Design Warranty and Indemnity
Design Warranty and Indemnity Sample Clauses
Related to Design Warranty and Indemnity
Warranty and Indemnity 9.1. The Contractor warrants to the Department that the obligations of the Contractor under this Contract will be performed by appropriately qualified and trained personnel with reasonable skill, care and diligence and to such high standards of quality as it is reasonable for the Department to expect in all the circumstances. The Department will be relying upon the Contractor's skill, expertise and experience in the performance of the Project and also upon the accuracy of all representations or statements made and the advice given by the Contractor in connection with the performance of the Project and the accuracy of any documents conceived, originated, made or developed by the Contractor as part of this Contract. The Contractor warrants that any goods supplied by the Contractor forming part of the Services will be of satisfactory quality and fit for their purpose and will be free from defects in design, material and workmanship. 9.2. Without prejudice to any other remedy, if any part of the Project is not performed in accordance with this Contract then the Department shall be entitled, where appropriate to: 9.2.1. require the Contractor promptly to re-perform or replace the relevant part of the Project without additional charge to the Department; or 9.2.2. assess the cost of remedying the failure (“the assessed cost”) and to deduct from any sums due to the Contractor the Assessed Cost for the period that such failure continues. 9.3. The Contractor shall be liable for and shall indemnify the Department in full against any expense, liability, loss, claim or proceedings arising under statute or at common law in respect of personal injury to or death of any person whomsoever or loss of or damage to property whether belonging to the Department or otherwise arising out of or in the course of or caused by the performance of the Project. 9.4. Without prejudice to any other exclusion or limitation of liability in this Contract, the liability of the Contractor for any claim or claims under this Contract shall be limited to such sums as it would be just and equitable for the Contractor to pay having regard to the extent of his responsibility for the loss or damage giving rise to such claim or claims etc. 9.5. All property of the Contractor whilst on the Department's premises shall be there at the risk of the Contractor and the Department shall accept no liability for any loss or damage howsoever occurring to it. 9.6. The Contractor shall ensure that it has adequate insurance cover with an insurer of good repute to cover claims under this Contract or any other claims or demands which may be brought or made against it by any person suffering any injury damage or loss in connection with this Contract. The Contractor shall upon request produce to the Department, it's policy or policies of insurance, together with the receipt for the payment of the last premium in respect of each policy or produce documentary evidence that the policy or policies are properly maintained
Warranty and Indemnification Executive warrants that Executive is not a party to any restrictive agreement limiting Executive’s activities in his employment by the Company. Executive further warrants that at the time of the signing of this Agreement, Executive knows of no written or oral contract or of any other impediment that would inhibit or prohibit employment with the Company, and that Executive will not knowingly use any trade secret, confidential information, or other intellectual property right of any other party in the performance of Executive’s duties hereunder. Executive shall hold the Company harmless from any and all suits and claims arising out of any breach of such restrictive agreement or contracts.
Intellectual Property Warranty and Indemnification Contractor represents and warrants that any materials or deliverables, including all Deliverable Materials, provided under this Contract are either original, or not encumbered, and do not infringe upon the copyright, trademark, patent or other intellectual property rights of any third party, or are in the public domain. If Deliverable Materials provided hereunder become the subject of a claim, suit or allegation of copyright, trademark or patent infringement, City shall have the right, in its sole discretion, to require Contractor to produce, at Contractor’s own expense, new non-infringing materials, deliverables or works as a means of remedying any claim of infringement in addition to any other remedy available to the City under law or equity. Contractor further agrees to indemnify, defend, and hold harmless the City, its officers, employees and agents from and against any and all claims, actions, costs, judgments or damages, of any type, alleging or threatening that any Deliverable Materials, supplies, equipment, services or works provided under this contract infringe the copyright, trademark, patent or other intellectual property or proprietary rights of any third party (Third Party Claim of Infringement). If a Third Party Claim
Liability and Indemnity a. In no event shall the City be liable to the Contractor for special, indirect, or consequential damages, except those caused by the City’s gross negligence or willful or wanton misconduct arising out of or in any way connected with a breach of this contract. The maximum liability of the City shall be limited to the amount of money to be paid or received by the City under this contract. b. The Contractor shall defend, indemnify and save harmless the City, its elected or appointed officials, agents and employees from and against any and all liability, suits, damages, costs (including attorney fees), losses, outlays and expenses from claims in any manner caused by, or allegedly caused by, or arising out of, or connected with, this contract, or the work or any subcontract thereunder (the Contractor hereby assuming full responsibility for relations with subcontractors), including, but not limited to, claims for personal injuries, death, property damage, or for damages from the award of this contract to Contractor, notwithstanding any possible negligence, whether sole or concurrent, on the part of the City, its officials, agents and employees. c. The Contractor shall indemnify and hold the City harmless from all wages or overtime compensation due any employees in rendering services pursuant to this agreement or any subcontract, including payment of reasonable attorneys’ fees and costs in the defense of any claim made under the Fair Labor Standards Act, the Missouri Prevailing Wage Law or any other federal or state law. d. The indemnification obligations of Contractor hereunder shall not be limited by any limitations as to the amount or type of damages, compensation or benefits payable by or for the Contractor, under any federal or state law, to any person asserting the claim against City, its elected or appointed officials, agents and employees, for which indemnification is sought. e. The indemnification obligations herein shall not negate, abridge or reduce in any way any additional indemnification rights of the City, its elected or appointed officials, agents and employees, which are otherwise available under statute, or in law or equity. f. Contractor affirms that it has had the opportunity to recover the costs of the liability insurance required in this agreement in its contract price. Contractor’s obligation under this agreement to defend, indemnify, and hold harmless any person from that person’s own negligence or wrongdoing is limited to the coverage and limits of the applicable insurance required of the Contractor under this agreement. g. The Contractor shall indemnify and hold the City harmless for any penalties, fines, fees or costs, including costs of defense, which are charged or assessed by any Federal, state or local agency including, but not limited to, Environmental Protection Agency or Department of Natural Resources.
Exclusion of Liability and Indemnity 7.1 Nothing in this clause 7 shall restrict or exclude liability of HKEX-IS or the Licensee in respect of death or personal injury resulting from negligence. 7.2 Subject to the foregoing, none of HKEX-IS, the Exchanges, any other member of the HKEX Group or any of their directors, officers, employees or agents shall be liable to the Licensee or any person claiming through the Licensee in respect of consequential, economic or any other loss or damage arising from any act or omission, mistake, delay, interruption, arising from or in connection with (a) the collection, use or transmission of the Information by or to the Licensee or (b) the Information being inaccurate, incomplete or otherwise misleading or (c) any other services to be provided by them pursuant to this Agreement, except to the extent of the wilful default, gross negligence or fraud of HKEX-IS, the Exchanges or any other member of the HKEX Group. Further the Licensee undertakes not to institute or attempt or threaten to institute any proceedings in any jurisdiction in or outside Hong Kong against HKEX-IS, the Exchanges, any other member of the HKEX Group or any of their directors, officers, employees or agents for recovery of any of the aforesaid loss suffered by the Licensee or by any other person or otherwise to maintain any claim against HKEX-IS, the Exchanges, any member of the HKEX Group or any of their directors, officers, employees or agents for or in respect of any of the aforesaid loss, provided that the Licensee shall not be precluded from instituting proceedings in the event of the wilful default, gross negligence or fraud of HKEX-IS, the Exchanges or any other member of the HKEX Group. 7.3 Subject to clause 7.1, the Licensee shall at all times hereafter indemnify and keep HKEX-IS, the Exchanges, all other members of the HKEX Group and all of their directors, officers, employees or agents effectively indemnified on demand against and in respect of all liabilities, economic or other losses, damages, costs, claims, suits, demands, fees and expenses of whatsoever nature which may be incurred by HKEX-IS, the Exchanges, any other member of the HKEX Group or any of their directors, officers, employees or agents towards or in relation to any person or which may be taken, made or claimed against HKEX-IS, the Exchanges, any other member of the HKEX Group or any of their directors, officers, employees or agents by any person as a result of or in connection with or arising out of any act, omission, mistake, delay or interruption, on the part of the Licensee, or on the part of HKEX-IS, the Exchanges, any other member of the HKEX Group or any of their directors, officers, employees or agents in relation to this Agreement, including (without prejudice to the generality of the foregoing) acts or omissions in respect of or in connection with or arising out of the collection, use or transmission of the Information by or to the Licensee or arising from the Information being inaccurate, incomplete or otherwise misleading, except to the extent of the wilful default, gross negligence or fraud of HKEX-IS, the Exchanges, any other member of the HKEX Group or any of their directors, officers, employees or agents. 7.4 The Licensee agrees to the exclusion of liability and indemnity under this clause 7 in favour of HKEX- IS, the Exchanges, other members of the HKEX Group and any of their directors, officers, employees or agents in consideration of the Exchanges consenting to HKEX-IS entering into this Agreement. For 7.5 HKEX-IS shall not be obliged to procure the supply of Third Party Content nor shall it ensure the accuracy, timeliness, reliability and completeness of any Third Party Content.
Warranties and Indemnity 5.1 In consideration of the Investor agreeing to enter into this Agreement, to purchase the Sale Shares and to subscribe for the Subscription Shares, the Existing Shareholder hereby represents and warrants to the Investor in the terms set out in Part 3 of the Schedule. 5.2 In consideration of the Investor agreeing to enter into this Agreement, to purchase the Sale Shares and to subscribe for the Subscription Shares, the Company hereby represents and warrants to the Investor in the terms set out in Part 3 of the Schedule. 5.3 The Warranties shall be given at the date of Completion. 5.4 The Existing Shareholder and the Company acknowledge that they are aware that the Investor, when agreeing to purchase the Sale Shares and subscribe for the Subscription Shares is or will be relying on the accuracy of the Warranties (save only as disclosed in the Disclosure Letter) and on the Tax Undertaking. The Warranties and the Tax Undertaking shall survive Completion of the purchase of the Sale Shares and the subscription for the Subscription Shares by the Investor. 5.5 Each Warranty which is set out in a separate paragraph, or which could be treated as a separate Warranty, shall be construed independently of any other to the intent that the rights of the Investor under, and the meaning given to, any one such Warranty shall not be restricted by reference to any other Warranty. 5.6 If the Investor makes a claim against the Existing Shareholder in relation to any breach of Warranty but, in relation to the same subject matter, does not make (or, having made, does not succeed with), any claim against the Company under Clause 5.2, the Existing Shareholder shall not have or pursue any claim or third party action to join in, claim against, seek a contribution from or otherwise claim or seek damages or compensation from the Company or any other Group Company in respect of any such claim and the Existing Shareholder hereby confirms to the Investor that neither the Company nor any Group Company has entered into or will enter into any indemnity or other agreement or arrangement concerning the liabilities of the Existing Shareholder for any breach of the Warranties. 5.7 The Existing Shareholder and the Company shall not be liable in respect of any claim under the Warranties to the extent that the matter or matters giving rise to such a claim are fairly disclosed in the Disclosure Letter. The Existing Shareholder and the Company each undertake to the Investor that any particulars of such matter or matters are true and accurate in all material respects and are not misleading in any material respect. 5.8 The aggregate liability of the Existing Shareholder in respect of any breach or breaches of the Warranties and the Tax Undertaking shall be limited to a maximum sum of (pound)750,000 ("the Maximum Amount"). 5.9 Neither the Existing Shareholder nor the Company shall have any liability under the Warranties and the Tax Undertaking unless and until the liability thereunder exceeds (pound)35,000 and thereafter the Existing Shareholder shall be liable for the entire amount up to the Maximum Amount. 5.10 The Existing Shareholder and the Company shall not be liable in respect of any claim under the Warranties or the Tax Undertaking (as the case may be) unless the claim shall have been notified to her before the expiry of a period of 12 months from Completion in the case of a claim under the Warranties and 36 months from Completion in the case of a claim under the Tax Undertaking. Any claim so notified will cease to be recoverable if legal proceedings in respect of such claim have not been commenced within 15 months from Completion in the case of a claim under the Warranties and 48 months from Completion in the case of a claim under the Tax Undertaking (unless settled, compromised or withdrawn within such period). In this respect, legal proceedings shall include commencement of any agreed arbitration. Notice of a claim shall include reasonable details of the nature and substance of the claim. 5.11 No liability or increase in liability (as the case may be) shall attach to the Existing Shareholder or the Company in respect of a claim under this Agreement to the extent that such claim arises or is increased as a consequence of a change in the law after the date hereof. 5.12 In the event that the Company is entitled to recover from a third party (whether by payment, discount, credit, relief or otherwise howsoever) any sum in relation to any loss, liability or damage which is the subject of a claim under the Warranties or the Tax Undertaking, the Company shall take (at the expense of the Existing Shareholder) such reasonable steps or proceedings as she may reasonably require and shall act in accordance with any such requirements subject to the Company being indemnified by the Existing Shareholder against all reasonable costs and expenses incurred in connection therewith and shall keep the Investor promptly informed of the progress of any such steps, proceedings or actions. 5.13 In the event of the Existing Shareholder or the Company having paid to the Investor an amount in respect of a claim under the Warranties or the Tax Undertaking and subsequent to the date of making such payment the Investor recovers from a third party (whether by payment, discount, credit, relief or otherwise howsoever) a sum which is referable to that payment then the Investor shall as soon as reasonably practicable repay to the Existing Shareholder or the Company of so much of the amount paid by the third party as does not exceed the sum paid by the Existing Shareholder or the Company to the Investor less the reasonable costs of the Investor in recovering such sum. 5.14 If any claim under the Warranties shall arise by reason of some liability of the Company which, at the time the claim is notified to the Existing Shareholder, is contingent only, the Existing Shareholder shall not be under any obligation to make any payment to the Investor in respect of such claim until such time as the contingent liability shall become an actual liability. 5.15 Nothing herein or in the Warranties shall be deemed to relieve the Investor from any common law or other duty to mitigate any loss or damage incurred by it. 5.16 Any amount paid by the Existing Shareholder to the Investor in respect of any breach of the Warranties shall be treated as a reduction in the consideration for the Sale Shares. 5.17 The Investor warrants to the Existing Shareholder that the Investor has power to enter into this Agreement and to perform the obligations expressed to be assumed by it and the Investor and Eurotelecom have taken or will, as soon as reasonably practicable, take all necessary corporate action to authorise the execution, delivery and performance of this Agreement and the issue of the Eurotelecom Shares.
Limitations of Liability and Indemnity 9.1 In the event the Company provides advice, information or recommendations to the Client, the Company shall not be responsible for the profitability of such advice, information or recommendations. The Client acknowledges that the Company shall not, in the absence of its fraud, willful default or gross negligence, be liable for any losses, costs, expenses or damages suffered by the Client arising from any inaccuracy or mistake in any information given to the Client including, without limitation, information relating to any Transactions. Subject to the right of the Company to void or close any Transaction in the specific circumstances set out the Operative Agreements, any Transaction following such inaccuracy or mistake shall nonetheless remain valid and binding in all respects on both the Company and the Client. 9.2 The Company shall not be liable for any loss or expense incurred by the Client in connection with, or directly or indirectly arising from: a) any error or failure in the operation of the Trading Platform or any delay caused by the Client Terminal; b) Transactions made via the Client Terminal; c) any failure by the Company to perform any of its obligations under the Operative Agreements as a result of a cause beyond its control; or d) acts, omissions or negligence of any third party. 9.3 The Client shall indemnify the Company and keep the Company indemnified on demand in respect of all liabilities, costs, claims, demands and expenses of any nature whatsoever which the Company suffers or incurs as a direct or indirect result of any failure by the Client to perform any of the Client’s obligations under the Operative Agreements. 9.4 The Company shall in no circumstances be liable to the Client for any consequential special or indirect losses, loss of profits, loss of opportunity (including in relation to subsequent market movements), costs, expenses or damages the Client may suffer in relation to the Operative Agreements, unless otherwise agreed in the Terms of Business.
LIMITATION OF LIABILITY AND INDEMNITY 19.1. Subject to the provisions of the relevant laws that are applicable in the Republic of Cyprus from time to time: a) AM CY and any Affiliates make no warranties either expressly or impliedly as to merchantability, fitness for a particular purpose, or otherwise (including as to accuracy, availability, completeness or quality), with respect to any services offered by virtue of the Agreement, including, without limitation, AM CY’s trading platform; b) AM CY and its Affiliates are excluded from all liability in contract or otherwise relating to or resulting from use of any service to be provided under this Agreement and for any loss incurred by you directly or indirectly without limitation as a result of or arising out of: i. any inaccuracy, error or delay in or omission from any information provided to you under this Agreement; ii. any delays or failures or inaccuracies, or loss of access to, the provision of a service to you including, without limitation, any delay, failure or inaccuracy in, or the loss of access to, the trading platform or in respect of the transmission of orders, instructions or any other information; iii. any misinterpretation of your order or instructions which are unclear, ambiguous, or not specific; or iv. a service disruption event. 19.2. AM CY and its Affiliates are not liable in contract, tort (including negligence) or otherwise for any loss of prospective profits or expenses or special, indirect or consequential damages resulting from the supply of a service and the provision of custodial or depository services (as and if applicable). 19.3. To the fullest extent permitted by law, you release, discharge and indemnify and agree to keep AM CY, its Affiliates and their directors, officers, employees, associates, agents and representatives as well as their affiliates indemnified from and against all claims arising out of: a) any default, whether by your act or omission under this Agreement or any order, instruction or transaction; b) any breach by you of any applicable law; c) any representation or warranty made or given by you under this Agreement proven to be untrue or incorrect; d) any error, omission, fraud, malfeasance, negligence, misappropriation or criminal act or omission by you or by any of your clients, employees, agents or authorised persons, consultants or servants; e) any failure of any of your computer or electronic systems or networks to perform, be available or successfully transmit data to AM CY, or any error or inadequacy in the data or information input into such systems or networks by you; f) any delays in processing any order or instruction including, for instance, as a result of systems or market delays, or due to verification procedures or unauthorised processes or due to call waiting time or adherence to internal policies and procedures; g) anything lawfully done by AM CY in accordance with, pursuant or incidental to this Agreement; h) any instruction, request or direction given by you; i) by reason of AM CY complying with any direction, request or requirement of applicable law, any financial market, any government body or any regulatory body having jurisdiction over AM CY; j) arising from and in connection with or in any way related to AM CY in good faith accepting and acting on instructions received by facsimile transmission, email or by other means which are signed by or purported to be signed by you or any authorised person; k) arising out of AM CY’s observance of this Agreement; or l) payable in connection with the acquisition of any financial product or in relation to any calls or demands for payments (including unpaid capital) in respect of them.
Limitations of Liability and Indemnification 5.1 No Personal Liability of Shareholders, Trustees, etc......................................11 5.2
Liability and Indemnities Save where alternative arrangements regarding liabilities and indemnities are agreed in writing between the Participating Bodies, the following shall apply. The Host Practice shall accept responsibility for, and shall at all times indemnify the Sending Body and Staff Members fully against, and hold them harmless from, all civil liabilities and in respect of or consequent on any illness, injury, death, damage or costs suffered, sustained or incurred arising out of or in connections with: any act or omission on the part of a Staff Member during or in connection with a Vaccination Session; or any act or omission by the Host Practice or its employees or agents during or in connection with a Vaccination Session. It is agreed and understood that Staff Members will be carrying out NHS primary medical services on behalf of the Host Practice and therefore will have the benefit of the CNSGP indemnity arrangements in respect of relevant liabilities covered by those arrangements. The Host Practice is required to ensure that it maintains appropriate and adequate insurance cover in respect of all non-clinical liabilities that may arise in connection with the delivery of the Vaccination Programme or participation in any Vaccination Session by any Staff Members, save for professional indemnity liabilities, which will be the responsibility of the relevant Staff Member. The Participating Bodies hereby indemnify each other against any and all claims, liabilities, actions, proceedings, costs (including legal fees), losses, damages, fines, expenses and demands suffered or incurred by any other Participating Body arising out of or resulting from the acts or omissions of the indemnifying Participating Body in respect of its employment or engagement of a Staff Member including but not limited to: its breach of this MOU; in the case of a Sending Body, the employment/engagement or termination of employment/engagement of the Staff Member; or in the case of the Host Practice, any actions it undertakes relating to a Staff Member during a Transfer Period and including, where no other indemnity arrangements provided for by NHS Resolution may apply, liability for personal injury, accident or illness suffered, breach of contract or in tort, unfair dismissal, equal pay, discrimination of any kind or under any legislation applicable in the United Kingdom.
