Control of Construction Disbursement Account, Dugan Property Sample Clauses

Control of Construction Disbursement Account, Dugan Property. Improvements Account and Construction Escrow Account. Xxx XSB Disbursement Agent hereby agrees and confirms that it has established the Construction Disbursement Account, the Dugan Property Improvements Account and the Construction Escrow Accouxx (xollectively, the "Construction Accounts") as set forth and defined in this Agreement. For so long as this Agreement remains in effect, the USB Disbursement Agent waives its rights of chargeback, setoff (including such right of setoff as set forth in Section 9-340 of the UCC) and/or banker's lien against the Construction Accounts. Until this Agreement terminates in accordance with the terms hereof, the Trustee shall have "control" (within the meaning of Section 9-104 of the UCC) of the Construction Accounts. If at any time the USB Disbursement Agent shall receive from the Trustee any instruction directing disposition of any funds in the Construction Accounts (a "Construction Account Order"), the USB Disbursement Agent shall comply with such Construction Account Order without further consent by the Authority or any other Person. In the event that the USB Disbursement Agent receives conflicting Construction Account Orders relating to the Construction Accounts, the USB Disbursement Agent shall comply with the Construction Account Orders originated by the Trustee. Each of the Authority and the USB Disbursement Agent agrees that it has not and will not execute and deliver, or otherwise become bound by, any agreement under which it agrees with any Person other than the Trustee to comply with Construction Account Orders originated by such Person relating to the Construction Accounts.
Sample 1
AutoNDA by SimpleDocs

Related to Control of Construction Disbursement Account, Dugan Property

  • Audit Rights Period for Construction-Related Accounts and Records Accounts and records related to the design, engineering, procurement, and construction of Connecting Transmission Owner’s Attachment Facilities and System Upgrade Facilities and System Deliverability Upgrades shall be subject to audit for a period of twenty-four months following Connecting Transmission Owner’s issuance of a final invoice in accordance with Article 12.2 of this Agreement.

  • Collateral Protection Expenses Preservation of Collateral (a) If an Event of Default shall have occurred and be continuing, the Agent may discharge taxes and other encumbrances at any time levied or placed on any of the Collateral, make repairs thereto and pay any necessary filing fees. Each Grantor agrees to reimburse the Agent on demand for any and all expenditures so made. The Agent shall have no obligation to any Grantor to make any such expenditures, nor shall the making thereof relieve any Grantor of any default. (b) Anything herein to the contrary notwithstanding, each Grantor shall remain liable under each contract or agreement comprised in the Collateral to be observed or performed by such Grantor thereunder. The Agent shall not have any obligation or liability under any such contract or agreement by reason of or arising out of this Agreement or the receipt by the Agent of any payment relating to any of the Collateral, nor shall the Agent be obligated in any manner to perform any of the obligations of any Grantor under or pursuant to any such contract or agreement, to make inquiry as to the nature or sufficiency of any payment received by the Agent in respect of the Collateral or as to the sufficiency of any performance by any party under any such contract or agreement, to present or file any claim, to take any action to enforce any performance or to collect the payment of any amounts which may have been assigned to the Agent or to which the Agent may be entitled at any time or times. The Agent’s sole duty with respect to the custody, safe keeping and physical preservation of the Collateral in its possession, under Sections 9-207 and 9-208 of the UCC or otherwise, shall be to deal with such Collateral in the same manner as the Agent deals with similar property for its own account. (c) Each Grantor shall, to the extent reasonably necessary to preserve and maintain the Intellectual Property Collateral and the interest of the Agent therein, diligently pursue legal or other action to enforce the Intellectual Property Collateral and any licenses thereof.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Application of Collateral Proceeds The proceeds and/or avails of the Collateral, or any part thereof, and the proceeds and the avails of any remedy hereunder (as well as any other amounts of any kind held by Lender, at the time of or received by Lender after the occurrence of an Event of Default hereunder) shall be paid to and applied as follows: (a) First, to the payment of out-of-pocket costs and expenses, including all amounts expended to preserve the value of the Collateral, of foreclosure or suit, if any, and of such sale and the exercise of any other rights or remedies, and of all proper fees, expenses, liability and advances, including reasonable legal expenses and attorneys’ fees, incurred or made hereunder by Lender, including, without limitation, Lender’s Expenses; (b) Second, to the payment to Lender of the amount then owing or unpaid on the Loans for any accrued and unpaid interest, the amounts which would have otherwise come due under Section 2.3(b)(ii), if the Loans had been voluntarily prepaid, the principal balance of the Loans, and all other Obligations with respect to the Loans (provided, however, if such proceeds shall be insufficient to pay in full the whole amount so due, owing or unpaid upon the Loans, then to the unpaid interest thereon, then to the amounts which would have otherwise come due under Section 2.3(b)(ii), if the Loans had been voluntarily prepaid, then to the principal balance of the Loans, and then to the payment of other amounts then payable to Lender under any of the Loan Documents); and (c) Third, to the payment of the surplus, if any, to Borrower, its successors and assigns, or to the Person lawfully entitled to receive the same.

  • Maintenance of Collateral Accounts Maintain any Collateral Account except pursuant to the terms of Section 6.6(b) hereof.

  • Early Construction of Base Case Facilities Developer may request Connecting Transmission Owner to construct, and Connecting Transmission Owner shall construct, subject to a binding cost allocation agreement reached in accordance with Attachment S to the ISO OATT, including Section 25.8.7 thereof, using Reasonable Efforts to accommodate Developer’s In-Service Date, all or any portion of any System Upgrade Facilities or System Deliverability Upgrades required for Developer to be interconnected to the New York State Transmission System which are included in the Base Case of the Class Year Study for the Developer, and which also are required to be constructed for another Developer, but where such construction is not scheduled to be completed in time to achieve Developer’s In-Service Date.

  • Establishment of Collateral Account The Securities Intermediary hereby confirms that: (a) the Securities Intermediary has established the Collateral Account; (b) the Collateral Account is a securities account; (c) subject to the terms of this Agreement, the Securities Intermediary shall identify in its records the Collateral Agent as the entitlement holder entitled to exercise the rights that comprise any financial asset credited to the Collateral Account; (d) all property delivered to the Securities Intermediary pursuant to this Agreement, including any Applicable Ownership Interests in the Treasury Portfolio (as specified in clause (i) of the definition thereof) or Treasury Securities and the Permitted Investments, will be credited promptly to the Collateral Account; and (e) all securities or other property underlying any financial assets credited to the Collateral Account shall be (i) registered in the name of the Purchase Contract Agent and indorsed to the Securities Intermediary or in blank, (ii) registered in the name of the Securities Intermediary or (iii) credited to another securities account maintained in the name of the Securities Intermediary. In no case will any financial asset credited to the Collateral Account be registered in the name of the Purchase Contract Agent (in its capacity as such) or any Holder or specially indorsed to the Purchase Contract Agent (in its capacity as such) or any Holder, unless such financial asset has been further indorsed to the Securities Intermediary or in blank.

  • Collection of Accounts, General Intangibles and Negotiable Collateral At any time upon the occurrence and during the continuance of an Event of Default, Agent or Agent’s designee may (a) notify Account Debtors of any Grantor that the Accounts, General Intangibles, Chattel Paper or Negotiable Collateral of such Grantor have been assigned to Agent, for the benefit of the Lender Group and the Bank Product Providers, or that Agent has a security interest therein, and (b) collect the Accounts, General Intangibles and Negotiable Collateral of any Grantor directly, and any collection costs and expenses shall constitute part of such Grantor’s Secured Obligations under the Loan Documents.

  • Delivery of Additional Collateral If at any time the Custodian shall notify a Fund by Written Notice that the fair market value of the Collateral securing any Overdraft Obligation of one of such Fund's Portfolios is less than the amount of such Overdraft Obligation, such Fund, on behalf of the applicable Portfolio, shall deliver to the Custodian, within one (1) Business Day following the Fund's receipt of such Written Notice, an additional Pledge Certificate describing additional Collateral. If such Fund shall fail to deliver such additional Pledge Certificate, the Custodian may specify Collateral which shall secure the unsecured amount of the applicable Overdraft Obligation in accordance with Section 3 of this Appendix C.

  • Application of Proceeds of Collateral Except as provided in subsection 2.4B(iii)(a) with respect to prepayments from Net Asset Sale Proceeds, all proceeds received by Administrative Agent in respect of any sale of, collection from, or other realization upon all or any part of the Collateral under any Collateral Document may, in the discretion of Administrative Agent, be held by Administrative Agent as Collateral for, and/or (then or at any time thereafter) applied in full or in part by Administrative Agent against, the applicable Secured Obligations (as defined in such Collateral Document) in the following order of priority: (a) To the payment of all costs and expenses of such sale, collection or other realization, including reasonable compensation to Administrative Agent and its agents and counsel, and all other expenses, liabilities and advances made or incurred by Administrative Agent in connection therewith, and all amounts for which Administrative Agent is entitled to indemnification under such Collateral Document and all advances made by Administrative Agent thereunder for the account of the applicable Loan Party, and to the payment of all costs and expenses paid or incurred by Administrative Agent in connection with the exercise of any right or remedy under such Collateral Document, all in accordance with the terms of this Agreement and such Collateral Document; (b) thereafter, to the extent of any excess such proceeds, to the payment of all other such Secured Obligations for the ratable benefit of the holders thereof; and (c) thereafter, to the extent of any excess such proceeds, to the payment to or upon the order of such Loan Party or to whosoever may be lawfully entitled to receive the same or as a court of competent jurisdiction may direct.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!