Power and Authority; Due Authorization; Execution and Delivery The execution and delivery by such Seller Party of this Agreement and each other Transaction Document to which it is a party, and the performance of its obligations hereunder and thereunder and, in the case of Seller, Seller’s use of the proceeds of Purchases made hereunder, are within its powers and authority, corporate or otherwise, and have been duly authorized by all necessary action, corporate or otherwise, on its part. This Agreement and each other Transaction Document to which such Seller Party is a party has been duly executed and delivered by such Seller Party.
Obligations of the Authority (i) The Authority shall, at its own cost and expense, undertake, comply with and perform all its obligations set out in this Agreement or arising hereunder.
(ii) The Authority shall be responsible for the correctness of the Scope of the Project, Project Facilities, Specifications and Standards and the criteria for testing of the completed Works.
(iii) The Authority shall, upon submission of the Performance Security as per the RFP by the Contractor, shall provide to the Contractor:
(a) No less than 90% (ninety per cent) of the required Right of Way of the Construction Zone of total length of the Project Highway within a period of 30 (thirty) days from the date of this Agreement, which shall be in contiguous stretches of length not less than 1( One) kilometre.
(b) approval of the general arrangement drawings (the “GAD”) from railway authorities to enable the Contractor to construct road over- bridges/ under- bridges at level crossings on the Project Highway in accordance with the Specifications and Standards, and subject to the terms and conditions specified in such approval, within a period of 60 (sixty) days from the Appointed Date, and reimbursement of all the costs and expenses paid by the Contractor to the railway authorities for and in respect of the road over- bridges/ under bridges; and7
(c) all environmental clearances as required under Clause 4.3.8
(iv) Delay in providing the Right of Way or approval of GAD by railway authorities, as the case may be, in accordance with the provisions of Clause 3.1 (iii) shall entitle the Contractor to Damages in a sum calculated in accordance with the provisions of Clause 8.3 of this Agreement and Time Extension in accordance with the provisions of Clause 10.5 of this Agreement. For the avoidance of doubt, the Parties agree that the Damages for delay in approval of GAD by the railway authorities for a particular road over-bridge/ under-bridge shall be deemed to be equal to the Damages payable under the provisions of Clause 8.3 for delay in providing Right of Way for a length of 2 (two) kilometre for each such road over-bridge/ under-bridge.
The Authority As to the Authority, the following section shall survive discharge: Section 2.3 (right to conduct audit).
Power of the Authority to undertake works (i) In the event the Parties are unable to agree to the proposed Change of Scope Orders in accordance with Clause 13.2, the Authority may, after giving notice to the Contractor and considering its reply thereto, award such Works or services to any person or agency on the basis of open competitive bidding. It is also agreed that the Contractor shall provide assistance and cooperation to the person or agency who undertakes the works or services hereunder. The Contractor shall not be responsible for rectification of any Defects, but the Contractor shall carry out maintenance of such works after completion of Defect Liability Period of work by other person or agency during the remaining period of this agreement without any extra payment.
(ii) The Works undertaken in accordance with this Clause 13.5 shall conform to the Specifications and Standards and shall be carried out in a manner that minimises the disruption in operation of the Project Highway. The provisions of this Agreement, insofar as they relate to Works and Tests, shall apply mutatis mutandis to the Works carried out under this Clause 13.5.
Power and Authority; Due Authorization The Servicer has all necessary power and authority to (i) execute and deliver this Agreement and the other Transaction Documents to which it is a party and (ii) perform its obligations under this Agreement and the other Transaction Documents to which it is a party and the execution, delivery and performance of, and the consummation of the transactions provided for in, this Agreement and the other Transaction Documents to which it is a party have been duly authorized by the Servicer by all necessary action.
Further Assurances; Power of Attorney During and after his employment, the Executive agrees to reasonably cooperate with the Company to (a) apply for, obtain, perfect, and transfer to the Company the Work Product as well as any and all Intellectual Property Rights in the Work Product in any jurisdiction in the world; and (b) maintain, protect and enforce the same, including, without limitation, giving testimony and executing and delivering to the Company any and all applications, oaths, declarations, affidavits, waivers, assignments, and other documents and instruments as shall be requested by the Company. The Executive hereby irrevocably grants the Company power of attorney to execute and deliver any such documents on the Executive’s behalf in his name and to do all other lawfully permitted acts to transfer the Work Product to the Company and further the transfer, prosecution, issuance, and maintenance of all Intellectual Property Rights therein, to the full extent permitted by law, if the Executive does not promptly cooperate with the Company’s request (without limiting the rights the Company shall have in such circumstances by operation of law). The power of attorney is coupled with an interest and shall not be affected by the Executive’s subsequent incapacity.
Corporate Authority If Tenant is a corporation, each individual executing this Lease on behalf of said corporation represents and warrants that he is duly authorized to execute and deliver this Lease on behalf of said corporation, in accordance with a duly adopted resolution of the board of directors of said corporation or in accordance with the by-laws of said corporation, and that this Lease is binding upon said corporation in accordance with its terms.
Corporate Authorization; Validity of Agreement; Necessary Action Each of Parent and Merger Sub has all necessary corporate power and authority to execute and deliver this Agreement, to perform its obligations hereunder and to consummate the transactions contemplated hereby. The execution, delivery and performance by each of Parent and Merger Sub of this Agreement and the consummation by them of the transactions contemplated hereby have been duly and validly authorized by all necessary corporate action and no other corporate proceedings on the part of the Parent or Merger Sub are necessary to authorize the execution and delivery by them of this Agreement and the consummation by them of the transactions contemplated hereby. This Agreement has been duly and validly executed and delivered by Parent and Merger Sub, and constitutes the legal, valid and binding obligation of Parent and Merger, enforceable against each of them in accordance with its terms, except that (i) such enforcement may be subject to applicable bankruptcy, insolvency, reorganization, moratorium or other similar laws, now or hereafter in effect, affecting creditors' rights generally and (ii) the remedy of specific performance and injunctive and other forms of equitable relief may be subject to equitable defenses and to the discretion of the court before which any proceeding may be brought.
Representations and Warranties of the Authority The Authority represents and warrants to the Contractor that:
(a) it has full power and authority to execute, deliver and perform its obligations under this Agreement and to carry out the transactions contemplated herein and that it has taken all actions necessary to execute this Agreement, exercise its rights and perform its obligations, under this Agreement;
(b) it has taken all necessary actions under the Applicable Laws to authorise the execution, delivery and performance of this Agreement;
(c) it has the financial standing and capacity to perform its obligations under this Agreement;
(d) this Agreement constitutes a legal, valid and binding obligation enforceable against it in accordance with the terms hereof;
(e) it has no knowledge of any violation or default with respect to any order, writ, injunction or any decree of any court or any legally binding order of any Government Instrumentality which may result in any material adverse effect on the Authority’s ability to perform its obligations under this Agreement;
(f) it has complied with Applicable Laws in all material respects;
(g) it has good and valid right to the Site and has the power and authority to grant the Right of Way in respect thereof to the Contractor; and
(h) it has procured Right of Way and environment clearances such that the Contractor can commence construction forthwith on 90% (ninety per cent) of the total length of the Project Highway.
Power and Authority; Authorization; Execution and Delivery; Binding Obligation The Purchaser has the power and authority to execute, deliver and perform its obligations under this Agreement. This Agreement has been duly authorized, executed and delivered by the Purchaser and constitutes the legal, valid and binding obligation of the Purchaser, enforceable against the Purchaser in accordance with its terms, except as such enforceability may be limited by insolvency, bankruptcy, reorganization or other laws relating to or affecting the enforcement of creditors’ rights and by general equitable principles.
