Failure to Deliver Applicable
Waiver or Delay No failure to exercise or delay by a party in exercising any right, power, or remedy under this License Agreement operates as a waiver of such right, power, or remedy. A single or partial exercise of any right, power, or remedy does not preclude any other or further exercise of that or any other right, power, or remedy. A waiver is not valid or binding on the party granting the waiver unless made in writing.
PRODUCT DELIVERY Delivery must be made as ordered to the address specified on the Purchase Order and in accordance with the terms of the Contract or Contract Award Notice. Unless otherwise specified in the Bid Documents, delivery shall be made within thirty calendar days after receipt of a Purchase Order by the Contractor. The decision of the Commissioner as to compliance with delivery terms shall be final. The burden of proof for delay in receipt of Purchase Order shall rest with the Contractor. In all instances of a potential or actual delay in delivery, the Contractor shall immediately notify the Commissioner and the Authorized User, and confirm in writing the explanation of the delay, and take appropriate action to avoid any subsequent late deliveries. Any extension of time for delivery must be requested in writing by the Contractor and approved in writing by the Authorized User. Failure to meet such delivery time schedule may be grounds for cancellation of the order or, in the Commissioner’s discretion, the Contract.
Failure to Notify If Contractor fails to specify in writing any problem or circumstance that materially affects the costs of its delivery of services or products, including a material breach by the Department, about which Contractor knew or reasonably should have known with respect to the period during the term covered by Contractor's status report, Contractor shall not be entitled to rely upon such problem or circumstance as a purported justification for an increase in the price for the agreed upon scope.
Service Delivery Grantee shall:
Non Delivery C15.1 Where the Goods, having been placed in transit, fail to be delivered to the Authority on the due date for delivery, the Authority shall, (provided that the Authority has been advised in writing of the dispatch of the Goods), within ten (10) Working Days of the notified date of delivery, give notice to the Contractor that the Goods have not been delivered and may request the Contractor free of charge to deliver substitute Goods within the timescales specified by the Authority or terminate the Contract in accordance with clause C13.4 (Delivery).
Failure to Make Payment In the event a participating Authorized User fails to make payment to the Contractor for Products delivered, accepted and properly invoiced, within thirty calendar days of such delivery and acceptance, the Contractor may, upon five business days advance written notice to both the Commissioner and the Authorized User’s purchasing official, suspend additional shipments of Product or provision of services to such entity until such time as reasonable arrangements have been made and assurances given by such entity for current and future Contract payments.
PRICE/DELIVERY Price(s) bid must be the price(s) for new goods, unless otherwise specified. Any bids containing modifying or “escalator” clauses will not be considered unless specifically requested in the bid specifications.
Failure to Close (A) If Seller(s) fails to convey the property as provided in this contract: Buyer(s) may exercise legal remedies including suit for specific performances or damages. Agent may xxx Xxxxxx(s) to recover loss of commission. Agent may pay Xxxxxxx Money into a court of competent jurisdiction, or retain Xxxxxxx Money until directed to distribute the same by a court of competent jurisdiction.
Delay in Delivery The Seller must deliver the Products to the Company within the schedules as prescribed in the Order or as agreed in the Contract. If the Products are not delivered on the due date then, without prejudice to any other rights which it may have under the Terms and Conditions, the Company reserves the right to: cancel the Order in whole or in part; refuse to accept any subsequent delivery of the Products which the Seller attempts to make; recover from the Seller any expenditure reasonably incurred by the Company in obtaining the Products in substitution from another supplier; and claim damages for any additional costs, losses or expenses incurred by the Company which are in any way attributable to the Seller’s failure to deliver the Products on the due date.
