DISPUTES AND GRIEVANCES Section 1. This Agreement is intended to provide close cooperation between management and labor. Each of the Unions will assign a representative to this project for the purpose of completing the construction of the project economically, efficiently, continuously, and without interruptions, delays, or work stoppages.
Section 2. The Port of Seattle, Contractors, Unions, and the employees, collectively and individually, realize the importance to all parties to maintain continuous and uninterrupted performance of the work of the project, and agree to resolve disputes in accordance with the grievance-arbitration provisions set forth in this Article.
Section 3. Any question or dispute arising out of and during the term of this Project Agreement (other than trade jurisdictional disputes) shall be considered a grievance and subject to resolution under the following procedures:
(a) When any employee subject to the provisions of this Agreement feels he/she is aggrieved by a violation of this Agreement, he/she, through his/her local union business representative or designated Union Representative, shall, within five (5) working days after the occurrence, or had knowledge of or should have known of the alleged violation, give notice to the work-site representative of the involved Contractor stating the provision(s) alleged to have been violated. The business representative of the local union or the designated Union Representative and the work-site representative of the involved Contractor and the Owners Representative shall meet and endeavor to adjust the matter within three (3) working days after timely notice has been given. The representative of the Contractor shall keep the meeting minutes and shall respond to the Union representative in writing and the Owners Representatives at the conclusion of the meeting but not later than twenty-four (24) hours thereafter. If they fail to resolve the matter within the prescribed period, the grieving party may, within forty-eight (48) hours thereafter, pursue Step 2 of the Grievance Procedure, provided the grievance is reduced to writing, setting forth the relevant information concerning the alleged grievance, including a short description thereof, the date on which the grievance occurred, and the provision(s) of the Agreement alleged to have been violated.
(b) Should the Local Union(s) or the Project Contractor or any Sub-Contractor of whatever tier have a dispute with the other party and, if after conferring, a settlement is not reached within three (3) working days, the dispute may be reduced to writing and proceed to Step 2 in the same manner as outlined herein for the adjustment of an employee complaint.
Step 2. The International Union Representative and the involved Contractor shall meet within seven (7) working days of the referral of a dispute to this second step to arrive at a satisfactory settlement thereof. Meeting minutes shall be kept by the Contractor. If the parties fail to reach an agreement, the dispute may be appealed in writing in accordance with the provisions of Step 3 within seven (7) calendar days thereafter.
DISPUTES AND LITIGATION In the event of a dispute concerning the tenancy created by this agreement, TENANT agrees that whether or not the premises are being actively managed by an AGENT for the record OWNER, TENANT agrees to hold AGENT, its heirs, employees and assigns harmless and shall look solely to the record OWNER of the premises in the event of a legal dispute. INTEGRATION: This lease and exhibits and attachments, if any, set forth the entire agreement between LANDLORD and TENANT concerning the premises, and there are no covenants, promises, agreements, conditions, or understandings, oral or written between them other than those herein set forth. If any provision in this agreement is illegal, invalid or unenforceable, that provision shall be void but all other terms and conditions of the agreement shall be in effect. MODIFICATIONS: No subsequent alteration, amendment, change or addition to this lease shall be binding upon LANDLORD unless reduced to writing and signed by the parties. RADON GAS: State law requires the following notice to be given: "Radon is a naturally occurring radioactive gas that, when it has accumulated in a building in sufficient quantities, may present health risks to persons who are exposed to it over time. Levels of radon that exceed federal and state guidelines have been found in buildings in Florida. Additional information regarding radon and radon testing may be obtained from your county public health unit." ABANDONED PROPERTY: BY SIGNING THIS RENTAL AGREEMENT, THE TENANT AGREES THAT UPON SURRENDER, ABANDONMENT, OR RECOVERY OF POSSESSION OF THE DWELLING UNIT DUE TO THE DEATH OF THE LAST REMAINING TENANT, AS PROVIDED BY CHAPTER 83, FLORIDA STATUTES, THE LANDLORD SHALL NOT BE LIABLE OR RESPONSIBLE FOR STORAGE OR DISPOSITION OF THE TENANT'S PERSONAL PROPERTY. ADDITIONAL STIPULATIONS:
Disputes and Law I1 Governing Law and Jurisdiction
DISPUTES AND APPLICABLE LAW 18.1. All disputes arising out of or in connection with the Contract shall be finally settled under the Rules of Arbitration of the International Chamber of Commerce by one or more arbitrators appointed in accordance with the said Rules. The arbitral proceedings shall be held in English.
18.2. The Contract shall be governed by the substantive law of Switzerland.
Disputes and Claims Failure to file such a protest within the time specified shall constitute agreement on the part of the Contractor with the terms, conditions, amounts and adjustments or non- adjustment to the contract price and/or contract time set forth in the field order.
Disputes and Governing Law This Agreement shall be construed in accordance with the laws of the PRC. Any disputes that arise in connection with this Agreement shall be litigated in courts located within the Pudong New Area, Shanghai, the PRC.
Disputes and Adjustments of Invoices In the event an invoice or portion thereof or any other claim or adjustments arising hereunder, is disputed, payment of the undisputed portion of the invoice shall be required to be made when due, with Notice of the objection given to the other Party. Any invoice dispute or invoice adjustment shall be in writing and shall state the basis for the dispute or adjustment. Payment of the disputed amount shall not be required until the dispute is resolved. The Parties agree to use good faith efforts to resolve the dispute or identify the adjustment as soon as possible in accordance with the provisions of Article Eighteen (Dispute Resolution). Upon resolution of the dispute or calculation of the adjustment, any required payment shall be made within fifteen (15) calendar days of such resolution along with interest accrued at the Interest Rate from and including the due date, but excluding the date on which the payment is made. Inadvertent overpayments shall be returned upon request or deducted by the Party receiving such overpayment from subsequent invoices, with interest accrued at the Interest Rate from and including the date of such overpayment to but excluding the date repaid or deducted by the Party receiving such overpayment. Any dispute with respect to an invoice is waived unless the other Party is Notified in accordance with this Section 9.4 within twelve (12) months after the invoice is rendered or any specific adjustment to the invoice is made. If an invoice is not rendered within twelve (12) months after the close of the month during which performance giving rise to the payment obligation occurred (or in the case of amounts based on CAISO invoices within twelve (12) months after the close of the month during which such invoice or revised invoice giving rise to the payment obligation was rendered), the right to payment for such performance is waived.
Labor Disputes and Acts of God Neither the business nor the properties of the Borrower or any Subsidiary or any Guarantor are affected by any fire, explosion, accident, strike, lockout, or other labor dispute, drought, storm, hail, earthquake, embargo, act of God or of the public enemy, or other casualty (whether or not covered by insurance), materially and adversely affecting such business or properties or the operation of the Borrower or such Subsidiary or such Guarantor.
Disputes, Etc Prompt written notice of (i) any claims, legal or arbitration proceedings, proceedings before any Governmental Authority, or disputes, or to the knowledge of the Borrower threatened, or affecting the Borrower, or any of its Subsidiaries which, if adversely determined, could reasonably be expected to cause a Material Adverse Change, or any material labor controversy of which the Borrower or any of its Subsidiaries has knowledge resulting in or reasonably considered to be likely to result in a strike against the Borrower or any of its Subsidiaries and (ii) any claim, judgment, Lien or other encumbrance (other than a Permitted Lien) affecting any Property of the Borrower or any Subsidiary if the value of the claim, judgment, Lien, or other encumbrance affecting such Property shall exceed $1,000,000;
Complaints Process The School shall establish and adhere to a process for resolving public complaints which shall include an opportunity for complainants to be heard. The final administrative appeal shall be heard by the School's Governing Board, except where the complaint pertains to a possible violation of any law or term under this Contract. The complaints process shall be readily accessible from the School’s website, as described in Section 11.4.1.
