Other Potential Changes Sample Clauses

Other Potential Changes. If, during the Term, the Province receives revenues in relation to gaming activities other than from the Actual Net Income of BCLC, which may include but are not limited to revenues received from a fee, levy or tax collected by the Province in relation to gaming activity, the Parties will meet to discuss the potential for sharing such revenues with Partnership. For greater certainty, the receipt of such revenues by the Province is not, in and of itself, a Change Event; however, if the receipt of such revenues has the effect of materially reducing or eliminating the stream of revenues generated by the Annual Gaming Revenue Entitlement, such reduction or elimination will be a Change Event and the Parties will engage in the Consultative Process in respect of such Change Event and related Alternative Measures.
Sample 1
AutoNDA by SimpleDocs

Related to Other Potential Changes

  • Material Changes Except as contemplated in the Prospectus, or disclosed in the Company’s reports filed with the Commission, there shall not have been any material adverse change in the authorized capital stock of the Company or any Material Adverse Effect or any development that would reasonably be expected to cause a Material Adverse Effect, or a downgrading in or withdrawal of the rating assigned to any of the Company’s securities (other than asset backed securities) by any rating organization or a public announcement by any rating organization that it has under surveillance or review its rating of any of the Company’s securities (other than asset backed securities), the effect of which, in the case of any such action by a rating organization described above, in the reasonable judgment of the Agent (without relieving the Company of any obligation or liability it may otherwise have), is so material as to make it impracticable or inadvisable to proceed with the offering of the Placement Shares on the terms and in the manner contemplated in the Prospectus.

  • Service Changes PBI may modify its Service by giving written notice to you (a “Service Change Notice”), which will state whether the change is material. After receiving a Service Change Notice, if the change is material, you may terminate Service by giving us a termination notice at the address indicated in Section 21 or you may create a case at xxxxxxxxxxx.xxx/xx/xxxxxxx-xx.xxxx (follow the instructions under “how to create a case”).

  • Contractor Changes The Contractor shall notify DAS in writing no later than ten (10) Days from the effective date of any change in: a. its certificate of incorporation or other organizational document; b. more than a controlling interest in the ownership of the Contractor; or c. the individual(s) in charge of the Performance. This change shall not relieve the Contractor of any responsibility for the accuracy and completeness of the Performance. DAS, after receiving written notice by the Contractor of any such change, may require such agreements, releases and other instruments evidencing, to DAS’s satisfaction, that any individuals retiring or otherwise separating from the Contractor have been compensated in full or that provision has been made for compensation in full, for all work performed under terms of the Contract. The Contractor shall deliver such documents to DAS in accordance with the terms of DAS’s written request. DAS may also require, and the Contractor shall deliver, a financial statement showing that solvency of the Contractor is maintained. The death of any Contractor Party, as applicable, shall not release the Contractor from the obligation to Perform under the Contract; the surviving Contractor Parties, as appropriate, must continue to Perform under the Contract until Performance is fully completed.

  • Contract Changes Changes may not be made in the terms and conditions of this contract without the agreement and written permission of the Director of Residence Life or the Director’s designee.

  • Deviations Deviations from the drawings and the dimensions therein given, whether or not error is believed to exist, shall be made only after written authority is obtained from the County, and shall be documented within the Detailed Scope of Work for the specific Job Order.

  • SCOPE CHANGES The Commissioner reserves the right to require, by written order, changes to the scope of the Contract, by altering, adding to or deducting from the Bid Specifications, such changes to be within the general scope of the Contract. If any such change causes an increase or decrease in the cost of, or the time required for, performance of any part of the work under the Contract, whether or not changed by the order, the Commissioner shall, upon notice from Contractor as hereafter stated, make an equitable adjustment in the Contract price, the delivery schedule or both and shall modify the Contract. The Contractor must assert its right to an adjustment under this clause within thirty days from the date of receipt of the written order. However, if the Commissioner decides that the facts justify it, the Commissioner may provide an adjustment without receipt of a proposal. Failure to agree to any adjustment shall be a dispute under the Disputes clause, provided, however, that nothing in this clause shall excuse the Contractor from proceeding with the Contract as changed.

  • TECHNOLOGICAL CHANGES 29.01 Any significant technological changes affecting members or their work environment will be discussed between Management and the Association prior to implementation with a view to resolving any problems. Whenever practical, the Board, through the Administration of the Service, will commence such discussions at least three (3) months in advance of the planned change.

  • Shift Changes When an employee is assigned to a specific shift and that assignment is changed, the employee shall be given seven (7) calendar days’ notice prior to the change.

  • Common Areas - Changes Lessor shall have the right, in Lessor's sole discretion, from time to time: (a) To make changes to the Common Areas, including, without limitation, changes in the location, size, shape and number of driveways, entrances, parking spaces, parking areas, loading and unloading areas, ingress, egress, direction of traffic, landscaped areas, walkways and utility raceways; (b) To close temporarily any of the Common Areas for maintenance purposes so long as reasonable access to the Premises remains available; (c) To designate other land outside the boundaries of the Industrial Center to be a part of the Common Areas; (d) To add additional buildings and improvements to the Common Areas; (e) To use the Common Areas while engaged in making additional improvements, repairs or alterations to the Industrial Center, or any portion thereof; and (f) To do and perform such other acts and make such other changes in, to or with respect to the Common Areas and Industrial Center as Lessor may, in the exercise of sound business judgment, deem to be appropriate.

  • Project Changes 1.8.1. All changes shall be administered per the UGC. 1.8.2. Upon authorization by the Owner, the Owner or Architect/Engineer will prepare and issue all changes to the Contract affecting cost, scope and/or time as a formal Change Order to the Contract on the standard University of Texas MD Xxxxxxxx Cancer Center Change Order form. The Change Order may include separate change issues, identified as Change Proposals and field orders. 1.8.3. Upon authorization by the Owner, Change Proposals may be issued to the Architect/Engineer for pricing by the Contractor. Contractor shall submit pricing to the Owner within twenty-one (21) days and pricing shall be indicated on the standard Owner "Change in Work Cost Analysis" ("Cost Analysis") form provided in the Pre-Construction Conference Brochure. Contractor may not include a Change Proposal within a Change Order unless the Owner has accepted the Change Proposal. 1.8.3.1. The Contractor shall summarize all costs for each change at each level of subcontractor and supplier by preparing the "Cost Analysis" form, and shall provide each subcontractor's cost summary on separate "Cost Analysis" forms as backup. Additional support documentation from both the Contractor and Contractor’s subcontractors is encouraged, but such will not replace use of the standard form. 1.8.3.2. When the Contractor believes it is entitled to a time extension, Contractor shall so state as part of Contractor’s response to the Change Proposal, including a justifica- tion for a time extension. Owner may grant time extensions only if a Change Proposal affects the activities on the Longest Path of an Owner approved Work Progress Schedule; i.e., when the Work impacts the "Contract Substantial Completion Date". 1.8.3.3. If the Owner’s Project Manager and Contractor cannot mutually agree upon a fair and reasonable cost and time settlement, the Owner’s Project Manager may: 1) Reject the quotation and void the Change Proposal, 2) Issue instructions to the Contractor to proceed on a time and material basis for a price to be determined later not to exceed a fixed maximum dollar and time, or 3) Issue a Unilateral Change Order. 1.8.3.4. The Owner’s Construction Inspector and/or Owner’s Project Manager may issue field orders directly to the Contractor for minor changes to the Contract, which can be negotiated in the field. Pricing backup is at the discretion of the Owner’s Construction Inspector, but pricing backup is required for any field order, the pricing backup is to be outlined on the "Cost Analysis" form. When the Owner and Contractor have signed the field order, the Work is authorized and the field order may be included in the next Change Order. 1.8.4. Request for payment for Change Order work may be submitted only after the Change Order has been fully executed.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!