Mileage Reimbursement and Use of Private Vehicles Sample Clauses

Mileage Reimbursement and Use of Private Vehicles. When an employee is required to travel or is assigned to work at a location other than his or her regularly assigned work location, the Court will either provide transportation for such travel or reimburse the employee for the use of a private vehicle consistent with the rate established by the Administrative Office of the Courts. Employees required to travel on business for the Court using a privately owned vehicle must: • have a valid driver's license • have proof of liability insurance in his or her possession while operating a vehicle on Court business • be covered for the minimum amount of liability insurance for the minimum amount prescribed by law • have a vehicle equipped with safety belts in operating condition • wear the safety belt and make sure all passengers are wearing his or her safety belt • attest that the vehicle is in safe mechanical condition to the best of his or her knowledge • report any accidents within 48 hours • complete an Authorization to Use Privately Owned Vehicles on State Business form (STD 251) annually
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
Mileage Reimbursement and Use of Private Vehicles. When an employee is required to travel or is assigned to work at a location other than his or her regularly assigned work locatiqn the Court will either provide transportation for such travel or reimburse the employee for the use of a private vehicle consistent with the rate established by i he Administrative Office of the Courts. Employees required to travel on business for the Court using a privately owned vehicle must: (a) have a valid driver's license (b) have proof of liability insurance in his or vehicle on Court business ler possession while operating a (c) be covered for the minimum amount of liability insurance for the minimum amount prescribed by law (d) have a vehicle equipped with safety belts in operating condition a. wear the safety belt and make sure all passengers are wearing his or her safety belt b. attest that the vehicle is in safe mechanical condition to the best of his or her knowledge (e) report any accidents within 48 hours (f) complete an Authorization to Use Privately Owned Vehicles on State Business form (STD 251) annually
Sample 1

Related to Mileage Reimbursement and Use of Private Vehicles

  • Mileage Reimbursement Subject to the current Vehicle Rules and Regulations established by the Board, an employee who is authorized to use a private automobile in the performance of duties shall be paid the Internal Revenue Service Standard Mileage Rate for the Business Use of a Car for each mile driven during each monthly period.

  • Transportation Reimbursement Employees who, during the course of their normal duties, are required to actually transport clients/consumers/felons in their own personal vehicle on a regular basis, are eligible for reimbursement for the cost of an automobile rider to their existing insurance policy. To be eligible for the reimbursement, the employee must demonstrate the following: 1. That he/she is normally required to transport clients/consumers/felons in the course of their duties. 2. That there is no access to or available State vehicles. 3. That public transportation cannot be used. 4. That their insurance company requires a special rider on their existing automobile policy. 5. Proof that such a rider has been purchased. 6. Proof of a valid driver’s license and insurance policy. By receiving such reimbursement, employees acknowledge that they may be required to use their own personal vehicle to transport clients/consumers/felons in the normal course of their duties. The reimbursement to such employee(s) is the actual cost of the rider not to exceed seventy-five dollars ($75) per year whichever is less. This reimbursement will be paid on a yearly basis in the pay period that includes July 1st. Employees who either resign, retire, or have their employment terminated during the year and employees who start during any part of the year will have the reimbursement prorated. In the case of employees who either retire, resign, or have their employment terminated will have that portion of the reimbursement repaid to the State, in the last paycheck.

  • REIMBURSEMENT FOR MILEAGE AND INSURANCE 1. An employee who is required by their employer to use their private vehicle for school district related purposes shall receive reimbursement of: Effective July 1, 2019 $ 0.56 c/Km Effective July 1, 2020 $ 0.57 c/Km Effective July 1, 2021 $ 0.58 c/Km 2. The mileage reimbursement rate established in Article B.10.1 shall be increased by 5 cents/kilometer for travel that is approved and required on unpaved roads. 3. The employer shall reimburse an employee who is required to use their personal vehicle for school district purposes, the difference in premium costs between ICBC rate Class 002 (Pleasure to/from Work) and ICBC rate Class 007 (Business Class) where the employee is required to purchase additional insurance in order to comply with ICBC regulations respecting the use of one’s personal vehicle for business purposes.

  • Maintenance of Hazard Insurance; Property Protection Expenses (a) The Master Servicer shall cause to be maintained for each Home Equity Loan hazard insurance naming the Master Servicer or related Subservicer as loss payee thereunder providing extended coverage in an amount which is at least equal to the lesser of (i) the maximum insurable value of the improvements securing such Home Equity Loan from time to time or (ii) the combined Loan Balance owing on such Home Equity Loan and any mortgage loan senior to such Home Equity Loan from time to time; provided, however, that such coverage may not be less than the minimum amount required to fully compensate for any loss or damage on a replacement cost basis. The Master Servicer shall also cause to be maintained on property acquired upon foreclosure, or deed in lieu of foreclosure, of any Home Equity Loan, fire insurance with extended coverage in an amount which is at least equal to the amount necessary to avoid the application of any co-insurance clause contained in the related hazard insurance policy. Amounts collected by the Master Servicer under any such policies (other than amounts to be applied to the restoration or repair of the related Mortgaged Property or property thus acquired or amounts released to the Mortgagor in accordance with the Master Servicer's normal servicing procedures) shall be deposited in the Custodial Account to the extent called for by Section 3.02. In cases in which any Mortgaged Property is located at any time during the life of a Home Equity Loan in a federally designated flood area, the hazard insurance to be maintained for the related Home Equity Loan shall include flood insurance (to the extent available). All such flood insurance shall be in amounts equal to the lesser of (i) the amount required to compensate for any loss or damage to the Mortgaged Property on a replacement cost basis and (ii) the maximum amount of such insurance available for the related Mortgaged Property under the national flood insurance program (assuming that the area in which such Mortgaged Property is located is participating in such program). The Master Servicer shall be under no obligation to require that any Mortgagor maintain earthquake or other additional insurance and shall be under no obligation itself to maintain any such additional insurance on property acquired in respect of a Home Equity Loan, other than pursuant to such applicable laws and regulations as shall at any time be in force and as shall require such additional insurance. If the Master Servicer shall obtain and maintain a blanket policy consistent with its general mortgage servicing activities insuring against hazard losses on all of the Home Equity Loans, it shall conclusively be deemed to have satisfied its obligations as set forth in the first sentence of this Section 3.04, it being understood and agreed that such policy may contain a deductible clause, in which case the Master Servicer shall, in the event that there shall not have been maintained on the related Mortgaged Property a policy complying with the first sentence of this Section 3.04 and there shall have been a loss which would have been covered by such policy, deposit in the Custodial Account the amount not otherwise payable under the blanket policy because of such deductible clause. Any such deposit by the Master Servicer shall be made on the last Business Day of the Collection Period in the month in which payments under any such policy would have been deposited in the Custodial Account. In connection with its activities as servicer of the Home Equity Loans, the Master Servicer agrees to present, on behalf of itself, the Issuer and the Indenture Trustee, claims under any such blanket policy.

  • Janitorial Services Tenant will not employ any person for the purpose of cleaning the Premises or permit any person to enter the Building for such purpose other than Landlord's janitorial service, except with Landlord's prior written consent. Tenant will not necessitate, and will be liable for the cost of, any undue amount of janitorial labor by reason of Tenant's carelessness in or indifference to the preservation of good order and cleanliness in the Premises. Janitorial service will not be furnished to areas in the Premises on nights when such areas are occupied after 9:30 p.m., unless such service is extended by written agreement to a later hour in specifically designated areas of the Premises.

  • Insurance Reimbursement If you have a health insurance policy, it will usually provide some coverage for mental health treatment. I will facilitate your receipt of the benefits to which you are entitled including filling out forms and speaking with insurance representatives. You will be held responsible for full payment of our agreed upon fee should your insurance company deny benefits or should your coverage lapse. Therefore, it is very important that you find out exactly what mental health benefits your insurance policy covers. Read your plan carefully and call your service representative if you have questions. Many insurance plans require advance authorization before they will provide reimbursement for mental health services. These plans often are oriented toward a short-term model and provide only a certain amount of sessions per year. Many insurance companies may only authorize a few sessions at a time and I will need to periodically call them to authorize additional sessions. When I call to authorize treatment or continue our sessions, I will provide them with the minimum amount of information needed, usually including a diagnosis, goals for treatment, and a brief summary of your current functioning. It is possible, but very rare, that they would require a copy of my clinical record. This information will become part of insurance company files and is likely to be computerized. All insurance companies claim to keep such information confidential, but once it is in their hands, I have no control over what they do with it. In some cases, they may share the information with a national medical information data bank. By signing this Agreement, you agree that I can provide requested information to your insurance carrier. If you request it, I will provide you with a copy of any report that I am asked to submit. I make it my policy to inform you along the way of where we stand with your insurance company and what kind of information they have requested. Should insurance coverage end for some reason, we can discuss an out-of-pocket session fee. You can always choose to select this option and have the right to pay for my services yourself to avoid the complexities of the insurance industry.

  • Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.

  • Telephone Allowance Employees on travel status who are required to obtain overnight accommodation shall be entitled to claim for one (1) fifteen (15) minute telephone call home to or within British Columbia, for the first night away and then for every three (3) consecutive nights away thereafter.

  • RIGHT OF ALLOTTEE TO USE COMMON AREAS AND FACILITIES SUBJECT TO PAYMENT OF TOTAL MAINTENANCE CHARGES The Allottee hereby agrees to purchase the [Apartment/Plot] on the specific understanding that is/her right to the use of Common Areas shall be subject to timely payment of total maintenance charges, as determined and thereafter billed by the maintenance agency appointed or the association of allottees (or the maintenance agency appointed by it) and performance by the Allottee of all his/her obligations in respect of the terms and conditions specified by the maintenance agency or the association of allottees from time to time.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!