Contractor’s claim for Damages Sample Clauses

Open Split View

Download

Share

Cite

Contractor’s claim for Damages. Note: The Contractor shall submit its claims in a form acceptable to the Authority.

Sample 1

Save

Copy

Related to Contractor’s claim for Damages

• CLAIMS FOR DAMAGES 7.4.1 Should either party to the Contract suffer injury or damage to person or property because of any act or omission of the other party or of any of his / her employees, agents or others for whose acts he / she is legally liable, claim shall be made in writing to such other party within a reasonable time after the first observance of such injury or damage.

• Third Party Claims The obligation of an indemnifying party to ------------------ indemnify another party to this Agreement under the provisions of this Article with respect to claims resulting from the assertion of liability by Persons not parties to this Agreement (including governmental claims for penalties, fines and assessments) shall be subject to the following terms and conditions: (a) The indemnified party shall give prompt written notice to the indemnifying party of any assertion of liability by a third party which might give rise to a claim for indemnification, which notice shall state the nature and basis of the assertion and the amount thereof, to the extent known, provided, however, that no delay on the part of the indemnified party in giving notice shall relieve the indemnifying party of any obligation to indemnify unless (and then solely to the extent that) the indemnifying party is prejudiced by such delay. (b) If any action, suit or proceeding (a "Legal Action") is brought against an indemnified party with respect to which the indemnifying party may have an obligation to indemnify, the Legal Action shall be defended by the indemnifying party and such defense shall include all proceedings and appeals which counsel for the indemnified party shall reasonably deem appropriate. (c) Notwithstanding the provisions of the previous subsection of this Article, until the indemnifying party shall have assumed the defense of any such Legal Action, the defense shall be handled by the indemnified party. Furthermore, (i) if the indemnified party shall have reasonably concluded that there are likely to be defenses available to the indemnified party that are different from or in addition to those available to the indemnifying party; (ii) if the indemnifying party fails to provide the indemnified party with evidence reasonably acceptable to the indemnified party that the indemnifying party has sufficient financial resources to defend and fulfill its indemnification obligation with respect to the Legal Action; (iii if the Legal Action involves other than money damages and seeks injunctive or other equitable relief; or (iv) if a judgment against the indemnified party will, in the good faith opinion of the indemnified party, establish a custom or precedent which will be materially adverse to the best interests of its continuing business, the indemnifying party shall not be entitled to assume the defense of the Legal Action and the defense shall be handled by the indemnified party. If the defense of the Legal Action is handled by the indemnified party under the provisions of this subsection, the indemnifying party shall pay all legal and other expenses reasonably incurred by the indemnified party in conducting such defense. (d) In any Legal Action initiated by a third party and defended by the indemnifying party (i) the indemnified party shall have the right to be represented by advisory counsel and accountants, at its own expense, (ii) the indemnifying party shall keep the indemnified party fully informed as to the status of such Legal Action at all stages thereof, whether or not the indemnified party is represented by its own counsel, (iii) the indemnifying party shall make available to the indemnified party, and its attorneys, accountants and other representatives, all books and records of the indemnifying party relating to such Legal Action and (iv) the parties shall render to each other such assistance as may be reasonably required in order to ensure the proper and adequate defense of the Legal Action. (e) In any Legal Action initiated by a third party and defended by the indemnifying party, the indemnifying party shall not make any settlement of any claim without the written consent of the indemnified party, which consent shall not be unreasonably withheld. Without limiting the generality of the foregoing, it shall not be deemed unreasonable to withhold consent to a settlement involving injunctive or other equitable relief against the indemnified party or its assets, employees or business, or relief which the indemnified party reasonably believes could establish a custom or precedent which will be adverse to the best interests of its continuing business.

• Indemnification; Third Party Claims The Master Servicer agrees to indemnify the Depositor, the Sponsor and the Trustee, and their respective officers, directors, agents and affiliates, and hold each of them harmless against any and all claims, losses, penalties, fines, forfeitures, reasonable legal fees and related costs, judgments, and any other costs, liability, fees and expenses that the Depositor, the Sponsor or the Trustee may sustain as a result of (a) any material breach by the Master Servicer of any if its obligations hereunder, including particularly its obligations to provide any reports under Section 9.25(a), Section 9.25(b), Section 9.26 or any information, data or materials required to be included in any Exchange Act report, (b) any material misstatement or omission in any information, data or materials provided by the Master Servicer, or (c) the negligence, bad faith or willful misconduct of the Master Servicer in connection with its performance hereunder, provided, however, that in no event shall the Master Servicer be liable for any special, consequential, indirect or punitive damages pursuant to this Section 9.31, even if advised of the possibility of such damages. The Depositor, the Sponsor and the Trustee shall immediately notify the Master Servicer if a claim is made by a third party with respect to this Agreement or the Mortgage Loans entitling the Depositor, the Sponsor or the Trustee to indemnification hereunder, whereupon the Master Servicer shall assume the defense of any such claim and pay all expenses in connection therewith, including counsel fees, and promptly pay, discharge and satisfy any judgment or decree which may be entered against it or them in respect of such claim. Notwithstanding anything to the contrary contained herein, the Master Servicer shall not settle any claim involving any of the other parties hereto without such party’s prior written consent unless such settlement involves a complete and absolute release of such party from any and all liability in connection with such claim. This indemnification shall survive the termination of this Agreement or the termination of the Master Servicer as a party to this Agreement.

• Defense of Infringement Claims In the event Licensee or Licensor becomes aware that Licensee’s or any of its Affiliates’ or any Sublicensees’ practice of the Licensed Patents is the subject of a claim for patent infringement by a Third Party, that Party shall promptly notify the other, and the Parties shall consider the claim and the most appropriate action to take. Licensee shall cause each of its Affiliates and each Sublicensee to notify Licensee promptly in the event such entity becomes aware that its practice of the Licensed Patents is the subject of a claim of patent infringement by another. To the extent Licensor takes any action, Licensor (or the ReGenX Licensors) shall have the right to require Licensee’s reasonable cooperation in any such suit, upon written notice to Licensee; and Licensee shall have the obligation to participate upon Licensor’s request, in which event, Licensor shall bear the cost of Licensee’s participation. Without Licensor’s prior written permission, Licensee must not settle or compromise any such suit in a manner that imposes any material obligations or restrictions on Licensor or the ReGenX Licensors or grants any rights to the Licensed Patents other than rights that Licensee has the right to grant under this Agreement.

• Claims for Consequential Damages The Owner retains its right to claim for consequential damages in the event the Design Professional fails to perform under this Contract.

• Indemnification Claims An Indemnified Party shall give written notification to the Indemnifying Party of the commencement of any Third Party Action. Such notification shall be given within 20 days after receipt by the Indemnified Party of notice of such Third Party Action, and shall describe in reasonable detail (to the extent known by the Indemnified Party) the facts constituting the basis for such Third Party Action and the amount of the claimed damages; provided, however, that no delay or failure on the part of the Indemnified Party in so notifying the Indemnifying Party shall relieve the Indemnifying Party of any liability or obligation hereunder except to the extent of any damage or liability caused by or arising out of such failure. Within 20 days after delivery of such notification, the Indemnifying Party may, upon written notice thereof to the Indemnified Party, assume control of the defense of such Third Party Action with counsel reasonably satisfactory to the Indemnified Party; provided that the Indemnifying Party may not assume control of the defense of Third Party Action involving criminal liability or in which equitable relief is sought against the Indemnified Party. If the Indemnifying Party does not, or is not permitted under the terms hereof to, so assume control of the defense of a Third Party Action, the Indemnified Party shall control such defense. The Non-controlling Party may participate in such defense at its own expense. The Controlling Party shall keep the Non-controlling Party advised of the status of such Third Party Action and the defense thereof and shall consider in good faith recommendations made by the Non-controlling Party with respect thereto. The Non-controlling Party shall promptly furnish the Controlling Party with such information as it may have or receive with respect to such Third Party Action (including copies of any summons, complaint or other pleading which may have been served on such party and any written claim, demand, invoice, billing or other document evidencing or asserting the same) and shall otherwise cooperate with and assist the Controlling Party in the defense of such Third Party Action. The fees and expenses of counsel to the Indemnified Party with respect to a Third Party Action shall be considered Damages for purposes of this Agreement if (x) the Indemnified Party controls the defense of such Third Party Action pursuant to the terms of this Section 5.3 or (y) the Indemnifying Party assumes control of such defense and the Indemnified Party reasonably concludes that the Indemnifying Party and the Indemnified Party have conflicting interests with respect to such Third Party Action. The Indemnifying Party shall not agree to any settlement of, or the entry of any judgment arising from, any Third Party Action without the prior written consent of the Indemnified Party, which shall not be unreasonably withheld, conditioned or delayed. The Indemnified Party shall not agree to any settlement of, or the entry of any judgment arising from, any such Third Party Action without the prior written consent of the Indemnifying Party, which shall not be unreasonably withheld, conditioned or delayed.

• Indemnification of Third Party Claims The obligations and liabilities of any party to indemnify any other under this Article 6 with respect to Claims relating to third parties shall be subject to the following terms and conditions:

• Non-Third Party Claims Upon discovery of any claim for which Buyer has an indemnification obligation under the terms of Section 12.1 which does not involve a claim by a third party against the Indemnitee, the Indemnitee shall give prompt notice to Buyer of such claim and, in any case, shall give Buyer such notice within 30 days of such discovery. A failure by Indemnitee to timely give the foregoing notice to Buyer shall not excuse Buyer from any indemnification liability except to the extent that Buyer is materially and adversely prejudiced by such failure.

• Defense of Third Party Claims An Indemnified Party shall give prompt written notice to VTDC or the Partnership, as applicable (the “Indemnifying Party”), of the commencement or assertion of any Claim by a third party (collectively, a “third-party action”) in respect of which such Indemnified Party seeks indemnification hereunder. Any failure so to notify the Indemnifying Party shall not relieve the Indemnifying Party from any liability that it, he, or she may have to such Indemnified Party under this Article VII unless the failure to give such notice materially and adversely prejudices the Indemnifying Party. The Indemnifying Party shall have the right to assume control of the defense of, settle, or otherwise dispose of such third-party action on such terms as it deems appropriate; provided, however, that: (a) The Indemnified Party shall be entitled, at its own expense, to participate in the defense of such third-party action (provided, however, that the Indemnifying Party shall pay the attorneys’ fees of the Indemnified Party if (i) the employment of separate counsel shall have been authorized in writing by the Indemnifying Party in connection with the defense of such third-party action; (ii) the Indemnifying Party shall not have employed counsel reasonably satisfactory to the Indemnified Party to have charge of such third-party action; (iii) the Indemnified Party shall have reasonably concluded that there may be defenses available to such Indemnified Party that are different from or additional to those available to the Indemnifying Party; or (iv) the Indemnified Party’s counsel shall have advised the Indemnified Party in writing, with a copy delivered to the Indemnifying Party, that there is a material conflict of interest that could violate applicable standards of professional conduct to have common counsel); (b) The Indemnifying Party shall obtain the prior written approval of the Indemnified Party before entering into or making any settlement, compromise, admission, or acknowledgment of the validity of such third-party action or any liability in respect thereof if, pursuant to or as a result of such settlement, compromise, admission, or acknowledgment, injunctive or other equitable relief would be imposed against the Indemnified Party or if, in the opinion of the Indemnified Party, such settlement, compromise, admission, or acknowledgment could have a Material Adverse Effect with respect to the Indemnified Party; (c) The Indemnifying Party shall not consent to the entry of any judgment or enter into any settlement without the consent of the Indemnified Party that does not include as an unconditional term thereof the giving by each claimant or plaintiff to the Indemnified Party of a release from all liability in respect of such third-party action; and (d) The Indemnifying Party shall not be entitled to control (but shall be entitled to participate at its own expense in the defense of), and the Indemnified Party shall be entitled to have sole control over, the defense or settlement, compromise, admission, or acknowledgment of any third-party action (i) as to which the Indemnifying Party fails to assume the defense within a reasonable length of time or (ii) to the extent the third-party action seeks an order, injunction, or other equitable relief against the Indemnified Party which, if successful, would materially adversely affect the business, operations, assets, or financial condition of the Indemnified Party; provided, however, that the Indemnified Party shall make no settlement, compromise, admission, or acknowledgment that would give rise to liability on the part of any Indemnifying Party without the prior written consent of such Indemnifying Party. The Parties shall extend reasonable cooperation in connection with the defense of any third-party action pursuant to this Article VII and, in connection therewith, shall furnish such records, information, and testimony and attend such conferences, discovery proceedings, hearings, trials, and appeals as may be reasonably requested.

• Third Party Infringement Claims In the event any claim or action for infringement of any patent, trademark, or other intellectual property right shall be made or brought by a third party against Seller, Purchaser or any of their respective Affiliates because of, or in anticipation of, the manufacture and supply of Product by Seller to Purchaser hereunder, or the marketing, sale or distribution of such Product to Purchaser Customers in the Territory by Purchaser hereunder (a “Third Party Infringement Claim”), the party first receiving such notice of the Third Party Infringement Claim shall promptly notify the other party. With respect to the Third Party Infringement Claim, Seller and Purchaser each hereby agrees that all Damages arising from or related to the Third Party Infringement Claim (including any legal fees and associated costs incurred in defending the Third Party Infringement Claim and any fees, royalties or other amounts paid in settlement or upon judgment) shall be shared as follows: (a) Except as provided in clause (b) below, Seller shall be 100% responsible for all Damages arising from any Third Party Infringement Claim, including any fees, royalties or other amounts agreed to be paid in settlement or upon judgment of the Lawsuit or otherwise; and (b) Purchaser shall be 100% responsible for all Damages arising from any Third Party Infringement Claim with respect to the use of Purchaser Trademarks. Each party agrees to indemnify the other party to ensure that Damages arising from any Third Party Infringement Claim are allocated in accordance with clauses (a) and (b) above. Unless otherwise agreed to by the parties, Seller shall control the defense any Third Party Infringement Claim described in clause (a) above and Purchaser shall control the defense of any Third Party Infringement Claim described in clause (b) above. The party controlling the defense of any Third Party Infringement Claim shall have the sole right to defend or settle any such Third Party Infringement Claim; provided, however, that such settlement does not impose any obligation or burden on the other party without the prior written consent of the other party (which consent shall not be unreasonably withheld). The party controlling the defense of any Third Party Infringement Claim shall keep the other party, at its request, materially informed of the status and progress of the defense of the Third Party Infringement Claim. No Third Party Infringement Claim shall be settled by the party who is not controlling the defense of such Third Party Infringement Claim without the prior written consent of the party controlling such defense. The non-controlling party, its employees, agents and Affiliates shall reasonably cooperate with the party (and its legal representatives) controlling the defense of any Third Party Infringement Claim in the investigation and defense of such Third Party Infringement Claim. Notwithstanding the above, and by way of clarification, neither party shall be obligated to indemnify the other party hereunder for modification or misuse of the Product by the other party or by wholesalers or the customers of either party. The provisions of this Section 17.4 shall be notwithstanding any conflicting provisions set forth in this Agreement, including Sections 17.1, 17.2 and 17.3.