Improvement Completion Agreement Sample Clauses

Improvement Completion Agreement a. DEVELOPER agrees to establish with the SBWRD a properly executed Improvement Completion Agreement (I.C. Agreement) to ensure and guarantee the completion of the extension or modification of the Public Wastewater System, warranty of the work as required by this Agreement and payment to the SBWRD of all amounts due including but not limited to construction costs, engineering fees, inspection fees, administrative fees, and legal fees and costs which may be experienced by the SBWRD under the terms of this Agreement. b. DEVELOPER shall establish the I. C. Agreement prior to the earliest occurrence of one of the following: 1) Final Design Approval.
Sample 1
AutoNDA by SimpleDocs
Improvement Completion Agreement a. DEVELOPER agrees to establish with SBWRD a properly executed Improvement Completion Agreement (I.C. Agreement) to ensure and guarantee the completion of the extension or modification of the Public Wastewater System, warranty of the work as required by this Agreement and payment to SBWRD of all amounts due including but not limited to construction costs, engineering fees, inspection fees, administrative fees, and legal fees and costs which may be experienced by SBWRD under the terms of this Agreement. b. DEVELOPER shall establish the I. C. Agreement prior to the earliest occurrence of one of the following: 1) Final Project Approval by SBWRD. 2) Substantial Completion Approval by SBWRD 3) Plat Approval or Site Plan Approval by SBWRD if DEVELOPER requests approval of the PROJECT dedication plat or site plan prior to the receipt of Final Project Approval and an extension or modification of the Public Wastewater System is required to provide wastewater service to the PROJECT. 4) Acceptance by SBWRD of Impact Fees for any building or facility located in the PROJECT if DEVELOPER or another builder requests a Building Permit from Park City Municipal Corporation or Summit County prior to the receipt of Final Project Approval. 5) Final Design Approval if the extension or modification to the Public Wastewater System covered by this Agreement will impact the ability of SBWRD to provide wastewater service to existing system users, as determined by SBWRD in its sole discretion. c. The initial I. C. Agreement amount shall be established based on the estimated construction cost of the extensions or modifications of the Public Wastewater System required for the PROJECT. The estimated construction cost shall be determined prior to Final Design Approval by SBWRD after reviewing an estimate of construction costs prepared by the DEVELOPER’s Project Engineer. d. The amount of the I. C. Agreement shall be 100 percent (100%) of the estimated construction cost as determined by SBWRD. If the I.C. Agreement is established after construction of the extensions or modification of the Public Wastewater System has begun, the amount of the I.C. Agreement established at that time will be based on the percent of work completed as defined in the I.C. Agreement. However, the release of funds from the I.C. Agreement will be based on the full I.C. Agreement Amount (100% of the total estimated construction cost). e. Release of funds from the I. C. Agreement to DEVELOPER shall be made in accor...
Sample 1

Related to Improvement Completion Agreement

  • Agreement Complete This Agreement contains all negotiations and agreements between the BCA and the Governmental Unit. No other understanding regarding this Agreement, whether written or oral, may be used to bind either party.

  • Project Completion The Contractor agrees to schedule a final job walk with the County. If required, the County will prepare a list of incomplete items, the “Punch List”. The Contractor agrees to complete the “Punch List” corrections and schedule a final project completion job walk. The County will sign the “Punch List” as completed when determined, the project is finished. The Contractor agrees to submit the following along with its final payment request:

  • Tenant Improvement Plans Any work proposed by Tenant (the “Tenant Improvements”) shall be subject to Landlord’s reasonable prior approval and shall be subject to the other terms and conditions of this Exhibit C; provided that it will be reasonable for Landlord to withhold its approval or consent (as and when applicable under this Exhibit C) if Landlord’s Mortgagee has not consented to the matter that is the subject of such approval or consent. All architectural, engineering and other design fees shall be paid by Tenant. Tenant shall use its architect, engineers and other design professionals, all of whom shall comply with any applicable licensing or governmental requirements of the City of Seattle and the State of Washington; Tenant’s architect shall be approved by Landlord (“Tenant’s Architect”), which approval shall not be unreasonably withheld, conditioned or delayed. Landlord shall also be entitled to receive a copy of the agreement between Tenant and Tenant’s Architect (the “Architect Agreement”). Tenant shall cause Tenant’s Architect to prepare a draft space plan (the “Space Plan”) for the Tenant Improvements and shall submit the proposed Space Plan to Landlord for the latter’s approval (not to be unreasonably withheld) in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Space Plan within ten (10) business days of receipt; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Space Plan to be revised to address such written comments and shall resubmit said Space Plan to Landlord for approval. Such process shall continue until Landlord has approved the Space Plan. Tenant’s Architect shall then prepare working drawings and specifications for the Tenant Improvements, including architectural, structural, plumbing, mechanical, electrical, and fire protection drawings as required, suitable for permit application (the “Working Drawings”) and shall submit the proposed Working Drawings to Landlord for the latter’s approval in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. The Space Plan and Working Drawings shall be subject to Landlord’s approval, which Landlord agrees shall not be unreasonably withheld, conditioned, or delayed. Landlord shall not be deemed to have acted unreasonably if it withholds its approval thereof because, in Landlord’s reasonable opinion, the work, as described in any such item: (i) is likely to adversely affect Building Systems, the structure of the Building or the safety of the Building and/or their occupants; (ii) might impair Landlord’s ability to furnish services to Tenant or other tenants in the Building; (iii) would materially increase the cost of operating the Building; (iv) would violate any governmental laws, rules or ordinances (or interpretations thereof); (v) contains or uses hazardous or toxic materials or substances; (vi) would negatively affect the appearance of the Building; (vii) is reasonably likely to adversely affect another tenant’s premises; or (viii) is prohibited by any ground lease affecting the Building or any mortgage, trust deed or other instrument encumbering the Building. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Working Drawings, within ten (10) business days of Landlord’s receipt of the Working Drawings; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Working Drawings to be revised to address such written comments and shall resubmit said Working Drawings to Landlord for approval. Landlord may, when approving the Tenant Improvement Plans, elect to require Tenant to remove any Non-Standard Improvements which are made to the Premises. If Landlord so elects, Tenant shall, at its own cost, restore the Premises to the condition designated by Landlord in its election, before the last day of the Term. Such process shall continue until both parties have approved the Working Drawings. Landlord’s approval of the Space Plan and/or the Working Drawings shall not be deemed any representation or warranty that the same comply with applicable codes.

  • Construction Completion The related Construction shall have been completed substantially in accordance with the related Plans and Specifications, the related Deed and all Applicable Laws, and such Leased Property shall be ready for occupancy and operation. All fixtures, equipment and other property contemplated under the Plans and Specifications to be incorporated into or installed in such Leased Property shall have been substantially incorporated or installed, free and clear of all Liens except for Permitted Liens.

  • Project Completion Date It is agreed between the Parties that the Project Completion Date is <END DATE, YEAR>. If the Project is not completed by such date then, subject to an amendment agreed to between the Parties, Alberta Innovates may elect to terminate this Investment Agreement. In such event, Alberta Innovates will notify the Applicant of its decision to terminate as soon as reasonably practical and shall advise the Applicant of the effective date of termination. Alberta Innovates will have no liability or obligation to reimburse the Applicant for any Project Costs incurred after the effective date of termination and may require the Applicant to return any portions of the Investment which were spent on Ineligible Expenses. Additionally, any portion of the Investment not used and accounted for in accordance with this Agreement as of the Project Completion Date or earlier termination is repayable by the Applicant to AI at AI’s request.

  • Development Agreement As soon as reasonably practicable following the ISO’s selection of a transmission Generator Deactivation Solution, the ISO shall tender to the Developer that proposed the selected transmission Generator Deactivation Solution a draft Development Agreement, with draft appendices completed by the ISO to the extent practicable, for review and completion by the Developer. The draft Development Agreement shall be in the form of the ISO’s Commission-approved Development Agreement for its reliability planning process, which is in Appendix C in Section 31.7 of Attachment Y of the ISO OATT, as amended by the ISO to reflect the Generator Deactivation Process. The ISO and the Developer shall finalize the Development Agreement and appendices as soon as reasonably practicable after the ISO’s tendering of the draft Development Agreement. For purposes of finalizing the Development Agreement, the ISO and Developer shall develop the description and dates for the milestones necessary to develop and construct the selected project by the required in-service date identified in the Generator Deactivation Assessment, including the milestones for obtaining all necessary authorizations. Any milestone that requires action by a Connecting Transmission Owner or Affected System Operator identified pursuant to Attachment P of the ISO OATT to complete must be included as an Advisory Milestone, as that term is defined in the Development Agreement. If the ISO or the Developer determines that negotiations are at an impasse, the ISO may file the Development Agreement in unexecuted form with the Commission on its own, or following the Developer’s request in writing that the agreement be filed unexecuted. If the Development Agreement is executed by both parties, the ISO shall file the agreement with the Commission for its acceptance within ten (10) Business Days after the execution of the Development Agreement by both parties. If the Developer requests that the Development Agreement be filed unexecuted, the ISO shall file the agreement at the Commission within ten (10) Business Days of receipt of the request from the Developer. The ISO will draft, to the extent practicable, the portions of the Development Agreement and appendices that are in dispute and will provide an explanation to the Commission of any matters as to which the parties disagree. The Developer will provide in a separate filing any comments that it has on the unexecuted agreement, including any alternative positions it may have with respect to the disputed provisions. Upon the ISO’s and the Developer’s execution of the Development Agreement or the ISO’s filing of an unexecuted Development Agreement with the Commission, the ISO and the Developer shall perform their respective obligations in accordance with the terms of the Development Agreement that are not in dispute, subject to modification by the Commission. The Connecting Transmission Owner(s) and Affected System Operator(s) that are identified in Attachment P of the ISO OATT in connection with the selected transmission Generator Deactivation Solution shall act in good faith in timely performing their obligations that are required for the Developer to satisfy its obligations under the Development Agreement.

  • Project Completion Report At the completion of construction and once a Project is placed in service, the Subrecipient must submit a Project Completion Report that includes the total number of units built and leased, affordable units built and leased, DR-MHP units built and leased, an accomplishment narrative, and the tenants names, demographics and income for each DR-MHP unit.

  • Notice to Proceed - Site Improvements The Recipient shall not commence, or cause to be commenced, any site improvements or other work on the Land until the Director has issued a Notice to Proceed to the Recipient. Such Notice to Proceed will not be issued until the Director is assured that the Recipient has complied with all requirements for the approval of a grant under Revised Code Sections 164.20 through 164.27 and has completed any land acquisition required by the Project. A Notice to Proceed shall be required for all Project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.

  • Project Agreement 1.1 If applicable, the Department will recommend approval of the project by the Federal Highway Administration. 1.2 The Sponsor agrees to comply with Title VI of the Civil Rights Act of 1964, 78 Stat. § 252, 42 U.S.C. § 2000d et seq., and all requirements imposed by or pursuant to Title 49, Code of Federal Regulations, Part 21 - “Nondiscrimination in federally assisted programs of the Department of Transportation - effectuation of Title VI of the Civil Rights Act 1964". 1.3 The DEPARTMENT and SPONSOR mutually recognize that each party is a governmental entity subject to the provisions of the Governmental Tort Claims Act (51 O.S. § 151 et seq.). The DEPARTMENT and SPONSOR hereby mutually agree that each is and may be held severally liable for any and all claims, demands, and suits in law or equity, of any nature whatsoever, paying for damages or otherwise, arising from any negligent act or omission of any of their respective employees, agents or contractors which may occur during the prosecution or performance of this Agreement to the extent provided in the Governmental Tort Claims Act. Each party agrees to severally bear all costs of investigation and defense of claims arising under the Governmental Tort Claims Act and any judgments which may be rendered in such cause to the limits provided by law. Nothing in this section shall be interpreted or construed to waive any legal defense which may be available to a party or any exemption, limitation or exception which may be provided by the Governmental Tort Claims Act. 1.4 The Sponsor understands that should it fail to fulfill its responsibilities under this Agreement, such a failure will disqualify the Sponsor from future Federal-aid funding participation on any proposed project. Federal-aid funds are to be withheld until such a time as an engineering staff, satisfactory to the Department has been properly established and functioning, the deficiencies in regulations have been corrected or the improvements to be constructed under this Agreement are brought to a satisfactory condition of maintenance.

  • COMMENCEMENT AND COMPLETION OF THE PROJECT Section 3.01 The Project (a) The Company intends and expects, together with any Sponsor Affiliate, to (i) construct and acquire the Project, and (ii) meet the Contract Minimum Investment Requirement within the Investment Period. The Company anticipates that the first Phase of the Project will be placed in service during the calendar year ending December 31, 2020. (b) Pursuant to the FILOT Act and subject to Section 4.03 hereof, the Company and the County hereby agree that the Company and any Sponsor Affiliates shall identify annually those assets which are eligible for FILOT payments under the FILOT Act and which the Company or any Sponsor Affiliate selects for such treatment by listing such assets in its annual PT-300S form (or comparable form) to be filed with the Department (as such may be amended from time to time) and that by listing such assets, such assets shall automatically become Economic Development Property and therefore be exempt from all ad valorem taxation during the Exemption Period. Anything contained in this Fee Agreement to the contrary notwithstanding, the Company and any Sponsor Affiliates shall not be obligated to complete the acquisition of the Project. However, if the Company, together with any Sponsor Affiliates, does not meet the Contract Minimum Investment Requirement within the Investment Period, the provisions of Section 4.03 hereof shall control. (c) The Company may add to the Land such real property, located in the same taxing District in the County as the original Land, as the Company, in its discretion, deems useful or desirable. In such event, the Company, at its expense, shall deliver an appropriately revised Exhibit A to this Fee Agreement, in form reasonably acceptable to the County.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!