Delay Rights Notwithstanding anything to the contrary contained herein, the Partnership may, upon written notice to any Selling Holder whose Registrable Securities are included in a Registration Statement, suspend such Selling Holder’s use of any prospectus which is a part of such Registration Statement (in which event the Selling Holder shall suspend sales of the Registrable Securities pursuant to such Registration Statement) if (i) the Partnership is pursuing an acquisition, merger, reorganization, disposition or other similar transaction and the Partnership determines in good faith that the Partnership’s ability to pursue or consummate such a transaction would be materially and adversely affected by any required disclosure of such transaction in such Registration Statement or (ii) the Partnership has experienced some other material non-public event, the disclosure of which at such time, in the good faith judgment of the Partnership, would materially and adversely affect the Partnership; provided, however, that in no event shall the Selling Holders be suspended from selling Registrable Securities pursuant to such Registration Statement for a period that exceeds an aggregate of sixty (60) days in any 180-day period or ninety (90) days in any 365-day period. Upon disclosure of such information or the termination of the condition described above, the Partnership shall provide prompt notice to the Selling Holders whose Registrable Securities are included in such Registration Statement, and shall promptly terminate any suspension of sales it has put into effect and shall take such other actions necessary or appropriate to permit registered sales of Registrable Securities as contemplated in this Agreement.
Delay No failure or delay on the part of any party in exercising any right, power, or remedy hereunder shall operate as a waiver thereof, nor shall any single or partial exercise of any such right, power, or remedy preclude any other or further exercise thereof or the exercise of any other right, power, or remedy. The remedies provided for herein are cumulative and are not exclusive of any remedies that may be available to a party at law or in equity or otherwise.
Power Failure Power Failure means the failure of power or other utility service if the failure takes place off the "residence premises". But if the failure results in a loss, from a Peril Insured Against on the "residence premises", we will pay for the loss caused by that peril.
Failure In the event the Company brings any action against Consultant for breach of this Agreement, Consultant’s entire liability to the Company shall not exceed the fees paid to Consultant hereunder. In no event shall Consultant be liable to the Company or any other party for any indirect, special or consequential damages, nor for any claim against the Company by any person or entity arising from or in any way related to this Agreement.
Effect of Failure or Delay in Requesting Compensation Failure or delay on the part of any Lender or the Issuing Bank to demand compensation pursuant to this Section 5.01 shall not constitute a waiver of such Lender’s or the Issuing Bank’s right to demand such compensation; provided that the Borrower shall not be required to compensate a Lender or the Issuing Bank pursuant to this Section 5.01 for any increased costs or reductions incurred more than 180 days prior to the date that such Lender or the Issuing Bank, as the case may be, notifies the Borrower of the Change in Law giving rise to such increased costs or reductions and of such Lender’s or the Issuing Bank’s intention to claim compensation therefor; provided further that, if the Change in Law giving rise to such increased costs or reductions is retroactive, then the 180-day period referred to above shall be extended to include the period of retroactive effect thereof.
No Delay Work requiring correction shall be corrected immediately and shall be carried out in such a way not to delay the completion of the Project. If it is not feasible to correct said work immediately, the corrective work shall be done on a schedule acceptable to the Owner.
Suspensions Upon giving no less than one day’s prior written notice to the Holders of Registrable Securities, the Company shall be entitled to delay or suspend the filing, effectiveness or use of a Registration Statement or Prospectus (a “Suspension”) if the Conflicts Committee of the Company’s Board of Directors determines in good faith that the filing, effectiveness or use of such Registration Statement or Prospectus would be materially detrimental to the Company and its shareholders because such registration would (x) materially interfere in a way materially adverse to the Company with a significant acquisition, merger, disposition, corporate reorganization or other similar transaction involving the Company, (y) require premature disclosure of material information that the Company has a bona fide business purpose for preserving as confidential or (z) render the Company unable to comply with requirements under applicable securities laws; provided, that the Company shall not be entitled to exercise a Suspension (i) more than twice during any 12-month period or (ii) for a period exceeding 90 days on any one occasion. The Company shall use its reasonable best efforts to resolve any Suspension. Each Holder who is notified by the Company of a Suspension pursuant to this Section 7 shall keep the existence of such Suspension confidential and shall immediately discontinue (and direct any other Person making offers or sales of Registrable Securities on behalf of such Holder to immediately discontinue) offers and sales of Registrable Securities pursuant to such Registration Statement or Prospectus until such time as it is advised in writing by the Company that the use of the Registration Statement or Prospectus may be resumed and, if applicable, is furnished by the Company with a supplemented or amended Prospectus as contemplated by Section 8(g). If the Company delays or suspends a Demand Registration, the Holder that initiated such Demand Registration shall be entitled to withdraw its Demand Registration Request and, if it does so, such Demand Registration Request shall not count against the limitation on the number of such Holder’s Demand Registrations set forth in Section 3(b).
Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.
Company’s Failure to Timely Convert If the Company shall fail to issue a certificate to the Holder or credit the Holder's balance account with DTC for the number of shares of Common Stock to which the Holder is entitled upon conversion of any Conversion Amount on or prior to the date which is five Business Days after the Conversion Date (a “Conversion Failure”), then the Company shall pay to the Holder payments (“Conversion Default Payments”) for a Conversion Failure in the amount of (i) (N/365), multiplied by (ii) an amount equal to the amount by which (x) the highest Closing Sale Price of the Common Stock during the period beginning on the date the Conversion Notice giving rise to the Conversion Failure in accordance with this Section 3(c)(ii) is transmitted (the “Conversion Failure Date”) and ending on the date immediately preceding the date on which the applicable Conversion Default Payment is made exceeds (y) the Conversion Price in respect of such Conversion Amount, multiplied by (iii) the number of shares of Common Stock the Company failed to so deliver in such Conversion Failure, multiplied by (iv) .18, where N equals the number of days from the Conversion Failure Date to the date that the Company effects the full conversion of the Conversion Amount which gave rise to the Conversion Failure. The accrued Conversion Default Payments for each calendar month shall be paid in cash to the Holder by the fifth day of the month following the month in which it has accrued. In addition to the foregoing, if within five Trading Days after the Company's receipt of the facsimile copy of a Conversion Notice the Company shall fail to issue and deliver a certificate to the Holder or credit the Holder's balance account with DTC for the number of shares of Common Stock to which the Holder is entitled upon such Holder's conversion of any Conversion Amount, and if on or after such Trading Day the Holder purchases (in an open market transaction or otherwise) Common Stock to deliver in satisfaction of a sale by the Holder of Common Stock issuable upon such conversion that the Holder anticipated receiving from the Company (a “Buy-In”), then the Company shall, within three Business Days after the Holder's request and in the Holder's discretion, either (i) pay cash to the Holder in an amount equal to the Holder's total purchase price (including brokerage commissions and other out-of-pocket expenses, if any) for the shares of Common Stock so purchased (the “Buy-In Price”), at which point the Company's obligation to deliver such certificate (and to issue such Common Stock) shall terminate, or (ii) promptly honor its obligation to deliver to the Holder a certificate or certificates representing such Common Stock and pay cash to the Holder in an amount equal to the excess (if any) of the Buy-In Price over the product of (A) such number of shares of Common Stock times (B) the Closing Sale Price on the Conversion Date. Nothing herein shall limit the Holder’s right to pursue actual damages for the Company’s failure to maintain a sufficient number of authorized shares of Common Stock or to otherwise issue shares of Common Stock upon conversion of this Note in accordance with the terms hereof, and the Holder shall have the right to pursue all remedies available at law or in equity (including a decree of specific performance and/or injunctive relief).
Termination Due To Lack Of Funding Appropriation If, in the judgment of the Director of Accounts and Reports, Department of Administration, sufficient funds are not appropriated to continue the function performed in this agreement and for the payment of the charges hereunder, State may terminate this agreement at the end of its current fiscal year. State agrees to give written notice of termination to contractor at least 30 days prior to the end of its current fiscal year, and shall give such notice for a greater period prior to the end of such fiscal year as may be provided in this contract, except that such notice shall not be required prior to 90 days before the end of such fiscal year. Contractor shall have the right, at the end of such fiscal year, to take possession of any equipment provided State under the contract. State will pay to the contractor all regular contractual payments incurred through the end of such fiscal year, plus contractual charges incidental to the return of any such equipment. Upon termination of the agreement by State, title to any such equipment shall revert to contractor at the end of the State's current fiscal year. The termination of the contract pursuant to this paragraph shall not cause any penalty to be charged to the agency or the contractor.
