DELIVERY DATE REQUIRED BY AGENCY. Weekly and Bi-weekly delivery schedule.
DELIVERY DATE REQUIRED BY AGENCY Sample Clauses
Related to DELIVERY DATE REQUIRED BY AGENCY
INSURANCE REQUIREMENT REVIEW Grantee agrees to periodic review of insurance requirements by Agency under this Agreement and to provide updated requirements as mutually agreed upon by Grantee and Agency.
Delivery Schedule The Goods specified in the List of Goods are required to be delivered within the acceptable time range (after the earliest and before the final date, both dates inclusive) specified in Section V, Schedule of Requirements. No credit will be given to deliveries before the earliest date, and Tenders offering delivery after the final date shall be treated as non-responsive. Within this acceptable period, an adjustment of [insert the adjustment factor], will be added, for evaluation purposes only, to the Tender price of Tenders offering deliveries later than the “Earliest Delivery Date” specified in Section V, Schedule of Requirements.
Drug-Free Workplace Certification As required by Executive Order No. 90-5 dated April 12, 1990, issued by the Governor of Indiana, the Company hereby covenants and agrees to make a good faith effort to provide and maintain a drug-free workplace at the Project Location. The Company will give written notice to the IEDC within ten (10) days after receiving actual notice that the Company, or an employee of the Company in the State of Indiana, has been convicted of a criminal drug violation occurring in the workplace. False certification or violation of this certification may result in sanctions including, but not limited to, suspension of payments under the Agreement, termination of the Agreement and/or debarment of contracting opportunities with the State for up to three (3) years. In addition to the provisions of the above paragraph, if the total amount set forth in the Agreement is in excess of $25,000.00, the Company agrees that it will provide a drug-free workplace by: A. Publishing and providing to all of its employees a statement notifying them that the unlawful manufacture, distribution, dispensing, possession or use of a controlled substance is prohibited in the Company’s workplace, and specifying the actions that will be taken against employees for violations of such prohibition;
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Reporting Covenant Required Complies Borrowing Base Certificate Monthly within 25 days of month end Yes No Quarterly financial statements with churn report and Compliance Certificate Quarterly within 50 days of quarter end Yes No Annual financial statements (CPA Audited) FYE within 120 days Yes No 10K and 10Q Within 5 days of filing Yes No A/R Audit Semi-annually Yes No IP Notices As required under Section 6.10 Yes No
Post-Closing Requirements Borrowers shall complete each of the post-closing obligations and/or provide to Agent each of the documents, instruments, agreements and information listed on Schedule 7.4 attached hereto on or before the date set forth for each such item thereon, each of which shall be completed or provided in form and substance satisfactory to Agent.
CERTIFICATION REGARDING DRUG-FREE WORKPLACE REQUIREMENTS 1. The Contractor certifies that it will provide a drug-free workplace by: a. Publishing a statement notifying employees that the unlawful manufacture, distribution, dispensing, possession or use of a controlled substance is prohibited in the Contractor’s workplace and specifying the actions that will be taken against employees for violation of such prohibition;
Evidence of Compliance with Conditions Precedent The Guarantor shall provide to the Guarantee Trustee such evidence of compliance with such conditions precedent, if any, provided for in this Guarantee Agreement that relate to any of the matters set forth in Section 314(c) of the Trust Indenture Act. Any certificate or opinion required to be given by an officer pursuant to Section 314(c)(1) may be given in the form of an Officers' Certificate.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
CONTRACT COMPLIANCE REQUIREMENT The HUB requirement on this Contract is 0%. The student engagement requirement of this Contract is 0 hours. The Career Education requirement for this Contract is 0 hours. Failure to achieve these requirements may result in the application of some or all of the sanctions set forth in Administrative Policy 3.10, which is hereby incorporated by reference.
