Contractor’s Schedules Sample Clauses

Contractor’s Schedules. CM shall review the Contractor’s Construction Schedules and updates thereof for: (i) verification of conformity to the requirements established in the Construction Contract for the Assigned Project; (ii) verification that all necessary activities to complete construction of the Assigned Project in accordance with the DSA reviewed Design Documents and the Construction Contract for the Assigned Project are reflected in the Contractor’s Schedules; (iii) verification that the duration for construction activities are reasonable; and (iv) if required by the terms of the Construction Contract for an Assigned Project, verification that the Contractor’s Schedules incorporate requirements for manpower and other resources necessary for the Contractor’s construction of the Assigned Project. If the CM, upon review of the Contractor’s Schedules is unable to verify any of the matters set forth above, the CM shall notify the District Representative in writing of such inability, along with recommendations for actions of the Contractor or modifications to the Contractor’s Schedules so that the CM can verify such matters. The CM shall implement such measures as directed or authorized by the District.
Sample 1Sample 2Sample 3See All (5)
AutoNDA by SimpleDocs
Contractor’s Schedules. 3.1.12.1 The Contractor, promptly after execution of the Contract, shall prepare and submit for the Owner’s information a schedule for the Work. The schedule, including the time required for design and construction, shall not exceed time limits current under the Contract Documents, shall utilize the critical path method, shall be revised at appropriate intervals as required by the conditions of the Work and Project which shall be no less often than monthly, shall be related to the entire Project to the extent required by the Contract Documents, shall provide for expeditious and practicable execution of the Work, and shall include allowances for periods of time required for the Owner’s review and for approval of submissions by authorities having jurisdiction over the Project. 3.1.12.2 The Contractor shall perform the Work in general accordance with the most recent schedules submitted to the Owner. 3.1.12.3 For purposes of whether any Change Orders or Construction Change Directives extend the contractual dates of Substantial Completion and Final Completion, any “float” or “slack” time for the whole or any part of the Work shall not be for the exclusive use or benefit of either the Owner or the Contractor but shall be reserved and apportioned by the Owner and Contractor in accordance with the needs of the Project. The Contractor shall not be entitled to make and waives any claim based upon an alleged inability to complete the Project early. 3.1.12.4 In the event the Owner determines that the performance of the Work has not progressed or reached the level of completion required by the current, approved Contractor’s schedule, the Owner shall have the right to order the Contractor to take corrective measures as necessary to restore the progress of the Work to the requirements of such schedule, including but not limited to (1) working additional shifts or overtime, (2) furnishing additional labor, services, materials, equipment and facilities and (3) other similar acceleration measures. The costs incurred by the Contractor pursuant to this Section shall be paid by the Contractor.
Sample 1Sample 2
Contractor’s Schedules. §3.10.1 The Performance Schedule (as defined in the Agreement), shall not be revised without the Owner’s written approval and shall provide for expeditious and practicable execution of the Work. §3.10.2 The Contractor’s Performance Schedule shall include (1) “milestone” dates for starting and completion of the various phases of the Work, within the Contract Time, including dates for fabrication, transportation and installation; (2) completion of shop drawings and submittals; (3) the dates proposed for any utility outages and tie-ins, parking lot and road obstructions, and other interferences to the normal operation and uses of the Campus; (4) estimated equipment delivery dates; and
Sample 1
Contractor’s Schedules. § 9.8.1 The Contractor, promptly after being awarded the Contract, shall submit for the Owner’s information a Contractor’s Schedule for the Work which shall become Exhibit B to this Contract. The schedule shall not exceed time limits current under the Contract Documents, shall be revised at appropriate intervals as required by the conditions of the Work and Project, shall be related to the entire Project to the extent required by the Contract Documents, and shall provide for expeditious and practicable execution of the Work. § 9.8.2 The Contractor shall perform the Work in general accordance with the most recent schedule submitted to the Owner. Contractor shall not be obligated to meet interim or milestone dates set forth in Contractor’s schedules other than those specifically required by Section 2.3.2 of this Contract, if any ("Mandatory Milestones") and may be liable only for Contractor’s failure, as a result of Contractor-caused delays, to meet the agreed date of Substantial Completion and Mandatory Milestones, if any, each as modified pursuant to the Contract Documents.
Sample 1

Related to Contractor’s Schedules

  • Wage Schedules The Parties shall, upon completing a wage adjustment calculation, forthwith prepare, publish, post and distribute a wage schedule resulting therefrom. The final determination of the wage schedules shall be issued no later than the 7th day of March or September, for the May and November adjustments, respectively.

  • Work Schedules Workweeks and work shifts of different numbers of hours may be established by the Employer in order to meet business and customer service needs, as long as the work schedules meet federal and state laws.

  • Shift Schedules 1501 Shift schedules for a minimum of a four (4) week period shall be posted at least two (2) weeks in advance of the beginning of the scheduled period. Shifts within the minimum four (4) week period shall not be altered after posting except by mutual agreement between the nurse(s) concerned and the Employer. Requests for specific days off duty shall be submitted in writing at least two (2) weeks prior to posting and granted, if possible in the judgment of the Employer. 1502 Requests for interchanges in posted shifts or a portion thereof shall also be submitted in writing, co-signed by the nurse willing to exchange shifts with the applicant. Where reasonably possible, interchanges in posted shifts are to be completed within the posted shift schedule. It is understood that any change in shifts or days off initiated by the nurses and approved by the Employer shall not result in overtime costs to the Employer. 1503 Night shift shall be considered as the first shift of each calendar day. 1504 Master rotations for each nursing unit shall be planned by the Employer in meaningful consultation with the nurse(s) concerned. The process for meaningful consultation shall include:  Employer proposes a master rotation including the Employer established criteria and provides to Nurses concerned  Nurses are provided reasonable time to submit feedback and/or an alternate master rotation for consideration.  The amended or new master rotation is provided to Nurses for review. Nurses are provided with a reasonable time to submit feedback.  At each step of the consultation process the Union will be provided with the new or revised master rotation to ensure contract compliance.  Employer has the sole discretion to select the new master rotation and provides rationale for the selection. Master Rotations shall, unless otherwise mutually agreed between the nurse(s) concerned and the Employer, observe the conditions listed hereinafter: (a) a minimum of fifteen hours (15) off between assigned shifts. (b) (i) a minimum of forty-seven (47) hours off at one time, or

  • Outage Schedules The Connecting Transmission Owner shall post scheduled outages of its transmission facilities on the NYISO OASIS. Developer shall submit its planned maintenance schedules for the Large Generating Facility to Connecting Transmission Owner and NYISO for a minimum of a rolling thirty-six month period. Developer shall update its planned maintenance schedules as necessary. NYISO may direct, or the Connecting Transmission Owner may request, Developer to reschedule its maintenance as necessary to maintain the reliability of the New York State Transmission System. Compensation to Developer for any additional direct costs that the Developer incurs as a result of rescheduling maintenance, including any additional overtime, breaking of maintenance contracts or other costs above and beyond the cost the Developer would have incurred absent the request to reschedule maintenance, shall be in accordance with the ISO OATT. Developer will not be eligible to receive compensation, if during the twelve (12) months prior to the date of the scheduled maintenance, the Developer had modified its schedule of maintenance activities other than at the direction of the NYISO or request of the Connecting Transmission Owner.

  • Vendor’s Subcontractors TIPS recognizes that many vendors operate in the open market through the use of subcontractors. For that reason, TIPS permits Vendor to utilize subcontractors as authorized and permitted by the TIPS Member Customer. However, all purchase documents must include: (1) Vendor’s Name, as known to TIPS, and; (2) Vendor’s TIPS Contract Name and Number under which it is making the TIPS Sale. Vendor must report the sale pursuant to the terms herein and Vendor agrees that it is legally responsible for all reporting and fee payment as described herein for TIPS Sales even when subcontractors are utilized. The TIPS Administration Fee is assessed on the amount paid by the TIPS Member to Vendor. The Parties intend that Vendor shall be responsible and for actions of subcontractors during a TIPS Sale. Vendor agrees that it is voluntarily authorizing subcontractors and in doing so, Xxxxxx agrees that it is doing so at its own risk and agrees to protect, indemnify, and hold TIPS harmless in accordance with Sections 14-17 above related to subcontractor TIPS Sales made pursuant to this Agreement or purporting to be made pursuant to this Agreement that may be asserted against Vendor whether rightfully brought or otherwise. The Parties further agree that it is no defense to Vendor’s breach of this Agreement that a subcontractor caused Vendor of breach this Agreement.

  • Contract Schedule The information set forth in the Contract Schedule is true and correct.

  • Exhibits/Schedules The Exhibits and Schedules to this Agreement are hereby incorporated and made a part hereof and are an integral part of this Agreement. All Exhibits and Schedules annexed hereto or referred to herein are hereby incorporated in and made a part of this Agreement as if set forth in full herein. Any capitalized terms used in any Schedule or Exhibit but not otherwise defined therein shall be defined as set forth in this Agreement.

  • PROGRESS SCHEDULE The Contractor, within ten (10) working days of receiving notice of the award of the contract, shall prepare and submit for the State's and Architect's information an estimated progress schedule for the Work. The progress schedule shall be related to the entire Project to the extent required by the Contract Documents, and shall provide for expeditious and practicable execution of the Work.

  • Wages Schedules Payable from the first pay period on or after the date specified.

  • Contracts with Subcontractors a. Grantee may enter into contracts with subcontractors unless restricted or otherwise prohibited in the Contract. b. Grantees are prohibited from subcontracting with for-profit organizations under this Contract. c. Prior to entering into a subcontract agreement equaling or exceeding $100,000, Grantee will obtain written approval from the System Agency. d. Grantee will obtain written approval from System Agency before modifying any subcontract agreement to cause the agreement to exceed $100,000. e. Grantee will establish written policies and procedures for competitive procurement and monitoring of subcontracts and will develop a subcontracting monitoring plan. f. monitor subcontractors for both financial and programmatic performance and will maintain pertinent records. g. submit quarterly monitoring reports to the System Agency in a format determined by the System Agency. h. ensure that subcontracts are fully aware of the requirements placed upon them by state/federal statutes, rules, and regulations and by the provisions of this Contract. i. ensure all subcontracts, must be in writing and include the following: 1. Name and address of all parties and the subcontractor’s Vendor Identification Number (VIN) or Employee Identification Number (EIN); 2. Detailed description of the services to be provided; 3. Measurable method and rate of payment and total not-to-exceed amount of the contract; 4. Clearly defined and executable termination clause; and 5. Beginning and ending dates that coincide with the dates of the Contract. j. ensure and be responsible for the performance of the subcontractor(s). k. not contract with a subcontractor, at any tier, that is debarred, suspended, or excluded from or ineligible for participation in federal assistance programs or if the subcontractor would be otherwise ineligible to abide by the terms of this Contract.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!