Licensed Technology (a) LICENSOR is not aware of any interference, infringement, misappropriation, or other conflict with any intellectual property rights of third parties, and LICENSOR has never received any charge, complaint, claim, demand, or notice alleging any such interference, infringement, misappropriation, or violation (including any claim that LICENSOR must license or refrain from using any intellectual property rights of any third party). To the knowledge of LICENSOR, no third party has interfered with, infringed upon, misappropriated, or otherwise come into conflict with any of the LICENSED TECHNOLOGY.
(b) Exhibit A identifies each patent or registration which has been issued to LICENSOR with respect to any of the LICENSED TECHNOLOGY and identifies each pending patent application or application for registration which LICENSOR has made with respect to any of the LICENSED TECHNOLOGY. LICENSEE acknowledges that LICENSOR has previously made available to LICENSEE correct and complete copies of all such patents, registrations and applications (as amended to-date) in LICENSOR’s possession and has made available to LICENSEE correct and complete copies of all other written documentation in LICENSOR’s possession evidencing ownership and prosecution (if applicable) of each such item.
(c) Exhibit A identifies each item of LICENSED TECHNOLOGY that is assigned to LICENSOR or that LICENSOR uses pursuant to license, sublicense, agreement, or permission. LICENSOR has made available to LICENSEE correct and complete copies of all such licenses, sublicenses, agreements, patent prosecution files and permissions (as amended to-date) in LICENSOR’s possession. With respect to each item of LICENSED TECHNOLOGY required to be identified in Exhibit A and to the knowledge of LICENSOR: (i) the license, sublicense, agreement, or permission covering the item is legal, valid, binding, enforceable, and in full force and effect; (ii) the license, sublicense, agreement, or permission will continue to be legal, valid, binding, enforceable, and in full force and effect on identical terms following the consummation of the transactions contemplated hereby; (iii) no Party to the license, sublicense, agreement, or permission is in breach or default, and no event has occurred which with notice or lapse of time would constitute a breach or default or permit termination, modification, or acceleration thereunder; (iv) no party to the license, sublicense, agreement, or permission has repudiated any provision thereof; (v) the underlying item of LICENSED TECHNOLOGY is not subject to any outstanding lien or encumbrance, injunction, judgment, order, decree, ruling, or charge; (vi) no action, suit, proceeding, hearing, investigation, charge, complaint, claim, or demand is pending or is threatened which challenges the legality, validity, or enforceability of the underlying item of LICENSED TECHNOLOGY; and (vii) except as provided in Exhibit A, LICENSOR has not granted any license or similar right to the LICENSED TECHNOLOGY within the GENERAL FIELD or PARTHENOGENESIS FIELD.
Licensed Materials The materials that are the subject of this Agreement are set forth in Appendix A ("Licensed Materials").
SHOP DRAWINGS, PRODUCT DATA AND SAMPLES 4.12.1 Shop Drawings are drawings, diagrams, schedules and other, data specially prepared for the Work by the Contractor or any Subcontractor, manufacturer, supplier or distributor to illustrate some portion of the Work.
4.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams and other information furnished by the Contractor to illustrate a material, product or system for some portion of the Work.
4.12.3 Samples are physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged.
4.12.4 The Contractor shall review, approve and submit, with reasonable promptness and in such sequence as to cause no delay in the Work or in the work of the State or any separate contractor, all Shop Drawings, Product Data and Samples required by the Contract Documents.
4.12.5 By approving and submitting Shop Drawings, Product Data and Samples, the Contractor represents that he / she has determined and verified all materials, field measurements, and field construction criteria related thereto, or will do so, and that he / she has checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents.
4.12.6 The Contractor shall not be relieved of responsibility for any deviation from the requirements of the Contract Documents by the Architect's approval of Shop Drawings, Product Data or Samples under Subparagraph 2.2.7 of these General Conditions unless the Contractor has specifically informed the Architect and the State in writing of such deviation at the time of sub- mission and the Architect and the State has given written approval to the specific deviation. The Contractor shall not be relieved from responsibility for errors or omissions in the Shop Drawings, Product Data or Samples by the Architect's approval thereof.
4.12.7 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data or Samples, to revisions other than those requested by the Architect on previous submittals.
4.12.8 No portion of the Work requiring submission of a Shop Drawing, Product Data or Sample shall be commenced until the submittal has been approved by the Architect as provided in Subparagraph 2.2.7 of these General Conditions. All such portions of the Work shall be in accordance with approved submittals.
Licensed Products Lessee will obtain no title to Licensed Products which will at all times remain the property of the owner of the Licensed Products. A license from the owner may be required and it is Lessee's responsibility to obtain any required license before the use of the Licensed Products. Lessee agrees to treat the Licensed Products as confidential information of the owner, to observe all copyright restrictions, and not to reproduce or sell the Licensed Products.
Licensed Product The term “Licensed Product” shall mean any product (a) the manufacture, use, importation, sale or offer for sale of which would, in the absence of the license granted by this Agreement, infringe a Valid Claim of any of the Licensed Patent Rights, or (b) that is comprised of, utilizes or incorporates Licensed Biological Materials, or (c) that is discovered, developed or made using a Licensed Process.
Licensed Software Computer program(s) provided by Contractor in connection with the Deliverables, subject to Section 14 of this Contract.
Patent Rights The State and the U. S. Department of Transportation shall have the royalty free, nonexclusive and irrevocable right to use and to authorize others to use any patents developed by the Engineer under this contract.
SOURCE CODE ESCROW FOR LICENSED PRODUCT If Source Code or Source Code escrow is offered by either Contractor or Product manufacturer or developer to any other commercial customers, Contractor shall either: (i) provide Licensee with the Source Code for the Product; or (ii) place the Source Code in a third party escrow arrangement with a designated escrow agent who shall be named and identified to the State, and who shall be directed to release the deposited Source Code in accordance with a standard escrow agreement acceptable to the State; or (iii) will certify to the State that the Product manufacturer/developer has named the State, acting by and through the Authorized User, and the Licensee, as a named beneficiary of an established escrow arrangement with its designated escrow agent who shall be named and identified to the State and Licensee, and who shall be directed to release the deposited Source Code in accordance with the terms of escrow. Source Code, as well as any corrections or enhancements to such source code, shall be updated for each new release of the Product in the same manner as provided above and such updating of escrow shall be certified to the State in writing. Contractor shall identify the escrow agent upon commencement of the Contract term and shall certify annually that the escrow remains in effect in compliance with the terms of this clause. The State may release the Source Code to Licensees under this Contract who have licensed Product or obtained services, who may use such copy of the Source Code to maintain the Product.
Licensed Patent Rights The Licensee shall indemnify and hold the IC, its employees, students, fellows, agents, and consultants harmless from and against all liability, demands, damages, expenses, and losses, including but not limited to death, personal injury, illness, or property damage in connection with or arising out of:
Licensed Patents Immune Design, at its expense, shall have the first right to file, prosecute and maintain all Licensed Patents for which Immune Design has any exclusive rights under this Agreement using patent counsel reasonably approved by IDRI, including conducting any interferences, reexaminations, reissues, oppositions, or request for patent term extension relating thereto. Immune Design shall conduct such filing, prosecution and maintenance in good faith, taking into consideration IDRI’s retained rights hereunder, and consistent with reasonable business judgment, provide IDRI with all relevant or material documentation and proposed filing in the Territory so that IDRI may be concurrently and promptly informed of the continuing prosecution, and consult with IDRI with regards to Immune Design’s patent strategy with the Licensed Patents for which Immune Design has any exclusive rights under this Agreement. Licensed Patents in the name of IDRI shall remain in the name of IDRI. Immune Design shall use commercially reasonable efforts to ***, as applicable. To the extent such ***, Immune Design shall provide IDRI reasonable opportunity to review and comment on such prosecution efforts regarding such Licensed Patents in the Territory, and any IDRI comments will be reasonably considered in such prosecution efforts, and included to the extent affecting the IDRI Exclusive Field or IDRI Territory, as the case may be. If Immune Design determines in its sole discretion to abandon or not maintain any Licensed Patent for which Immune Design has any exclusive rights under this Agreement in the Territory, then Immune Design shall promptly provide IDRI with written notice of such determination at least sixty (60) days before any deadline for taking action to avoid abandonment and shall provide IDRI with the right, opportunity and reasonable assistance to prepare, file, prosecute and maintain such Licensed Patent in the applicable jurisdiction in IDRI’s sole discretion and at IDRI’s expense, provided that Immune Design shall provide such reasonable assistance at its own costs and expenses. If IDRI elects to prepare, file, prosecute and maintain such Licensed Patent in such jurisdiction for which Immune Design has any exclusive rights, then Immune Design’s license rights to such Licensed Patent in such country will become nonexclusive in such country under such Licensed Patent (and/or patent application). If IDRI desires Immune Design to file, in a particular jurisdiction, a Licensed Patent for which Immune Design has any exclusive rights under this Agreement that claims priority to another Licensed Patent for which Immune Design has any exclusive rights under this Agreement, IDRI shall provide written notice to Immune Design requesting that Immune Design file such patent application in such jurisdiction. If IDRI provides such written notice to Immune Design, Immune Design shall either (i) file and prosecute such patent application and maintain any patent issuing thereon in such jurisdiction and the Parties shall share the related costs and expenses (A) in countries *** on the basis of *** percent (***%) Immune Design: *** percent (***%) IDRI or (B) in countries within the IDRI Territory equally; or (ii) notify IDRI that Immune Design does not desire to file such patent application in such jurisdiction and provide IDRI with the opportunity to file and prosecute such patent application, provided that if IDRI files and prosecutes such patent application in such jurisdiction, then Immune Design’s license rights to such License Patent in such country will become nonexclusive in such country under such Licensed GLA Patent (and/or patent application). Immune Design shall be responsible for the costs and expenses incurred in connection with its own activities for filing, prosecuting and maintaining the Licensed Patents; IDRI shall be responsible for monitoring of such activities by IDRI.
