not be void or voidable, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and Tenant shall have no obligation to pay monthly Base Rent or Additional Charges with respect to the Expansion Premises until the day following the date on which possession of the Expansion Premises is delivered to Tenant (such date thereupon becoming the “Expansion Date” for purposes of this Amendment). Notwithstanding the foregoing, if Landlord is unable to deliver the Expansion Premises by August 1, 2012 (as extended day-for-day for each day of Force Majeure Delay) (the “Expansion Premises Outside Delivery Date”), then Tenant shall have the right, as its sole remedy, to terminate this Amendment to Lease by providing written notice to Landlord within fifteen (15) business days following the Expansion Premises Outside Delivery Date, in which event the Lease shall continue in full force and effect as if the parties had not entered into this Amendment and Landlord shall promptly return to Tenant the August, 2012 Base Rent for the Expansion Premises paid by Tenant pursuant to the provisions of Section 6(d). For purposes hereof, the failure of the existing tenant of the Expansion Premises to vacate the Expansion Premises shall not be an event of Force Majeure Delay. (c) Notwithstanding the above, Tenant shall be entitled to early occupancy of the Expansion Premises at any time after the Expansion Premises Delivery Date for the sole purposes of (1) installing Tenant’s furniture and telephone and other communications cabling and (2) performing Tenant’s Expansion Work (defined below), provided that (i) Tenant covenants and agrees that Tenant and Tenant’s employees, agents or contractors will cooperate with Landlord to coordinate the performance and completion of the Landlord’s Expansion Work concurrently with Tenant’s Expansion Work, (ii) Landlord shall have no liability to Tenant for delays in completing the Landlord’s Expansion Work which result from, are caused by or arise out of the interference by Tenant or Tenant’s employees, agents or contractors in the performance of the Landlord’s Expansion Work, (iii) Tenant and Tenant’s employees, agents and contractors shall promptly comply with any and all requests made by Landlord or Landlord’s contractor(s) that Tenant remove its property from those areas in or around which Landlord is performing the Landlord’s Expansion Work, and (iv) Landlord shall not be liable for, Tenant hereby waives all claims which Tenant may have against the Landlord Parties, and Tenant shall indemnify and hold harmless Landlord from and defend Landlord against any and all claims or liability for any injury or damage to any person or property in or about the Expansion Premises resulting from or arising out of or in connection with the performance of Tenant’s Expansion Work (except to the extent arising from the negligence or willful misconduct of Landlord). Tenant’s early occupancy of the Expansion Premises for the sole purpose provided in this Section shall be subject to all of the terms and conditions of the Lease, provided that (x) the Premises shall not include the Expansion Premises until the Expansion Date, and (y) Tenant shall not be obligated to pay monthly Base Rent or Additional Charges with respect to the Expansion Premises for the period from the Expansion Premises Delivery Date until the Expansion Date. (d) Within five (5) business days after the Expansion Date, the parties shall execute a letter confirming the Expansion Date and certifying that Tenant has accepted delivery of the Premises, in form substantially similar to EXHIBIT “D” attached to the Lease (the “Expansion Date Memorandum”). Either party’s failure to request execution of, or to execute, the Expansion Date Memorandum shall not in any way alter the Expansion Date.

  • Acceptance of Premises Lessee hereby acknowledges: (a) that it has been advised by the Broker(s) to satisfy itself with respect to the condition of the Premises (including but not limited to the electrical and fire sprinkler systems, security, environmental aspects, seismic and earthquake requirements, and compliance with the Americans with Disabilities Act and applicable zoning, municipal, county, state and federal laws, ordinances and regulations and any covenants or restrictions of record (collectively, "Applicable Laws") and the present and future suitability of the Premises for Lessee's intended use; (b) that Lessee has made such investigation as it deems necessary with reference to such matters, is satisfied with reference thereto, and assumes all responsibility therefore as the same relate to Lessee's occupancy of the Premises and/or the terms of this Lease; and (c) that neither Lessor, nor any of Lessor's agents, has made any oral or written representations or warranties with respect to said matters other than as set forth in this Lease.

  • DESTRUCTION OF PREMISES (A) If, during the term of this Lease, the Leased Premises are totally or partially destroyed by fire or the elements, so as to render the premises wholly unfit for occupancy, or make it impossible in the opinion of a licensed third party arbitrator knowledgeable in the child care business reasonably acceptable to Lessee and Lessor, for Lessee to conduct its business therein, then either Lessor or Lessee shall have the right to terminate this Lease from the date of such damage or destruction by giving written notice. The parties agree to use reasonable promptness to obtain the opinion of such licensed third party arbitrator. Upon the giving of such notice, Lessee shall immediately surrender the Leased Premises and all interest therein to Lessor, and in case of any such termination, Lessor may re-enter and repossess the Leased Premises and may dispossess all parties then in possession thereof. If not otherwise terminated, in the event the Leased Premises shall be repaired, restored, and rebuilt by Lessee with the use of insurance proceeds (which Lessor shall cooperate to make available), but otherwise at its own sole cost and expense, within one hundred eighty (180) days from the date of destruction (subject to force majuere as set forth in paragraph C hereof, then all rents payable by Lessee shall be abated during the period of repair and restoration to the extent Lessor shall be compensated by the proceeds of rents loss insurance. In no event shall Lessor be required to provide its own money for the repair or restoration of the Leased Premises other than the net proceeds of moneys received by it from any insurance policy or policies covering such loss or damages. Lessee shall be liable for repair of the Leased Premises with all reasonable speed, and the rents shall recommence on the date that the repairs are completed. Lessee shall be under no obligation to so repair during the last five (5) years of the term of the Lease, or as extended, but if Lessee shall desire to rebuild during the last 12 months of the Lease term, Lessor will make insurance proceeds available to rebuild the Leased Premises conditioned upon Lessee then exercising its next renewal option under the Lease. Lessor will make insurance proceeds available to rebuild the Leased Premises in the event Lessee rebuilds, except as stated above. (B) If the damage does not, in the opinion of a licensed third party arbitrator reasonably acceptable to Lessee and Lessor, render the Leased Premises unfit for occupancy, then Lessor agrees that the damage shall be repaired as soon as practicable and in that case, Lessee shall pay full rent during the repair period. All repairs shall be paid for by Lessee out of any insurance proceeds received (which Lessor shall cooperate to make available), but if the insurance proceeds are insufficient to rebuild or repair the Leased Premises according to the original plans and specifications, whether repair or restoration is commenced pursuant to paragraph A or B hereof, then Lessee agrees to pay all additional amounts that are required to rebuild the building in accordance with the original plans and specifications. All improvements or betterments placed by Lessee on the demised premises shall, however, in any event, be repaired and replaced by Lessee at its own expense and not at the expense of Lessor. The purpose of this Article is to require Lessee to carry insurance coverage on the Leased Premises sufficient to rebuild the improvements in the event of damage or destruction. Lessee shall be under no obligation to so rebuild during the last five (5) years of the term, as extended, as the case may be, but if Lessee shall desire to rebuild during the last 12 months of the Lease term, Lessor will make insurance proceeds available to rebuild the Leased Premises conditioned upon Lessee then exercising its next renewal option under the Lease. Lessor will make insurance proceeds available to rebuild the Leased Premises in the event Lessee rebuilds, except as stated above. Risk that the insurance company shall be insolvent or shall refuse to make insurance proceeds available shall be with Lessee. The Leased Premises shall be so restored or rebuilt so as to be of at least equal value and substantially the same character as prior to such damage or destruction. If the insurance proceeds are less than $100,000 they shall be paid to Lessee for such repair and restoration. If the insurance proceeds are greater than or equal to $100,000 they shall be deposited by Lessee and Lessor into a customary construction escrow at a nationally recognized title insurance company, or at Lessee's option, with Lessor ("Escrowee") and shall be made available from time to time to Lessee for such repair and restoration. Such proceeds shall be disbursed in conformity with the terms and conditions of a commercially reasonable construction loan agreement. Lessee shall, in either instance, deliver to Lessor or Escrowee (as the case may be) satisfactory evidence of the estimated cost of completion together with such architect's certificates, waivers of lien, contractor's sworn statements and other evidence of cost and of payments as the Lessor or Escrowee may reasonably require and approve. If the estimated cost of the work exceeds One Hundred Thousand Dollars ($100,000), all plans and specifications for such rebuilding or restoration shall be subject to the reasonable approval of Lessor. (C) Lessee shall comply with the time period stated above for restoration of the Leased Premises as set forth in this Article; provided, however, that said period of time shall be extended for a period or periods of time equal to any period or periods of delay caused by strikes, lockouts, fire, or other casualty, the elements, acts of God, delay by or refusal or failure of governmental authorities to grant necessary permits and approvals for the reconstruction of the Leased Premises (Lessee agreeing to use reasonable diligence to procure the same), or other causes other than financial, beyond Lessee's reasonable control or the reasonable control of Lessee's contractor.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!