Indemnity Limitation for TIPS Sales Texas and other jurisdictions restrict the ability of governmental entities to indemnify others. Vendor agrees that if any "Indemnity" provision which requires the TIPS Member to indemnify Vendor is included in any TIPS sales agreement/contract between Vendor and a TIPS Member, that clause must either be stricken or qualified by including that such indemnity is only permitted, "to the extent permitted by the laws and constitution of [TIPS Member's State]” unless the TIPS Member expressly agrees otherwise. Any TIPS Sale Supplemental Agreement containing an "Indemnity" clause that conflicts with these terms is rendered void and unenforceable.
Availability of Earnings Statements The Company shall make generally available to holders of its securities as soon as may be practicable but in no event later than the last day of the fifteenth (15th) full calendar month following the calendar quarter in which the most recent effective date occurs in accordance with Rule 158 of the Rules and Regulations, an earnings statement (which need not be audited but shall be in reasonable detail) for a period of twelve (12) months ended commencing after the effective date, and satisfying the provisions of Section 11(a) of the Act (including Rule 158 of the Rules and Regulations).
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
SCHEDULE FOR PERFORMANCE REVIEWS 7.1 The performance of the Employee in relation to his performance agreement shall be reviewed for the following quarters with the understanding that the reviews in the first and the third quarter may be verbal if performance is satisfactory:
EPP service availability Refers to the ability of the TLD EPP servers as a group, to respond to commands from the Registry accredited Registrars, who already have credentials to the servers. The response shall include appropriate data from the Registry System. An EPP command with “EPP command RTT” 5 times higher than the corresponding SLR will be considered as unanswered. If 51% or more of the EPP testing probes see the EPP service as unavailable during a given time, the EPP service will be considered unavailable.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Employee Performance Review When a formal review of an employee’s performance is made, the employee concerned shall be given an opportunity to discuss, sign and make written comments on the review form in question and the employee is to receive a signed copy to indicate that its contents have been read. An employee shall be entitled to a minimum of two (2) work days to review the performance review prior to providing any response to the Employer, verbally or in writing, with respect to the evaluation.
Quarterly Contractor Performance Reporting Customers shall complete a Contractor Performance Survey (Exhibit I) for each Contractor on a Quarterly basis. Customers will electronically submit the completed Contractor Performance Survey(s) to the Department Contract Manager no later than the due date indicated in Contract Exhibit D, Section 17, Additional Special Contract Conditions. The completed Contractor Performance Survey(s) will be used by the Department as a performance-reporting tool to measure the performance of Contractors. The Department reserves the right to modify the Contractor Performance Survey document and introduce additional performance-reporting tools as they are developed, including online tools (e.g. tools within MyFloridaMarketPlace or on the Department's website).
Please see the current Washtenaw Community College catalog for up-to-date program requirements Conditions & Requirements
