Minimum Purchase Requirements Distributor shall make the minimum annual purchase of Products established in Exhibit B, unless the Agreement has become coexclusive. In the period within the fixed term and extension, if applicable, of the Agreement under Section 10(a) subsequent to [ * ], the parties shall meet in San Francisco at least [ * ] prior to the beginning of each of respective year to discuss market conditions and appropriate minimum purchases for such year. In the event that the parties fail to agree on an appropriate minimum any year subsequent to [ * ], the minimum annual purchase requirement for such year shall be calculated increasing or decreasing (as the case may be) the minimum purchase requirement for the preceding year in proportion to the increase or decrease in the [ * ] (based on data from mutually acceptable data provider) of the applicable product in the Territory. In the event Supplier is unable to deliver Products ordered by Distributor in an amount consistent with the most recent forecast, then the minimum annual purchase requirement shall be reduced by the quantity of Products that Supplier is unable to deliver when requested. In the event Distributor fails in any year (a “Shortfall Year”) to make the annual minimum purchase of Agreement Products required by Exhibit B, Supplier shall have the right to give Distributor written notice of default, and if such failure to make the minimum purchase is not cured (through the purchase of an amount of Agreement Product equal to the entire shortfall in the Shortfall Year, which amount shall not be counted towards any minimum purchase requirements for the year of purchase) within [ * ] of receipt of the notice, then Supplier shall have the right, in Supplier’s sole discretion and as Supplier’s sole remedy for Distributor’s failure to meet the minimum purchase requirements hereunder, either to convert the appointment of Distributor from exclusive to non-exclusive or to terminate this Agreement. In the event of either conversion to non-exclusive or termination of this Agreement pursuant to this Section 3(e), the Supplier shall pay Distributor a conversion fee equal to [ * ], and Distributor shall transfer all Regulatory Approvals relating to BMS or DES in the Territory to Supplier.
Minimum Vendor License Requirements Vendor shall maintain, in current status, all federal, state, and local licenses, bonds and permits required for the operation of the business conducted by Vendor. Vendor shall remain fully informed of and in compliance with all ordinances and regulations pertaining to the lawful provision of goods or services under the TIPS Agreement. TIPS and TIPS Members reserve the right to stop work and/or cancel a TIPS Sale or terminate this or any TIPS Sale Supplemental Agreement involving Vendor if Vendor’s license(s) required to perform under this Agreement or under the specific TIPS Sale have expired, lapsed, are suspended or terminated subject to a 30‐day cure period unless prohibited by applicable statue or regulation.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Purchase Order Requirements Customers shall use a Request for Quote per section 287.056(2), Florida Statutes, when making purchases off of this State Term Contract. Customers shall issue Request for Quotes to at least 25 vendors approved to provide IT Staff Augmentation services in accordance with section 287.0591(5), Florida Statutes. Customers shall order services from the Request for Quote via a Purchase Order with the Customers’ selected Contractor. The terms of the Purchase Order shall not conflict with the terms and conditions established by this Contract. In accepting a Purchase Order, the Contractor recognizes its responsibility for all tasks and deliverables contained therein, warrants that it has fully informed itself of all relevant factors affecting accomplishment of the tasks and deliverables and agrees to be fully accountable for the performance thereof.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Funding Restrictions and Order Quantities The Agency reserves the right to reduce or increase estimated or actual quantities in whatever amount necessary without prejudice or liability to the Agency, if:
12.3.1 Funding is not available;
12.3.2 Legal restrictions are placed upon the expenditure of monies for this category of service or supplies; or,
12.3.3 The Agency’s requirements in good faith change after award of the contract.
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Minimum Condition and Warranty Requirements for TIPS Sales All goods quoted or sold through a TIPS Sale shall be new unless clearly stated otherwise in writing. All new goods and services shall include the applicable manufacturers minimum standard warranty unless otherwise agreed to in the Supplemental Agreement.
Contract Quantity The Contract Quantity during each Contract Year is the amount set forth in the applicable Contract Year in Section D of the Cover Sheet (“Delivery Term Contract Quantity Schedule”), which amount is inclusive of outages.
License Requirements The Hotel’s alcoholic beverage license requires that the Hotel shall: (i) request proper identification (photo ID) of any person of questionable age and refuse alcoholic beverage service if the person is either under age or proper identification cannot be produced, and (ii) refuse alcoholic beverage service to any person who, in the Hotel’s judgment, appears to be intoxicated; and (iii) instruct its personnel to avoid encouraging patrons to consume alcoholic beverages (commonly referred to as “over-pouring”).
