Owner’s Right to Perform Work. The Owner reserves the right to perform construction or operations related to the Project with Separate Contractors on the Site. If the Contractor claims that delay or additional cost is because of such action by the Owner, the Contractor shall assert such claims as provided in Section 5, Part 2 of the General Conditions.
Owner’s Right to Perform Work. In the event Owner issues such instructions to stop Work, and in the further event that Design/Builder fails and refuses within seven (7) days of receipt of same to provide adequate assurance to Owner that the cause of such instructions will be eliminated or corrected, then Owner shall have the right to carry out the Work with its own forces, or with the forces of other contractors, and Design/Builder shall be fully responsible for the reasonable costs incurred in performing such Work. The rights set forth in Paragraph 12.12 and this Paragraph 12.13 are in addition to, and without prejudice to, any other rights or remedies Owner may have against Design/Builder, including the rights to terminate or withhold payment as provided herein.
Owner’s Right to Perform Work. 6.3.1 If the Contractor's Work is stopped by the Owner under Paragraph 6.2, and the Contractor fails within seven (7) days of such stoppage to provide adequate assurance to the Owner that the cause of such stoppage will be eliminated or corrected, then the Owner may, without prejudice to any other rights or remedies the Owner may have against the Contractor, proceed to carry out the subject Work. In such a situation, an appropriate Change Order shall be issued deducting from the Contract Price the cost of correcting the subject deficiencies, plus compensation for the any additional services and expenses necessitated thereby, if any. If the unpaid portion of the Contract Price is insufficient to cover the amount due the Owner, the Contractor shall pay the difference to the Owner.
Owner’s Right to Perform Work. If Contractor fails, within three (3) days after written notice from Owner or Professional, to correct defective Work or to remove and replace rejected defective Work as required by Owner or Professional, or if Contractor fails to perform the Work in accordance with the Contract Documents, or if Contractor fails to comply with any of the provisions of the Contract Documents, Owner may, correct and remedy any such deficiency; provided, however, in the event that any defective or non-conforming work is deemed by Owner in its sole discretion to present an immediate threat to safety or security, Owner shall be entitled to immediately correct and fix such defective or non- conforming portions of the Work without three (3) days written notice to Contractor. To the extent necessary to complete corrective and remedial action, Owner may exclude Contractor from any or all of the Project Site, take possession of all or any part of the Work, and suspend Contractor’s services related thereto, take possession of Contractor’s tools, appliances, construction equipment and machinery at the Project Site and incorporate in the Work all materials and equipment stored at the Project site or for which Owner has paid Contractor but which are stored elsewhere. Contractor shall allow Owner, Professional and their respective representatives, agents, and employees such access to the Project Site as may be necessary to enable Owner to exercise the rights and remedies under this Section. All direct, indirect and consequential costs of Owner in exercising such rights and remedies shall be charged against Contractor, and a Change Order shall be issued, incorporating the necessary revisions to the Contract Documents, including an appropriate decrease to the Contract Price. Such direct, indirect and consequential costs shall include fees and charges of engineers, architects, attorneys and other professionals, all court and arbitration costs and all costs of repair and replacement of work of others destroyed or damaged by correction, removal or replacement of Contractor’s defective Work. Contractor shall not be allowed an extension of the Contract Time because of any delay in performance of the Work attributable to the exercise by Owner of Owner’s rights and remedies hereunder.
Owner’s Right to Perform Work. 6.3.1 If the Contractor has installed defective or deficient Work which is not in conformity with the requirements of the Contract Documents, or if the Contractor fails or refuses to perform any portion of the Work, then the Owner may, without prejudice to any other rights or remedies the Owner may have against the Contractor, proceed to carry out the subject Work. In such a situation, the Contract Price shall be reduced by the cost of performing the subject Work, plus compensation for the Architect’s additional services and expenses necessitated thereby, if any. If such Work is performed by employees of the Owner, the Contract Price reduction shall reflect the reasonable value of such Work based upon the reasonable commercial cost of such Work as if performed by an independent contractor. If the unpaid portion of the Contract Price is insufficient to cover the amount due the Owner, the Contractor shall pay the difference to the Owner within ten (10) days of receipt of demand from the Owner.
Owner’s Right to Perform Work. 6.3.1 If the Contractor's work is stopped by the Owner under Paragraph 6.2, and the Contractor fails within seven (7) days of such stoppage to provide adequate assurance to the Owner that the cause of such stoppage will be eliminated or corrected, then the Owner may, without prejudice to any other rights or remedies the Owner may have against the Contractor, proceed to carry out the subject work. In such a situation, an appropriate Change Order shall be issued deducting from the Contract Price the cost of correcting the subject deficiencies, plus compensation for the Engineer's additional services and expenses necessitated thereby, if any. If the unpaid portion of the Contract Price is insufficient to cover the amount due the Owner, the Contractor shall pay the difference to the Owner.
7.1 The Contractor shall perform the work strictly in accordance with this Contract.
7.2 The Contractor shall supervise and direct the work using the Contractor's best skill, effort and attention. The Contractor shall be responsible to the Owner for any and all acts or omissions of the Contractor, its employees and others engaged in the work on behalf of the Contractor.
Owner’s Right to Perform Work. And to Award Separate Contracts;
Owner’s Right to Perform Work. And to Award Separate Contracts; and Cooperation with Separate Contractors
26.01 If Contractor causes damage to the property of Owner or to other work or property on the Project site, Contractor shall promptly remedy such damage as provided in this Agreement.
26.02 If Contractor delays or causes damage to the work or property of any separate contractor, Contractor shall, upon due notice, promptly attempt to settle with such other contractor by agreement, or otherwise to resolve the dispute.
26.03 The requirements of this Article shall be included in all Trade Contracts.
Owner’s Right to Perform Work. And to Award Separate Contracts; and Cooperation with Separate Contractors
26.1 Design/Builder expressly understands that Owner reserve the right to directly engage contractors and other Design/Builders (collectively referred to in this Article XXVI as contractors) to perform work on the Project. These contractors, may provide additional work beyond the Work covered by this Agreement including, but not limited to, tenant improvements or may perform work covered by this Agreement which is not, in the opinion of Owner, being performed in keeping with the Project’s objectives of cost, quality and schedule. The Agreements with contractors hired directly by the Owner may include terms, covenants, conditions and warranties different from those of any Trade Contract or the Contract Documents. Design/Builder shall, without additional compensation, coordinate the Work with the work of such contractors and with the work of Trade Contractors and the Project in general. Design/Builder shall cooperate with such contractors in providing access to the Project site and to the work as the contractors may reasonably request. Design/Builder shall furnish to such contractors any services which Design/Builder furnishes to Trade Contractors including, but not limited to, use of hoisting facilities and temporary utilities. Design/Builder shall be compensated for any costs, including without limitation, those arising by virtue of delays or coordination issues arising out of Owner’s use of other contractors or Design/Builders.
26.2 Design/Builder agrees to cooperate with such contractors and to provide such assistance for the purpose of coordinating the work of such contractors and Design/Builder as well as integrating the Progress Schedule with the schedule of such contractors as may be necessary or proper in the interest of the Project. Design/Builder shall afford Owner and such contractors opportunity to install or cause the installation of equipment of furnishings in the Project, provided that such installation shall not materially interfere with Design/Builder’s performance of its obligations.
26.3 If Design/Builder causes damage to the property of Owner or such contractors or to other work or property on the Project Site, Design/Builder shall promptly remedy such damage as provided in this Agreement. If the Owner or any such contractor causes damage to the Work and Design/Builder is required to remedy such damage, Owner will issue a Change Order in accordance with Article XX...
Owner’s Right to Perform Work. If Construction Manager defaults or neglects to carry out all or any portion of the Work or correct any Defects in accordance with the terms and conditions of this Agreement, the Owner, without prejudice to any other right or remedy under this Agreement, upon providing five (5) Days written notice to Construction Manager, may perform the Work or correct such Defects, or any part thereof, by whatever methods or means it may deem expedient.
