Services and Duties of the Distributor A. The Distributor agrees to sell Shares on a best efforts basis as agent for the Trust upon the terms and at the current offering price (plus sales charge, if any) described in the Prospectus. As used in this Agreement, the term “Prospectus” shall mean the current prospectus, including the statement of additional information, as both may be amended or supplemented, relating to the Fund and included in the currently effective registration statement (the “Registration Statement”) of the Trust filed under the Securities Act of 1933, as amended (the “1933 Act”) and the 1940 Act. The Trust shall in all cases receive the net asset value per Share on all sales. If a sales charge is in effect, the Distributor shall remit the sales charge (or portion thereof) to broker-dealers who have sold Shares, as described in Section 2(G), below. In no event shall the Distributor be entitled to all or any portion of such sales charge.
B. During the continuous public offering of Shares, the Distributor will hold itself available to receive orders, satisfactory to the Distributor, for the purchase of Shares and will accept such orders on behalf of the Trust. Such purchase orders shall be deemed effective at the time and in the manner set forth in the Prospectus.
C. The Distributor, with the operational assistance of the Trust’s transfer agent, shall make Shares available for sale and redemption through the National Securities Clearing Corporation’s Fund/SERV System.
D. The Distributor acknowledges and agrees that it is not authorized to provide any information or make any representations other than as contained in the Prospectus and any sales literature specifically approved by the Trust.
E. The Distributor agrees to cooperate with the Trust or its agent in the development of all proposed advertisements and sales literature relating to the Fund. The Distributor agrees to review all proposed advertisements and sales literature for compliance with applicable laws and regulations, and shall file with appropriate regulators those advertisements and sales literature it believes are in compliance with such laws and regulations. The Distributor agrees to furnish to the Trust any comments provided by regulators with respect to such materials and to use its best efforts to obtain the approval of the regulators to such materials.
F. The Distributor, at its sole discretion, may repurchase Shares offered for sale by shareholders of the Fund. Repurchase of Shares by the Distributor shall be at the price determined in accordance with, and in the manner set forth in, the Prospectus. At the end of each business day, the Distributor shall notify the Trust and its transfer agent, by any appropriate means, of the orders for repurchase of Shares received by the Distributor since the last report, the amount to be paid for such Shares and the identity of the shareholders offering Shares for repurchase. The Trust reserves the right to suspend such repurchase right upon written notice to the Distributor. The Distributor further agrees to act as agent for the Trust to receive and transmit promptly to the Trust’s transfer agent, shareholder requests for redemption of Shares.
G. The Distributor may, in its discretion, enter into agreements with such qualified broker-dealers as it may select, in order that such broker-dealers also may sell Shares of the Fund. The form of any dealer agreement shall be approved by the Trust. To the extent there is a sales charge in effect, the Distributor shall pay the applicable sales charge (or portion thereof), or allow a discount, to the selling broker-dealer, as described in the Prospectus.
H. The Distributor shall devote its best efforts to effect sales of Shares of the Fund but shall not be obligated to sell any certain number of Shares.
I. The Distributor shall prepare reports for the Board regarding its activities under this Agreement as from time to time shall be reasonably requested by the Board, including reports regarding the use of any 12b-1 payments received by the Distributor.
J. The Distributor agrees to advise the Trust promptly in writing of the initiation of any proceedings against it by the SEC or its staff, the NASD or any state regulatory authority.
K. The Distributor shall monitor amounts paid under Rule 12b-1 plans and pursuant to sales loads to ensure compliance with applicable NASD rules.
DUTIES OF GFS GFS’s duties with respect to Fund Accounting, Fund Administration and Transfer Agency services are detailed in Appendices I, II and III to this Agreement.
(a) In order for GFS to perform the Services, the Trust (i) shall cause all service providers to the Funds of the Trust to furnish any and all information to GFS, and assist GFS as may be required and (ii) shall ensure that GFS has access to all records and documents maintained by the Trust or any service provider to the Trust or a Fund of the Trust.
(b) GFS shall, for all purposes herein, be deemed to be an independent contractor and shall, unless otherwise expressly provided or authorized, have no authority to act for or represent the Trust in any way or otherwise be deemed an agent of the Trust.
(c) Whenever, in the course of performing its duties under this Agreement, GFS determines, on the basis of information supplied to GFS by the Trust, that a violation of applicable law has occurred, or that, to its knowledge, a possible violation of applicable law may have occurred, or with the passage of time could occur, GFS shall promptly notify the Trust and its legal counsel of such violation.
Duties of Contractor The Contractor shall provide the following services relative to this Contract:
Duties of the Distributor (a) The Distributor agrees to serve as the principal underwriter of the Funds in connection with the review and approval of all Purchase and Redemption Orders of Creation Units of each Fund by Authorized Participants that have executed an Authorized Participant Agreement with the Distributor and Transfer Agent/ Index Receipt Agent. Nothing herein shall affect or limit the right and ability of the Transfer Agent/ Index Receipt Agent to accept Fund Securities, Deposit Securities, and related Cash Components through or outside the Clearing Process, and as provided in and in accordance with the Registration Statement and Prospectus. The Trust acknowledges that the Distributor shall not be obligated to approve any certain number of orders for Creation Units.
(b) The Distributor agrees to use commercially reasonable efforts to provide the following services to the Trust with respect to the continuous distribution of Creation Units of each Fund: (i) at the request of the Trust, the Distributor shall enter into Authorized Participant Agreements between and among Authorized Participants, the Distributor and the Transfer Agent/Index Receipt Agent, for the purchase and redemption of Creation Units of the Funds, (ii) the Distributor shall approve and maintain copies of confirmations of Creation Unit purchase and redemption order acceptances; (iii) upon request, the Distributor will make available copies of the Prospectus to purchasers of such Creation Units and, upon request, the Statement of Additional Information; and (iv) the Distributor shall maintain telephonic, facsimile and/or access to direct computer communications links with the Transfer Agent.
(c) The Distributor shall ensure that all direct requests to Distributor for Prospectuses, Statements of Additional Information, product descriptions and periodic fund reports, as applicable, are fulfilled.
(d) The Distributor agrees to make available, at the Trust’s request, one or more members of its staff to attend, either via telephone or in person, Board meetings of the Trust in order to provide information with regard to the Distributor’s services hereunder and for such other purposes as may be requested by the Board of Trustees of the Trust.
(e) Distributor shall review and approve, prior to use, all Trust marketing materials (“Marketing Materials”) for compliance with SEC and FINRA advertising rules, and will file all Marketing Materials required to filed with FINRA. The Distributor agrees to furnish to the Trust’s investment adviser any comments provided by FINRA with respect to such materials.
(f) The Distributor shall not offer any Shares and shall not approve any creation or redemption order hereunder if and so long as the effectiveness of the Registration Statement then in effect or any necessary amendments thereto shall be suspended under any of the provisions of the 1933 Act or if and so long as a current prospectus as required by Section 10 of the 1933 Act is not on file with the SEC; provided, however, that nothing contained in this paragraph shall in any way restrict or have any application to or bearing upon the Trust’s obligation to redeem or repurchase any Shares from any shareholder in accordance with provisions of the Prospectus or Registration Statement.
(g) The Distributor shall work with the Index Receipt Agent to review and approve orders placed by Authorized Participants and transmitted to the Index Receipt Agent.
(h) The Distributor agrees to maintain, and preserve for the periods prescribed by Rule 31a-2 under the 1940 Act, such records as are required to be maintained by Rule 31a-1(d) under the 1940 Act. The Distributor agrees that all records which it maintains pursuant to the 1940 Act for the Trust shall at all times remain the property of the Trust, shall be readily accessible during normal business hours, and shall be promptly surrendered upon the termination of the Agreement or otherwise on written request; provided, however, that Distributor may retain all such records required to be maintained by Distributor pursuant to applicable FINRA or SEC rules and regulations.
(j) The Distributor agrees to maintain compliance policies and procedures (a “Compliance Program”) that are reasonably designed to prevent violations of the Federal Securities Laws (as defined in Rule 38a-1 of the 0000 Xxx) with respect to the Distributor’s services under this Agreement, and to provide any and all information with respect to the Compliance Program, including without limitation, information and certifications with respect to material violations of the Compliance Program and any material deficiencies or changes therein, as may be reasonably requested by the Trust’s Chief Compliance Officer or Board of Trustees.
Duties of the Parties JHU is not a commercial organization. It is an institute of research and education. Therefore, JHU has no ability to evaluate the commercial potential of any PATENT RIGHTS or LICENSED PRODUCT or other license or rights granted in this Agreement. It is therefore incumbent upon Company to evaluate the rights and products in question, to examine the materials and information provided by JHU, and to determine for itself the validity of any PATENT RIGHTS, its freedom to operate, and the value of any LICENSED PRODUCTS or SERVICES or other rights granted.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Services and Duties of USBFS USBFS shall provide the following transfer agent and dividend disbursing agent services to the Fund:
A. Receive and process all orders for the purchase, exchange, transfer, and/or redemption of Fund shares in accordance with Rule 22c-1 under the 1940 Act, other applicable regulations, and as specified in the Fund's prospectus (the "Prospectus”).
B. Process purchase and redemption orders with prompt delivery, where appropriate, of payment and supporting documentation to the shareholder based on the shareholder’s or the Trust’s custodian instructions, and record the appropriate number of shares being held in the appropriate shareholder account.
C. Process redemption requests received in good order and, where relevant, deliver appropriate documentation to the Trust's custodian.
D. Pay proceeds upon receipt from the Trust's custodian, where relevant, in accordance with the instructions of redeeming shareholders.
E. Process transfers of shares in accordance with the shareholder's instructions, after receipt of appropriate documentation from the shareholder as specified in the Prospectus.
F. Prepare and transmit payments, or apply reinvestments for income dividends and capital gains distributions declared by the Trust with respect to a Fund, after deducting any amount required to be withheld by any applicable laws, rules and regulations and in accordance with shareholder instructions.
G. Serve as the Fund’s agent in connection with systematic plans including, but not limited to, systematic investment plans, systematic withdrawal plans, and systematic exchange plans.
H. Make changes to shareholder records, including, but not limited to, address and plan changes (e.g., systematic investment and withdrawal, dividend reinvestment).
I. Handle load and multi-class processing, including rights of accumulation and purchases by letters of intent in accordance with the Prospectus.
J. Record the issuance of shares of each Fund and maintain, pursuant to Rule 17Ad-10(e) promulgated under the Securities Exchange Act of 1934, as amended (the "Exchange Act"), a record of the total number of shares of each Fund which are authorized, issued and outstanding.
K. Prepare ad-hoc reports as necessary at prevailing rates.
L. Mail shareholder reports and Prospectuses to current shareholders.
M. Prepare and file U.S. Treasury Department Forms 1099 and other appropriate information returns required with respect to dividends and distributions for all shareholders.
N. Provide shareholder account information upon shareholder or Trust requests and prepare and mail confirmations and statements of account to shareholders for all purchases, redemptions and other confirmable transactions as agreed upon with the Trust.
O. Mail and/or obtain shareholders’ certifications under penalties of perjury and pay on a timely basis to the appropriate federal or state authorities any taxes to be withheld on dividends and distributions paid by the Trust, all as required by applicable federal and state tax laws and regulations.
P. Answer correspondence from shareholders, securities brokers and others relating to USBFS’ duties hereunder within required time periods established by applicable regulation.
Q. Reimburse the Fund for all material losses resulting from “as of” processing errors for which USBFS is responsible in accordance with the “as of” processing guidelines set forth on Exhibit B hereto.
R. Calculate average assets held in shareholder accounts for purposes of paying Rule 12b-1 and/or shareholder servicing fees as directed by a Fund
S. Provide service and support to financial intermediaries including but not limited to trade placements, settlements, and corrections.
DUTIES AND REPRESENTATIONS OF THE TRUST (a) The Trust shall furnish to NLD copies of all financial statements and other documents to be delivered to shareholders or investors at least two (2) Fund Business Days prior to such delivery and shall furnish NLD copies of all other financial statements, documents and other papers or information which NLD may reasonably request for use in connection with the distribution of Shares. The Trust shall make available to NLD the number of copies of the Funds’ Prospectuses as NLD shall reasonably request.
(b) The Trust shall take, from time to time, subject to the approval of the Board and any required approval of the shareholders of the Funds, all actions necessary to fix the number of authorized Shares (if such number is not unlimited) and to register the Shares under the Securities Act, to the end that there will be available for sale the number of Shares as reasonably may be expected to be sold pursuant to this Agreement.
(c) The Trust will execute any and all documents, furnish any and all information and otherwise take all actions that may be reasonably necessary to register or qualify Shares for sale in such states as NLD may designate to the Funds and the Funds may approve, and the Funds shall pay all fees and other expenses incurred in connection with such registration or qualification; provided that NLD shall not be required to register as a broker-dealer or file a consent to service of process in any State and the Funds shall not be required to qualify as a foreign corporation, Fund or association in any State. Any registration or qualification may be withheld, terminated or withdrawn by the Funds at any time in its discretion. NLD shall furnish such information and other material relating to its affairs and activities as the Funds require in connection with such registration or qualification.
(d) The Trust represents and warrants to NLD that:
(i) It is a business trust duly organized and existing and in good standing under the laws of the state of Delaware;
(ii) It is empowered under applicable laws and by its Organizational Documents to enter into and perform this Agreement;
(iii) All proceedings required by the Organizational Documents have been taken to authorize it to enter into and perform its duties under this Agreement;
(iv) It is an open-end management investment company registered with the SEC under the 1940 Act;
(v) All Shares, when issued, shall be validly issued, fully paid and non-assessable;
(vi) This Agreement, when executed and delivered, will constitute a legal, valid and binding obligation of the Trust, enforceable against the Trust in accordance with its terms, subject to bankruptcy, insolvency, reorganization, moratorium and other laws of general application affecting the rights and remedies of creditors and secured parties;
(vii) The performance by the Trust of its obligations hereunder does not and will not contravene any provision of the Trust’s Agreement and Declaration of Trust.
(viii) The Registration Statement is currently effective and will remain effective with respect to all Shares of the Funds being offered for sale;
(ix) The Registration Statement and Prospectus have been or will be, as the case may be, carefully prepared in conformity with the requirements of the Securities Act and the rules and regulations thereunder;
(x) The Registration Statement and Prospectus contain or will contain all statements required to be stated therein in accordance with the Securities Act and the rules and regulations thereunder; all statements of fact contained or to be contained in the Registration Statement or Prospectus are or will be true and correct at the time indicated or on the effective date as the case may be; and neither the Registration Statement nor any Prospectus, when they shall become effective or be authorized for use, will include an untrue statement of a material fact or omit to state a material fact required to be stated therein or necessary to make the statements therein not misleading to a purchaser of Shares;
(xi) It will from time to time file such amendment or amendments to the Registration Statement and Prospectus as, in the light of then-current and then-prospective developments, shall, in the opinion of its counsel, be necessary in order to have the Registration Statement and Prospectus at all times contain all material facts required to be stated therein or necessary to make any statements therein not misleading to a purchaser of Shares ("Required Amendments");
(xii) It shall not file any amendment to the Registration Statement or Prospectus without giving NLD reasonable advance notice thereof; provided, however, that nothing contained in this Agreement shall in any way limit the Funds’ right to file at any time such amendments to the Registration Statement or Prospectus, of whatever character, as the Funds may deem advisable, such right being in all respects absolute and unconditional; and
(xiii) All Shares of the Fund are properly registered in the states as required by applicable state laws; and
(xiv) Any amendment to the Registration Statement or Prospectus hereafter filed will, when it becomes effective, contain all statements required to be stated therein in accordance with the 1940 Act and the rules and regulations thereunder; all statements of fact contained in the Registration Statement or Prospectus will, when it becomes effective, be true and correct at the time indicated or on the effective date as the case may be; and no such amendment, when it becomes effective, will include an untrue statement of a material fact or will omit to state a material fact required to be stated therein or necessary to make the statements therein not misleading to a purchaser of the Shares.
(xv) In connection with any registered representatives maintained under this Agreement, the Trust agrees to cooperate with NLD and provide reports as necessary to maintain appropriate licensing and qualifications and report to NLD any complaints, arbitrations, litigation or any other material matter that may affect a registered representative’s registration status.
(xvi) It has adopted necessary procedures to comply with the Bank Secrecy Act ("BSA"), as amended by The International Money Laundering Abatement and Financial Anti-Terrorism Act of 2002, Title III of the USA PATRIOT Act (the “PATRIOT Act"), its implementing regulations, and related SEC and SRO rules. Consistent with this requirement, the Trust shall ensure that the account opening forms utilized by the Funds contain the necessary customer information such as name, address, taxpayer identification and other information to verify the identity of such customers as well as provide proper notification to customers of such anti-money laundering program adopted by the Trust and/or its service providers.
(xvii) NLD may rely on and will be held harmless from relying on oral or written instructions it receives from an officer, agent, or legal counsel to the Trust.
NON-TEACHING DUTIES The Board and the Association acknowledge that a teacher's primary responsibility is to teach, and that his/her energies should be utilized to this end. It is agreed that teachers will be relieved of non-teaching duties to the extent possible and practical through the use of non-teaching personnel to perform clerical-type tasks and supervise playgrounds and lunchrooms.
Construction and Maintenance There are on-going maintenance, renovation and construction projects taking place in and around the residences. The work typically takes place during regular business hours, but may begin earlier or extend into evenings or weekends. On-going construction or renovation projects will continue through midterm and final exam periods. The University will take measures to ensure that prudent construction practices are followed, but there may be noise, dust and temporary interruption of some services. Residents may be required to temporarily or permanently relocate to facilitate construction or renovation to their residence area. There will be no compensation or reduction to your residence fees due to disruption and/or relocation.
