Development and Testing Sample Clauses
Development and Testing. Eleven has been, and currently is, engaged in the process of developing and testing a POS Pinpad with Integrated Tactually Discernable Keypad for use in 7-Eleven Stores.
Development and Testing. First Union has finalized the initial development and testing of its Talking ATM project.
Development and Testing. Washington Mutual, in conjunction with its principal ATM vendor, commenced in May 2000 and has developed and tested, in a controlled laboratory setting, Washington Mutual Talking ATMs.
Development and Testing. Wal-Mart has been, and currently is, engaged in the process of developing and testing a POS Terminal with Integrated Tactually Discernable Keypad for use in Wal-Mart Stores. Claimants have provided comments and suggestions to Wal- Mart in connection with the development and testing of this terminal. Claimants agree and acknowledge that installation of POS Terminals with Integrated Tactually Discernable Keypads in the manner set forth in this Agreement satisfies their Claims pursuant to any and all Access Laws.
Development and Testing. 3.1.1. Trader Joe’s has been, and currently is, engaged in the process of
3.1.2. For thirty days, beginning no later than August 31, 2006, Trader Joe’s will install three (3) Point of Sale Terminals with Integrated Tactually
3.1.3. Assuming the testing performed pursuant to paragraph 3.1.2 above is successful, by no later than September 30, 2006, Trader Joe’s will install an additional three Point of Sale Terminals with Integrated Tactually Discernible Keypads in each of twelve (12) stores, for a total of thirty-six (36) additional terminals. The parties have agreed on the locations of these stores.
Development and Testing. Commercial licences often do not have terms within them to allow for testing and development on a platform unless they are specifically development licences. Development environments need to be appropriately licensed. This workshop will look at how in-house applications are developed and how they are licensed. It will also look at how the current staging or pre-production environments are covered for testing of patches and security updates prior to release into the production environment.
Development and Testing. Following the adoption of the Day Two Plan, Purchaser and Seller shall use commercially reasonable efforts to develop and test the Day Two Plan on or prior to November 15, 2001, or such other date as is agreed to in the Day Two Plan, and in connection therewith will cooperate in performing the activities, procedures and tests set forth under the heading "Development and Testing" in the Deliverables. To the extent that Agilent's responsibilities for such activities, procedures and tests shall not have been completed by November 15, 2001, or such other date as the parties agree, the terms of the relevant Service Level Agreements shall be extended, as provided in the Master Service Level Agreement.
Development and Testing. (a) Prior to: (1) obtaining a production key or other credentials for a new Application; (2) making any changes to the configuration of Your existing production key in respect of an existing Application; or (3) placing a modified and/or upgraded Application into production; in each case, You may be required to submit test results, from the testing of the Application, at Your expense, to Purolator in order for Purolator to confirm that the Application complies with the instructions, specifications and certification requirements (if applicable) provided by Purolator from time to time through the Resource Centre.
(b) Purolator retains the right to require You to submit to Purolator (or such Person designated by Purolator) for review and approval, any screen shots and other content included in an Application. You agree to make any changes to the Application requested by Purolator in order to conform to the requirements set out in this Agreement. All submissions and changes are at Your sole expense.
Development and Testing. (a) Xxxxx Systems shall develop, test, and deliver the deliverables required to implement the capabilities, features and functions described under each Detailed FRD, which includes the Legacy Customizations by performing the tasks and other activities described in the applicable AD&Ds, except to the extent such tasks and activities are assigned to Newco in such AD&Ds. Newco shall perform the tasks and other activities assigned to Newco in the AD&Ds.
(b) Each Party shall perform the unit, system, performance, quality assurance and other testing assigned to such Party for each capability, feature and function of the Legacy Customizations in accordance with the Detailed FRD relating to testing and the AD&D applicable to such capability, feature and function and the VRS Project Plan. Unless otherwise stated in the applicable Detailed FRD or the applicable AD&D, Newco shall be responsible for performing user acceptance tests in accordance with the mutually agreed test criteria and timeframes described in the applicable AD&D (which shall reflect the testing criteria and timeframes included in the Detailed FRD relating to testing). No element of the VRS Project will be placed into production until Newco has accepted such element.
(c) If Newco is unable to perform any task, including but not limited to develop or testing any deliverable or system, in accordance with the VRS Project Plan because a Xxxxx Systems deliverable or task is delayed (whether due to tardiness or defects), the completion date for such task shall be extended by the number of days by which Xxxxx Systems’ deliverable is delayed. Similarly, if Xxxxx Systems is unable to perform any task in accordance with the VRS Project Plan because a Newco deliverable or task is delayed (whether due to tardiness or defects), the completion date for such task shall be extended by the number of days by which Newco’s deliverable is delayed. Notwithstanding the foregoing, each Party shall use reasonable commercial efforts to mitigate the impact of any such delays on the VRS Project Plan by (i) performing all tasks that do not require the delayed deliverable, and (ii) taking such other actions as are reasonably practicable.
(d) Upon completion of testing in accordance with the applicable AD&D and the Detailed FRD relating to testing, Xxxxx Systems shall notify Newco, in writing, that the deliverables required under the VRS Project are complete and ready for testing. Following such notice, Newco’s VRS Project Manage...
Development and Testing. The COM DLL has been developed in Microsoft Visual C++ as a component object model dynamic link library to interface the Third Party Vendor's software with the Purchaser Satellite as per the specifications in Schedule "B". To test the COM DLL it was integrated into a Third Party Vendor's software. The integration was then setup in a live environment to read from and reply to the Purchaser Satellite. Two Third Party Vendors were chosen to complete the testing of the COM DLL: BNW Software (venue for live environment test was UCLA) and CMR Computer (venue for live environment test was a Ron Hemelgarn fitness xxxx). Xxxx sets of integrations and test installations were successful. Deliverables: - Development of COM DLL as per Schedule B specifications - Successful integration of COM DLL with two Third Party Vendors - Successful installation of Satellite controlled by COM DLL through Third Party Vendors' software PHASE 2: INTEGRATION