State Approval of Replacement Personnel The Engineer may not replace the project manager or key personnel without prior consent of the State. The State must be satisfied that the new project manager or other key personnel is qualified to provide the authorized services. If the State determines that the new project manager or key personnel is not acceptable, the Engineer may not use that person in that capacity and shall replace him or her with one satisfactory to the State within forty-five (45) days.
Amendment of Schedules Each party hereto agrees that, with respect to the representations and warranties of such party contained in this Agreement, such party shall have the continuing obligation until 24 hours prior to the anticipated effectiveness of the Registration Statement to supplement or amend promptly the Schedules hereto with respect to any matter hereafter arising or discovered which, if existing or known at the date of this Agreement, would have been required to be set forth or described in the Schedules, provided however, that supplements and amendments to Schedules 5.10, 5.11, 5.14 and 5.15 shall only have to be delivered at the Closing Date, unless such Schedule is to be amended to reflect an event occurring other than in the ordinary course of business. Notwithstanding the foregoing sentence, no amendment or supplement to a Schedule prepared by the Company that constitutes or reflects an event or occurrence that would have a Material Adverse Effect may be made unless TCI and a majority of the Founding Companies other than the Company consent to such amendment or supplement; and provided further, that no amendment or supplement to a Schedule prepared by TCI or Newco that constitutes or reflects an event or occurrence that would have a Material Adverse Effect may be made unless a majority of the Founding Companies consent to such amendment or supplement. For all purposes of this Agreement, including without limitation for purposes of determining whether the conditions set forth in Sections 8.1 and 9.1 have been fulfilled, the Schedules hereto shall be deemed to be the Schedules as amended or supplemented pursuant to this Section 7.8. In the event that one of the Other Founding Companies seeks to amend or supplement a Schedule pursuant to Section 7.8 of one of the Other Agreements, and such amendment or supplement constitutes or reflects an event or occurrence that would have a Material Adverse Effect on such Other Founding Company, TCI shall give the Company notice promptly after it has knowledge thereof. If TCI and a majority of the Founding Companies (other than the Founding Company seeking to amend or supplement a Schedule) consent to such amendment or supplement, which consent shall have been deemed given by TCI or any Founding Company if no response is received within 24 hours following receipt of notice of such amendment or supplement (or sooner if required by the circumstances under which such consent is requested), but the Company does not give its consent, the Company may terminate this Agreement pursuant to Section 12.1(iv) hereof. In the event that the Company seeks to amend or supplement a Schedule pursuant to this Section 7.8, and TCI and a majority of the Other Founding Companies do not consent to such amendment or supplement, this Agreement shall be deemed terminated by mutual consent as set forth in Section 12.1(i) hereof. In the event that TCI or Newco seeks to amend or supplement a Schedule pursuant to this Section 7.8 and a majority of the Founding Companies do not consent to such amendment or supplement, this Agreement shall be deemed terminated by mutual consent as set forth in Section 12.1(i) hereof. No party to this Agreement shall be liable to any other party if this Agreement shall be terminated pursuant to the provisions of this Section 7.8. No amendment of or supplement to a Schedule shall be made later than 24 hours prior to the anticipated effectiveness of the Registration Statement.
Attachment C_ CONTRACT AFFIRMATIONS For purposes of these Contract Affirmations, HHS includes both the Health and Human Services Commission (HHSC) and the Department of State Health Services (DSHS). System Agency refers to HHSC, DSHS, or both, that will be a party to this Contract. These Contract Affirmations apply to all Contractors and Grantees (referred to as “Contractor”) regardless of their business form (e.g., individual, partnership, corporation). By entering into this Contract, Contractor affirms, without exception, understands, and agrees to comply with the following items through the life of the Contract:
Please see the current Washtenaw Community College catalog for up-to-date program requirements Conditions & Requirements
Construction Progress Schedule A schedule indicating proposed activity sequences and durations, milestone dates for receipt and approval of pertinent information, preparation, submittal, and processing of Shop Drawings and Samples, delivery of materials or equipment requiring long-lead time procurement, and proposed date(s) of Material Completion and Occupancy and Final Completion. The schedule will be developed to represent the sixteen or seventeen CSI Specification Divisions. It shall have a minimum number of activities as required to adequately represent to Owner the complete scope of work and define the Project’s critical path and associated activities. If the Project is to be phased, then each individual Phase should be identified from start through completion of the overall Project and should be individually scheduled and described, including any Owner’s occupancy requirements and showing portions of the Project having occupancy priority. The format of the schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, Material Completion and Occupancy Date, final inspection dates, Punchlist, and Final Completion date.
Change Orders and Contract Amendments 33.1 The Procuring Entity may at any time order the Supplier through notice in accordance GCC Clause 8, to make changes within the general scope of the Contract in any one or more of the following:
a) drawings, designs, or specifications, where Goods to be furnished under the Contract are to be specifically manufactured for the Procuring Entity;
b) the method of shipment or packing;
c) the place of delivery; and
d) the Related Services to be provided by the Supplier.
33.2 If any such change causes an increase or decrease in the cost of, or the time required for, the Supplier's performance of any provisions under the Contract, an equitable adjustment shall be made in the Contract Price or in the Delivery/Completion Schedule, or both, and the Contract shall accordingly be amended. Any claims by the Supplier for adjustment under this Clause must be asserted within twenty-eight (28) days from the date of the Supplier's receipt of the Procuring Entity's change order.
33.3 Prices to be charged by the Supplier for any Related Services that might be needed but which were not included in the Contract shall be agreed upon in advance by the parties and shall not exceed the prevailing rates charged to other parties by the Supplier for similar services.
Execution of Change Orders Change Orders shall be signed by the Contractor, ordinarily certified by the Design Professional, and approved by the Owner in accordance with the form of Change Order prescribed by the Owner. No request for payment by the Contractor for a Change Order shall be due, nor shall any such request appear on an Application for Payment, until the Change Order is executed by the Owner. In the event of emergency (see Article
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Assignment Amendments Waiver and Contract Complete 032620-FDX
CONTRACTOR NAME CHANGE An amendment is required to change the Contractor's name as listed on this Agreement. Upon receipt of legal documentation of the name change the State will process the amendment. Payment of invoices presented with a new name cannot be paid prior to approval of said amendment.
