Delivery of Samples. As part of the costs covered by the GMP, Contractor shall provide and deliver all samples to be tested at locations other than the Site. Samples shall be delivered either to the Project Inspector or to the testing laboratory or such other address specified in the Contract Documents. Delivery of all samples to the testing laboratory shall be made in ample time to allow the test to be made without delaying construction. No extra time will be allowed for the completion of the Work by reason of delay in testing samples required by the Contract Documents or due to Contractor’s request for substitution. Contractor shall allow free access at all times to the representatives of the testing laboratory to the Work, and shall point out the sources from which samples are taken. All test reports shall be sent to all parties specified in the Contract Documents.
Delivery of Samples. Before delivering Products to Biosil in accordance with Section 6.1, ASC will courier to Biosil (by Federal Express or other reputable courier service) sufficient quantities of a sample of the Products to be shipped to enable Biosil to conduct the tests envisaged in Section 6.5.1. Courier costs of samples will be borne by Biosil.
Delivery of Samples. 2 The Entity shall, at its sole cost and expense, furnish, package, mark, and deliver all samples to be tested at 3 locations other than the Site. Samples shall be delivered either to the Project Inspector or to the testing 4 laboratory or such other address specified by the District’s Representative. 5 6 Delivery of all samples to the testing laboratory shall be made in ample time to allow the test to be made 7 without delaying construction. No extra time will be allowed for the completion of the Work by reason of 8 delay in testing samples required by the Construction Documents or due to the Entity’s request for 9 substitution. 11 The Entity shall allow free access at all times to the representatives of the testing laboratory to the Work, and 12 shall point out the sources from which samples are taken. 13 14 All test reports shall be sent to all parties specified by the District’s Representative. 15
Delivery of Samples. Upon timely delivery of samples, AFL will use its best efforts in meeting standard turnaround times. The risk of loss or damage to the sample during shipment remains with CLIENT. AFL will advise you of samples which are missing or received in damaged, contaminated, or improperly preserved condition. The risk of loss or damage to the sample will be assumed by AFL at the time possession of the sample is delivered to an employee of AFL. AFL reserves the right to refuse, to accept, or to rescind acceptance of any sample, which in the judgment of AFL is likely to pose any unreasonable risk in handling and/or analysis. CLIENT represents and warrants that any sample containing any hazardous substance, which is to be delivered to AFL will be packaged, labeled, transported, and delivered in accordance with applicable laws.
Delivery of Samples. Unless otherwise arranged with and approved by GLS in writing, Client will deliver, or cause to be delivered, each sample to GLS’ testing facilities. Within five (5) business days of delivery to GLS, GLS will notify Client of any missing samples or samples that are received in a damaged and/or contaminated condition or any other discrepancy. Upon such notification, Client will provide GLS with additional instructions regarding such missing, damaged and/or contaminated samples. GLS will have the right to refuse acceptance of, or to return at Client’s expense, any sample that GLS deems, in its sole discretion, to present a hazard or an unreasonable risk with respect to its handling and/or analysis. Notwithstanding anything to the contrary herein, Client will retain the risk of loss or damage to all samples during shipment to GLS.
Delivery of Samples. 3.1 Whole blood samples collected under the NSP will be sent to the Contractor by the Authority once the Authority is content that the Contractor has demonstrated a validated genotyping service as detailed in Conditions 3.2 and 3.3.
Delivery of Samples. If Client requires Samples to be shipped separately from any Batch, OXB will ship such Samples as directed by Client Ex Works (INCOTERMS 2020) the Facility. OXB shall notify Client of the date on which the Samples will be ready for collection and the place of Delivery at least [***] prior to making them available for collection. Within [***] following completion of any study or assay, unless OXB has previously agreed in writing to transfer any remaining unused materials to Client at Client’s cost, OXB will discard or destroy any remaining unused material, provided such unused material is not required by cGMP to be retained, at Client’s request and expense.
Delivery of Samples. Upon timely delivery of samples, NEOGEN will use its good faith efforts in meeting standard turnaround times. The risk of loss or damage to the sample during shipments remains with CLIENT. NEOGEN will advise CLIENT of the samples which are missing or received in damaged, contaminated, or improperly preserved condition. The risk of loss or damage to the sample will be assumed by NEOGEN at the time possession of the sample is delivered to an employee of NEOGEN. NEOGEN reserves the right to refuse to accept or to rescind acceptance of any sample, which in the judgement of NEOGEN is likely to pose any unreasonable risk in handling and/or analysis. CLIENT represent and warrant that any sample containing any hazardous substance which is to be delivered to NEOGEN will be packaged, labeled, transported and delivered in accordance with applicable laws.
Delivery of Samples. Upon timely delivery of samples, AAL will use its best efforts in meeting standard turnaround times. The risk of loss or damage to the sample during shipment remains with CLIENT. AAL will advise you of samples which are missing or received in damaged, contaminated, or improperly preserved condition. The risk of further loss or damage to the sample will be assumed by AAL at the time possession of the sample is delivered to an employee of AAL. AAL reserves the right to refuse, to accept, or to rescind acceptance of any sample, which in the judgment of AAL is likely to pose any unreasonable risk in handling and/or analysis. CLIENT represents and warrants that any sample containing any hazardous substance, which is to be delivered to AAL will be packaged, labeled, transported, and delivered in accordance with applicable laws.
Delivery of Samples. Upon timely delivery of samples, Company will use commercially reasonable efforts in meeting standard turnaround times. The risk of loss or damage to the sample during shipment remains with you. Company will advise you of samples which are missing or received in damaged, contaminated, or improperly preserved condition. The risk of loss or damage to the sample will be assumed by Company at the time possession of the sample is delivered to an employee of Company; however, Company’s sole responsibility in the event of such loss or damage shall be to pay for the cost of delivering a substitute sample. Company reserves the right to refuse to accept or to rescind acceptance of any sample, which in the judgment of Company is likely to pose any unreasonable risk in handling and/or analysis. You represent and warrant that any sample containing any hazardous substance which is to be delivered to Company will be packaged, labeled, transported, and delivered in accordance with applicable laws.
