Extension of time for completion (i) Without prejudice to any other provision of this Agreement for and in respect of extension of time, the Contractor shall be entitled to extension of time in the Project Completion Schedule (the “Time Extension”) to the extent that completion of any Project Milestone is or will be delayed by any of the following, namely:
(a) delay in providing the Right of Way of Construction Zone, environmental clearances or approval of railway authorities, specified in Clause 3.1 (iv);
(b) Change of Scope (unless an adjustment to the Scheduled Completion Date has been agreed under Article 13);
(c) occurrence of a Force Majeure Event;
(d) any delay, impediment or prevention caused by or attributable to the Authority, the Authority's personnel or the Authority's other contractors on the Site; and
(e) any other cause or delay which entitles the Contractor to Time Extension in accordance with the provisions of this Agreement.
(ii) The Contractor shall, no later than 15 (fifteen) business days from the occurrence of an event or circumstance specified in Clause 10.5 (i), inform the Authority’s Engineer by notice in writing, with a copy to the Authority, stating in reasonable detail with supporting particulars, the event or circumstances giving rise to the claim for Time Extension in accordance with the provisions of this Agreement. Provided that the period of 15 (fifteen) business days shall be calculated from the date on which the Contractor became aware, or should have become aware, of the occurrence of such an event or circumstance. Provided further that notwithstanding anything to the contrary contained in this Agreement, Time Extension shall be due and applicable only for the Works which are affected by the aforesaid events or circumstances and shall not in any manner affect the Project Completion Schedule for and in respect of the Works which are not affected hereunder.
(iii) On the failure of the Contractor to issue to the Authority’s Engineer a notice in accordance with the provisions of Clause 10.5 (ii) within the time specified therein, the Contractor shall not be entitled to any Time Extension and shall forfeit its right for any such claims in future. For the avoidance of doubt, in the event of failure of the Contractor to issue notice as specified in this clause 10.5 (iii), the Authority shall be discharged from all liability in connection with the claim.
(iv) The Authority’s Engineer shall, on receipt of the claim in accordance with the provisions of Clause 10.5 (ii), examine the claim expeditiously within the time frame specified herein. In the event the Authority’s Engineer requires any clarifications to examine the claim, the Authority’s Engineer shall seek the same within 15 (fifteen) days from the date of receiving the claim. The Contractor shall, on receipt of the communication of the Authority’s Engineer requesting for clarification, furnish the same to the Authority’s Engineer within 10 (ten) days thereof. The Authority’s Engineer shall, within a period of 30 (thirty) days from the date of receipt of such clarifications, forward in writing to the Contractor its determination of Time Extension. Provided that when determining each extension of time under this Clause 10.5, the Authority’s Engineer shall review previous determinations and may increase, but shall not decrease, the total Time Extension.
(v) If the event or circumstance giving rise to the notice has a continuing effect:
(a) a fully detailed claim shall be considered as interim;
(b) the Contractor shall, no later than 10 (ten) days after the close of each month, send further interim claims specifying the accumulated delay, the extension of time claimed, and such further particulars as the Authority’s Engineer may reasonably require; and
(c) the Contractor shall send a final claim within 30 (thirty) days after the effect of the event or the circumstance ceases. Upon receipt of the claim hereunder, the Authority’s Engineer shall examine the same in accordance with the provisions of Clause 10.5 (iv) within a period of 30 (thirty) days of the receipt thereof
Order of Completion of Transactions The transactions provided for in Article II and Article III of this Agreement shall be completed immediately following the Effective Time in the following order: first, the transactions provided for in Article II shall be completed in the order set forth therein; and second, following the completion of the transactions provided for in Article II, the transactions provided for in Article III, if they occur, shall be completed.
Aggregation of Trades Subadviser, to the extent permitted by applicable laws and regulations, may, but shall be under no obligation to, aggregate the securities or other investments to be sold or purchased for the Fund as well as other clients of Subadviser in order to seek best execution. In such event, allocation of the securities or futures contracts so purchased or sold, as well as the expenses incurred in the transaction, will be made by Subadviser in the manner Subadviser considers to be the most equitable and consistent with its fiduciary obligations to the Fund and to such other clients.
Authorization of Transactions The Company is a corporation duly authorized and in good standing in the State of Florida and has the requisite power and capacity to execute and deliver the Transaction Documents to which it is a party and to perform its obligations hereunder and thereunder. The execution, delivery and performance by the Company of the applicable Transaction Documents and the consummation of the Transactions have been duly and validly authorized by all requisite action on the part of the Company. The Transaction Documents to which the Company is a party have been duly and validly executed and delivered by The Company. Each Transaction Document to which the Company is a party constitutes the valid and legally binding obligation of the Company, enforceable against the Company in accordance with its terms and conditions, except to the extent enforcement thereof may be limited by applicable bankruptcy, insolvency or other Laws affecting the enforcement of creditors’ rights or by the principles governing the availability of equitable remedies.
Extension of Time; Waiver At any time prior to the Effective Time, the parties may, by action taken or authorized by their respective Boards of Directors, to the extent permitted by applicable Law, (a) extend the time for the performance of any of the obligations or acts of the other parties, (b) waive any inaccuracies in the representations and warranties of the other parties set forth in this Agreement or any document delivered pursuant hereto or (c) subject to applicable Law, waive compliance with any of the agreements or conditions of the other parties contained herein; provided, however, that after the Company Stockholder Approval has been obtained, no waiver may be made that pursuant to applicable Law requires further approval or adoption by the Stockholders without such further approval or adoption. Any agreement on the part of a party to any such waiver shall be valid only if set forth in a written instrument executed and delivered by a duly authorized officer on behalf of such party. No failure or delay of any party in exercising any right or remedy hereunder shall operate as a waiver thereof, nor shall any single or partial exercise of any such right or power, or any abandonment or discontinuance of steps to enforce such right or power, or any course of conduct, preclude any other or further exercise thereof or the exercise of any other right or power. The rights and remedies of the parties hereunder are cumulative and are not exclusive of any rights or remedies which they would otherwise have hereunder.
Extension of Term If the term of NASPO ValuePoint Master Agreement is extended for any reason, the Term of this Participating Addendum shall be automatically modified to account for that extension, so long as such extension complies with the Colorado Procurement Code.
Execution of Transactions (a) In executing transactions for the Assets, selecting brokers or dealers and negotiating any brokerage commission rates, the Sub-Adviser will use its best efforts to seek best execution. In assessing best execution available for any portfolio transaction, the Sub-Adviser will consider all factors it deems relevant including, but not limited to, the breadth of the market in the security, the price of the security, the financial condition and execution capability of the broker or dealer and the reasonableness of any commission for the specific transaction and for transactions executed through the broker or dealer in the aggregate. In selecting brokers or dealers to execute a particular transaction and in evaluating the best overall terms available, to the extent that the execution and price offered by more than one broker or dealer are comparable the Sub-Adviser may consider any brokerage and research services (as those terms are defined in Section 28(e) of the Securities Exchange Act of 1934) provided to the Sub-Adviser or to CSAM for use on behalf of the Fund or other clients of the Sub-Adviser or CSAM.
(b) It is understood that the services of the Sub-Adviser are not exclusive, and nothing in this Agreement shall prevent the Sub-Adviser from providing similar services to other investment companies or from engaging in other activities, provided that those activities do not adversely affect the ability of the Sub-Adviser to perform its services under this Agreement. The Fund and CSAM further understand and acknowledge that the persons employed by the Sub-Adviser to assist in the performance of its duties under this Agreement will not devote their full time to that service. Nothing contained in this Agreement will be deemed to limit or restrict the right of the Sub-Adviser or any affiliate of the Sub-Adviser to engage in and devote time and attention to other businesses or to render services of whatever kind or nature, provided that doing so does not adversely affect the ability of the Sub-Adviser to perform its services under this Agreement.
(c) On occasions when the Sub-Adviser deems the purchase or sale of a security to be in the best interest of the Fund as well as of other investment advisory clients of the Sub-Adviser, the Sub-Adviser may, to the extent permitted by applicable laws and regulations, but shall not be obligated to, aggregate the securities to be so sold or purchased with those of its other clients. In such event, allocation of the securities so purchased or sold, as well as the expenses incurred in the transaction, will be made by the Sub-Adviser in a manner that is fair and equitable, in the judgment of the Sub-Adviser, in the exercise of its fiduciary obligations to the Fund and to such other clients. The Fund recognizes that the effect of the aggregation may operate on some occasions to the Fund's advantage or disadvantage. The Sub-Adviser shall provide to CSAM and the Fund all information reasonably requested by CSAM and the Fund relating to the decisions made by the Sub-Adviser regarding allocation of securities purchased or sold, as well as the expenses incurred in a transaction, among the Fund and the Sub-Adviser's other investment advisory clients.
(d) In connection with the purchase and sale of securities for the Fund, the Sub-Adviser will provide such information as may be reasonably necessary to enable the custodian and co-administrators to perform their administrative and recordkeeping responsibilities with respect to the Fund.
Authorization of Transaction The Buyer has full power and authority (including full corporate power and authority) to execute and deliver this Agreement and to perform its obligations hereunder. This Agreement constitutes the valid and legally binding obligation of the Buyer, enforceable in accordance with its terms and conditions. The Buyer need not give any notice to, make any filing with, or obtain any authorization, consent, or approval of any government or governmental agency in order to consummate the transactions contemplated by this Agreement.
Extension of Time, Waiver, Etc At any time prior to the Effective Time, any party may, subject to applicable Law, (a) waive any inaccuracies in the representations and warranties of any other party hereto, (b) extend the time for the performance of any of the obligations or acts of any other party hereto or (c) waive compliance by the other party with any of the agreements contained herein or, except as otherwise provided herein, waive any of such party’s conditions. Notwithstanding the foregoing, no failure or delay by the Company, Parent or Merger Sub in exercising any right hereunder shall operate as a waiver thereof nor shall any single or partial exercise thereof preclude any other or further exercise thereof or the exercise of any other right hereunder. Any agreement on the part of a party hereto to any such extension or waiver shall be valid only if set forth in an instrument in writing signed on behalf of such party.
Conditions of Transfer With respect to any Performance Share Units awarded to Employee, as a condition of Employee receiving a transfer of corresponding Common Shares in accordance with paragraph 4 above, Employee shall meet all of the following conditions during the entire period from the Grant Date hereof through the Distribution Date relating to such Performance Share Units:
(a) Employee must continue to be an active employee of the Company (“Continuous Employment”);
(b) Employee must refrain from Engaging in Competition (as defined in Section 2.25 of the Plan) without first having obtained the written consent thereto from the Company (“Non-competition”); and
(c) Employee must refrain from committing any criminal offense or malicious tort relating to or against the Company or, as determined by the Committee in its discretion, engaging in willful acts or omissions or acts or omissions of gross negligence that are or potentially are injurious to the Company’s operations, financial condition or business reputation. (“No Improper Conduct”). The Company’s determination as to whether or not particular conduct constitutes Improper Conduct shall be conclusive. If Employee should fail to meet the requirements relating to (i) Continuous Employment, (ii) Non-competition, or (iii) No Improper Conduct, then Employee shall forfeit the right to receive a distribution of any Performance Share Units for which the above conditions of transfer have not already been met as of the time such failure is determined, and Employee shall accordingly forfeit the right to receive the transfer of title to any corresponding Common Shares. The forfeiture of rights with respect to Performance Share Units (and corresponding Common Shares) shall not affect the rights of Employee with respect to any Performance Share Units for which the above conditions of transfer already have been met nor with respect to any Common Shares the title of which has already been transferred to Employee’s Account.
