Definition of Excusable Delay Sample Clauses

Definition of Excusable Delay. A Delay is “Excusable” if such act, event, or condition has a materially adverse effect on the ability of Contractor to perform its obligations under this Contract as scheduled, and/or materially increases the cost to Contractor to perform such obligations as scheduled and if such act, event, or condition and its effect:
Sample 1Sample 2
AutoNDA by SimpleDocs
Definition of Excusable Delay. The term “
Sample 1
Definition of Excusable Delay. A delay in the performance by Seller of any obligations under this Purchase Order, which is caused by an event which is outside the reasonable control of Seller, including but not limited to an act of God, act of government, fire, floods, epidemics, quarantine restrictions, strikes, freight embargo, unusually severe weather, riot, war, acts of terrorism or any other event which constitutes a superior force and is beyond the reasonable control of Seller. A delay caused by the default of a subcontractor of the Seller shall constitute an Excusable Delay if the event causing the default of such subcontractor is an event, which (i) meets the foregoing Definition of Excusable Delay and (ii) has not been caused by Seller, unless the subcontracted supplies or services were obtainable at reasonable prices on commercially reasonable terms from other sources in sufficient time for Seller to meet the required delivery schedule. In the event of an Excusable Delay, any affected delivery date shall be postponed for such period as is reasonably necessary to offset the effects of the Excusable Delay. No adjustment will be made to price under this Purchase Order. Adjustment of the delivery schedule is the exclusive remedy of Seller for an Excusable Delay.
Sample 1

Related to Definition of Excusable Delay

  • Excusable Delay The Contractor is entitled to an equitable adjustment of time, issued via Change Order, for delays caused by the following:

  • Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.

  • Definition of Force Majeure For the purposes of this section, an event of force majeure shall mean any cause beyond the control of the affected Interconnection Party or Construction Party, including but not restricted to, acts of God, flood, drought, earthquake, storm, fire, lightning, epidemic, war, riot, civil disturbance or disobedience, labor dispute, labor or material shortage, sabotage, acts of public enemy, explosions, orders, regulations or restrictions imposed by governmental, military, or lawfully established civilian authorities, which, in any of the foregoing cases, by exercise of due diligence such party could not reasonably have been expected to avoid, and which, by the exercise of due diligence, it has been unable to overcome. Force majeure does not include (i) a failure of performance that is due to an affected party’s own negligence or intentional wrongdoing; (ii) any removable or remediable causes (other than settlement of a strike or labor dispute) which an affected party fails to remove or remedy within a reasonable time; or (iii) economic hardship of an affected party.

  • Definition of Working Days Working day" as used in the Grievance and Arbitration procedure shall mean a day other than Saturday, Sunday or a recognized holiday.

  • Overtime Work Definition Overtime for non-exempt employees working any work schedule is actual time worked in excess of forty (40) hours per workweek.

  • Definition of a Grievance A grievance is defined as a dispute or disagreement as to the interpretation or application of the specific terms and conditions of this Agreement.

  • Definition of Service Fast Post‐Fault Active Power Recovery is the recovery of a Providing Unit’s MW Output to at least 90% of its pre‐Fault Disturbance MW Output within 250ms of the voltage at the Providing Unit’s Connection Point recovering to at least 90% of its pre‐Fault Disturbance value for any Fault Disturbance that is cleared within 900ms. The Providing Unit must be exporting Active Power to the Power System and must remain connected to the Power System for at least 15 minutes following the Fault Disturbance.

  • Overtime Definition Overtime shall be defined as being all hours worked in excess of the normal or standard work day, or in excess of the normal or standard work week. The overtime rate shall be one and one-half (1½) times the regular straight time hourly rate of pay. NOTE: Article 16.04 is applicable to full-time employees only.

  • Unavoidable Delay When construction is impeded as a result of strikes, lockouts, acts of God or other factors beyond the control, and ability to remedy, of the Developer.

  • Employee Definition The term “employee" when used in this Agreement will refer to all employees in the unit for bargaining as defined in Section 1.

Time is Money Join Law Insider Premium to draft better contracts faster.