Nature of the Authority Sample Clauses

Nature of the Authority. The Authority is a political subdivision of the State of Colorado, formed in conformity with the provisions of Sections 29-1-203 and -203.5, C.R.S. and the provisions of those statutes apply to the Authority. In carrying out its purposes, the Authority will observe and comply with statutes and laws applicable to the District and the City, including, but not limited to Parts 1, 5, and 6 of Article 1, Title 29, C.R.S., regarding budget preparation, accounting, and auditing; and Part 4 of Article 6, Parts 2 and 3 of Article 72 as applicable to the Authority, and Articles 6 and 10 of Title 24, C.R.S., regarding open meetings, open records, criminal justice records, and governmental immunity. The Parties intend that the Authority is not considered a “district” subject to Article X, Section 20 of the Colorado Constitution. The Authority boundaries shall consist of the combined territorial boundaries of the Parties.
Sample 1
AutoNDA by SimpleDocs
Nature of the Authority. The Authority is a separate legal entity organized pursuant to Arizona Revised Statutes §48-805.01. In carrying out its purposes, the Authority will observe and comply with statutes and laws applicable to a fire protection district, including but not limited to Articles I, 2, and 3 of Title 48, Chapter 5, regarding Fire Districts, Title 38, §38-101 et seq., regarding Public Officers and Employees, Title 35 regarding Public Finances, Title 36 regarding Public Safety, and others. The Authority boundaries shall consist of the combined jurisdictional and contractual territorial boundaries of the Parties hereto as of the date of execution of this Agreement.
Sample 1
Nature of the Authority. The Authority is a separate governmental entity, political subdivision and a public corporation of the state, separate from the Parties, established pursuant to Section 29-1-204.2(4), C.R.S. The Authority shall have the duties, privileges, immunities, rights, liabilities, and disabilities of a public body politic and corporate. In carrying out its purposes, the Authority shall observe and comply with statutes and laws applicable to the Parties, including but not limited to Parts 1, 5, and 6 of Article 1, Title 29, C.R.S., regarding budget preparation, accounting, and auditing; Part 4 of Article 6, and Parts 2 and 3 of Article 72 as applicable to the Authority; and Article 10 of Title 24, C.R.S., regarding open meetings, open records, criminal justice records, and governmental immunity. The parties intend that the Authority not be considered a “district” subject to XXXXX.
Sample 1

Related to Nature of the Authority

  • The Authority As to the Authority, the following section shall survive discharge: Section 2.3 (right to conduct audit).

  • Obligations of the Authority (i) The Authority shall, at its own cost and expense, undertake, comply with and perform all its obligations set out in this Agreement or arising hereunder. (ii) The Authority shall be responsible for the correctness of the Scope of the Project, Project Facilities, Specifications and Standards and the criteria for testing of the completed Works. (iii) The Authority shall, upon submission of the Performance Security as per the RFP by the Contractor, shall provide to the Contractor: (a) No less than 90% (ninety per cent) of the required Right of Way of the Construction Zone of total length of the Project Highway within a period of 30 (thirty) days from the date of this Agreement, which shall be in contiguous stretches of length not less than 1( One) kilometre. (b) approval of the general arrangement drawings (the “GAD”) from railway authorities to enable the Contractor to construct road over- bridges/ under- bridges at level crossings on the Project Highway in accordance with the Specifications and Standards, and subject to the terms and conditions specified in such approval, within a period of 60 (sixty) days from the Appointed Date, and reimbursement of all the costs and expenses paid by the Contractor to the railway authorities for and in respect of the road over- bridges/ under bridges; and7 (c) all environmental clearances as required under Clause 4.3.8 (iv) Delay in providing the Right of Way or approval of GAD by railway authorities, as the case may be, in accordance with the provisions of Clause 3.1 (iii) shall entitle the Contractor to Damages in a sum calculated in accordance with the provisions of Clause 8.3 of this Agreement and Time Extension in accordance with the provisions of Clause 10.5 of this Agreement. For the avoidance of doubt, the Parties agree that the Damages for delay in approval of GAD by the railway authorities for a particular road over-bridge/ under-bridge shall be deemed to be equal to the Damages payable under the provisions of Clause 8.3 for delay in providing Right of Way for a length of 2 (two) kilometre for each such road over-bridge/ under-bridge.

  • Committee Authority The Committee shall have all discretion, power, and authority to interpret the Plan and this Agreement and to adopt such rules for the administration, interpretation and application of the Plan as are consistent therewith. All actions taken and all interpretations and determinations made by the Committee in good faith shall be final and binding upon the Employee, the Company and all other interested persons, and shall be given the maximum deference permitted by law. No member of the Committee shall be personally liable for any action, determination or interpretation made in good faith with respect to the Plan or this Agreement.

  • Jurisdiction of the Arbitrator The arbitrator shall have no power to alter, add to, subtract from the terms of this Agreement. The arbitrator's decision will be based upon the specific provisions of this Agreement. This arbitration provision shall be for grievances only.

  • Authority of the Arbitrator i. It is the intent of both parties to this Collective Agreement that no grievance shall be defeated merely because of a technical error in processing the grievance through the grievance procedure. To this end an arbitrator shall have the power to allow all necessary amendments to the grievance and the power to waive formal procedural irregularities in the processing of a grievance in order to determine the real matter in dispute and to render a decision according to equitable principles and the justice of the case. ii. The arbitrator shall not have jurisdiction to alter or change the provisions of the Collective Agreement or to substitute new ones. iii. The provisions of this article do not override the provisions of the B.C.

  • CONDUCT OF THE AUCTION Conduct of the auction and increments of bidding are at the discretion of the Auctioneer. The Auctioneer's decision is final in the event of a dispute over any matter. The Auctioneer reserves the right to accept bids in any increments he deems to be in the best interest of his client, and reserves the right to waive any previously announced requirements. Bid rigging and bid suppression schemes are violations of the Xxxxxxx Antitrust Act and are deemed illegal and punishable as a federal felony.

  • Xxxxxx of the Arbitrator It shall be the function of the arbitrator, and he/she shall be empowered, except as his/her powers are limited below, after due investigation, to make a decision in cases of alleged violation of the specific articles and sections of this Agreement. 1. The arbitrator shall have no power to add to, subtract from, disregard, alter, or modify any of the terms of this Agreement. 2. The arbitrator shall have no power to rule on any of the following: a. Actions taken by the Employer with respect to probationary employees including, but not limited to, discipline and discharge. b. Any claim or complaint for which there is another remedial procedure or forum established by law or by regulation having the force of law. c. Any matter involving the content of an employee evaluation. 3. He/she shall have no power to change any practice, policy, or rule of the Employer nor to substitute his/her judgment for that of the Employer as to the reasonableness of any such practice, policy, rule, or any action taken by the Employer. His/her power shall be limited to deciding whether the Employer has violated the express articles or sections of this Agreement; and he/she shall not imply obligations and conditions binding upon the Employer from this Agreement, it being understood that any matter not specifically set forth herein remains within the reserved rights of the Employer. 4. He/she shall have no power to decide any question which, under this Agreement, is within the responsibility of management to decide. In rendering a decision, an arbitrator shall give due regard to the responsibility of management and shall so construe the Agreement that there will be no interference with such responsibilities, except as they may be specifically conditioned by this Agreement. 5. If either party disputes the arbitrability of any grievance under the terms of this Agreement, the arbitrator shall first determine the arbitrability of said dispute. By stipulation of the parties, the Arbitrator shall have the authority to concurrently hear both the jurisdictional issues and the merits of the dispute in the same proceeding. Should the Arbitrator determine that he/she is without jurisdiction to rule, the matter shall be dismissed without decision on the merits. Submission of jurisdictional issues to the Arbitrator shall not be regarded as a waiver by either party of its right to institute civil litigation contesting either the authority of the Arbitrator or any award allegedly rendered in excess of such authority. 6. There shall be no appeal from the arbitrator’s decision if within the scope of his/her authority as set forth above. It shall be final and binding on the Association, its members, the employee or employees involved and the Employer. Any litigation to vacate or enforce the Arbitrator’s decision must be initiated within six (6) months of the issuance of the Opinion and Award. 7. The fees and expenses of the arbitrator shall be shared equally by the Association and the Employer.

  • Decision of the Arbitrator The decision of the arbitrator shall be final, binding, and enforceable on the Parties. The arbitrator shall have the power to dispose of a grievance by any arrangement deemed just and equitable. However, the arbitrator shall not have the power to change this Agreement by altering, modifying, or amending any provision.

  • AGREEMENT OFFICIALS AND DELEGATIONS OF AUTHORITY ‌ The following are authorized to subscribe to and file this Agreement and any accompanying materials and any subsequent modifications to this Agreement with the Federal Maritime Commission: (i) Any authorized officer of either party; and (ii) Legal counsel for either party.

  • Power of the Authority to undertake works (i) In the event the Parties are unable to agree to the proposed Change of Scope Orders in accordance with Clause 13.2, the Authority may, after giving notice to the Contractor and considering its reply thereto, award such Works or services to any person or agency on the basis of open competitive bidding. It is also agreed that the Contractor shall provide assistance and cooperation to the person or agency who undertakes the works or services hereunder. The Contractor shall not be responsible for rectification of any Defects, but the Contractor shall carry out maintenance of such works after completion of Defect Liability Period of work by other person or agency during the remaining period of this agreement without any extra payment. (ii) The Works undertaken in accordance with this Clause 13.5 shall conform to the Specifications and Standards and shall be carried out in a manner that minimises the disruption in operation of the Project Highway. The provisions of this Agreement, insofar as they relate to Works and Tests, shall apply mutatis mutandis to the Works carried out under this Clause 13.5.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!