Limitations Upon A/E’s Certification Sample Clauses

Limitations Upon A/E’s Certification. The A/E’s certifications and representations hereunder are subject to an evaluation of the Work for conformity with the terms of the Construction Contract upon Substantial Completion, the results of subsequent tests and inspections, minor deviations from the terms of the Construction Contract correctable prior to Final Completion and any specific qualifications expressed by the A/E. The issuance of a Certificate for Payment shall not be deemed a representation that the A/E has: (i) made exhaustive or continuous Site inspections to check the quality or quantity of the Work; (ii) reviewed construction means, methods, sequences or procedures; (iii) reviewed copies of requisitions received from Subcontractors and material suppliers and other data requested by the District to substantiate the Contractor’s right to payment, except as included in the materials accompanying an Application for Progress Payment transmitted to and reviewed by the A/E hereunder; or (iv) ascertained for or what purpose the Contractor has used funds previously disbursed under prior Application(s) for Progress Payment.
AutoNDA by SimpleDocs

Related to Limitations Upon A/E’s Certification

  • Preservation of Purchase Rights Upon Merger, Consolidation, etc In case of any consolidation of the Company with or merger of the Company into another corporation or in case of any sale, transfer or lease to another corporation of all or substantially all of the property of the Company, the Company or such successor or purchasing corporation, as the case may be, shall execute with the Warrantholders an agreement that the Warrantholders shall have the right thereafter upon payment of the Exercise Price in effect immediately prior to such action to purchase upon exercise of this Warrant the kind and amount of shares and other securities and property which such holder would have owned or have been entitled to receive after the happening of such consolidation, merger, sale, transfer or lease had this Warrant been exercised immediately prior to such action; PROVIDED, HOWEVER, that no adjustment in respect of cash dividends, interest or other income on or from such shares or other securities and property shall be made during the term of this Warrant or upon the exercise of this Warrant. Such agreement shall provide for adjustments, which shall be as nearly equivalent as practicable to the adjustments provided for in this Section 5. The provisions of this Section 5 shall apply similarly to successive consolidations, mergers, sales, transfers or leases.

  • Action upon Instructions; Certain Rights and Limitations Subject to the terms of Sections 5.02(a), 5.06, 6.01 and 6.03 hereof, upon the written instructions at any time and from time to time of a Majority in Interest of Note Holders, the Mortgagee shall, subject to the terms of this Section 6.02, take such of the following actions as may be specified in such instructions: (i) give such notice or direction or exercise such right, remedy or power hereunder as shall be specified in such instructions and (ii) give such notice or direction or exercise such right, remedy or power hereunder with respect to any part of the Collateral as shall be specified in such instructions; it being understood that without the written instructions of a Majority in Interest of Note Holders, the Mortgagee shall not, except as provided in Section 6.01, approve any such matter as satisfactory to the Mortgagee. The Mortgagee will execute and the Owner will file such continuation statements with respect to financing statements relating to the security interest created hereunder in the Collateral as may be specified from time to time in written instructions of a Majority in Interest of Note Holders (which instructions shall be accompanied by the form of such continuation statement so to be filed). The Mortgagee will furnish to each Note Holder, promptly upon receipt thereof, duplicates or copies of all reports, notices, requests, demands, certificates and other instruments furnished to the Mortgagee hereunder.

  • Class Certification Solely for the purposes of this Settlement, the Parties stipulate and agree to certification of the claims asserted on behalf of Class Members. As such, the Parties stipulate and agree that in order for this Settlement to occur, the Court must certify the Class as defined in this Agreement.

  • Termination and Waiver of Rights of First Refusal The rights of first refusal established by this Section 4 shall not apply to, and shall terminate upon the earlier of (i) the effective date of the registration statement pertaining to the Company’s Initial Offering or (ii) an Acquisition. Notwithstanding Section 5.5 hereof, the rights of first refusal established by this Section 4 may be amended, or any provision waived with and only with the written consent of the Company and the Major Investors holding a majority of the Registrable Securities held by all Major Investors, or as permitted by Section 5.5.

  • Restrictions on Transfer of a Definitive Note for a Beneficial Interest in a Global Note A Definitive Note may not be exchanged for a beneficial interest in a Rule 144A Global Note or a Regulation S Global Note except upon satisfaction of the requirements set forth below. Upon receipt by the Trustee of a Definitive Note, duly endorsed or accompanied by appropriate instruments of transfer, in form satisfactory to the Trustee, together with: (i) certification, in the form set forth on the reverse of the Note, that such Definitive Note is either (A) being transferred to a QIB in accordance with Rule 144A or (B) being transferred after expiration of the Distribution Compliance Period by a Person who initially purchased such Note in reliance on Regulation S to a buyer who elects to hold its interest in such Note in the form of a beneficial interest in the Regulation S Global Note; and (ii) written instructions directing the Trustee to make, or to direct the Notes Custodian to make, an adjustment on its books and records with respect to such Rule 144A Global Note (in the case of a transfer pursuant to clause (b)(i)(A)) or Regulation S Global Note (in the case of a transfer pursuant to clause (b)(i)(B)) to reflect an increase in the aggregate principal amount of the Notes represented by the Rule 144A Global Note or Regulation S Global Note, as applicable, such instructions to contain information regarding the Agent Member account to be credited with such increase, then the Trustee shall cancel such Definitive Note and cause, or direct the Notes Custodian to cause, in accordance with the standing instructions and procedures of the Depository and the Notes Custodian, the aggregate principal amount of Notes represented by the Rule 144A Global Note or Regulation S Global Note, as applicable, to be increased by the aggregate principal amount of the Definitive Note to be exchanged and shall credit or cause to be credited to the account of the Person specified in such instructions a beneficial interest in the Rule 144A Global Note or Regulation S Global Note, as applicable, equal to the principal amount of the Definitive Note so canceled. If no Rule 144A Global Notes or Regulation S Global Notes, as applicable, are then outstanding, the Issuer shall issue and the Trustee shall authenticate, upon written order of the Issuer in the form of an Officer’s Certificate of the Issuer, a new Rule 144A Global Note or Regulation S Global Note, as applicable, in the appropriate principal amount.

  • Limitations on Forms of Consideration The Company reserves, at any and all times, the right, in the Company’s sole and absolute discretion, to establish, decline to approve or terminate any program or procedure providing for payment of the Exercise Price through any of the means described below, including with respect to the Participant notwithstanding that such program or procedures may be available to others.

  • Exclusion of Certain Securities from Eligibility for Selection for Redemption Securities shall be excluded from eligibility for selection for redemption if they are identified by registration and certificate number in a written statement signed by an authorized officer of the Issuer and delivered to the Trustee at least 40 days prior to the last date on which notice of redemption may be given as being owned of record and beneficially by, and not pledged or hypothecated by either (a) the Issuer or (b) an entity specifically identified in such written statement as directly or indirectly controlling or controlled by or under direct or indirect common control with the Issuer.

  • Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.

  • Instructions for Certification – First Tier Participants a. By signing and submitting this proposal, the prospective first tier participant is providing the certification set out below. b. The inability of a person to provide the certification set out below will not necessarily result in denial of participation in this covered transaction. The prospective first tier participant shall submit an explanation of why it cannot provide the certification set out below. The certification or explanation will be considered in connection with the department or agency's determination whether to enter into this transaction. However, failure of the prospective first tier participant to furnish a certification or an explanation shall disqualify such a person from participation in this transaction. c. The certification in this clause is a material representation of fact upon which reliance was placed when the contracting agency determined to enter into this transaction. If it is later determined that the prospective participant knowingly rendered an erroneous certification, in addition to other remedies available to the Federal Government, the contracting agency may terminate this transaction for cause of default. d. The prospective first tier participant shall provide immediate written notice to the contracting agency to whom this proposal is submitted if any time the prospective first tier participant learns that its certification was erroneous when submitted or has become erroneous by reason of changed circumstances. e. The terms "covered transaction," "debarred," "suspended," "ineligible," "participant," "person," "principal," and "voluntarily excluded," as used in this clause, are defined in 2 CFR Parts 180 and 1200. “First Tier Covered Transactions” refers to any covered transaction between a grantee or subgrantee of Federal funds and a participant (such as the prime or general contract). “Lower Tier Covered Transactions” refers to any covered transaction under a First Tier Covered Transaction (such as subcontracts). “First Tier Participant” refers to the participant who has entered into a covered transaction with a grantee or subgrantee of Federal funds (such as the prime or general contractor). “Lower Tier Participant” refers any participant who has entered into a covered transaction with a First Tier Participant or other Lower Tier Participants (such as subcontractors and suppliers).

  • NOTICE OF CERTAIN EVENTS AFFECTING REGISTRATION; SUSPENSION OF RIGHT TO MAKE A PUT The Company shall promptly notify the Investor upon the occurrence of any of the following events in respect of a Registration Statement or related prospectus in respect of an offering of the Securities: (i) receipt of any request for additional information by the SEC or any other federal or state governmental authority during the period of effectiveness of the Registration Statement for amendments or supplements to the Registration Statement or related prospectus; (ii) the issuance by the SEC or any other federal or state governmental authority of any stop order suspending the effectiveness of any Registration Statement or the initiation of any proceedings for that purpose; (iii) receipt of any notification with respect to the suspension of the qualification or exemption from qualification of any of the Securities for sale in any jurisdiction or the initiation or notice of any proceeding for such purpose; (iv) the happening of any event that makes any statement made in such Registration Statement or related prospectus or any document incorporated or deemed to be incorporated therein by reference untrue in any material respect or that requires the making of any changes in the Registration Statement, related prospectus or documents so that, in the case of a Registration Statement, it will not contain any untrue statement of a material fact or omit to state any material fact required to be stated therein or necessary to make the statements therein not misleading, and that in the case of the related prospectus, it will not contain any untrue statement of a material fact or omit to state any material fact required to be stated therein or necessary to make the statements therein, in the light of the circumstances under which they were made, not misleading; and (v) the Company’s reasonable determination that a post-effective amendment or supplement to the Registration Statement would be appropriate, and the Company shall promptly make available to Investor any such supplement or amendment to the related prospectus. The Company shall not deliver to Investor any Put Notice during the continuation of any of the foregoing events in this Section 5.10.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!