Excuse for Nonperformance or Delayed Performance Except with respect to defaults of subcontractors, Contractor/Vendor shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure by Contractor/Vendor to make progress in the prosecution of the work hereunder which endangers such performance) if Contractor/Vendor has notified the Commission or designee within 15 days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes or other labor disputes; freight embargoes; or unusually severe weather. If the failure to perform is caused by the failure of a subcontractor to perform or to make progress, and if such failure arises out of causes similar to those set forth above, Contractor/Vendor shall not be deemed to be in default, unless the services to be furnished by the subcontractor were reasonably obtainable from other sources in sufficient time to permit Contractor to meet the contract requirements. Upon request of Contractor, the Commission or designee shall ascertain the facts and extent of such failure, and, if such officer determines that any failure to perform was occasioned by any one or more of the excusable causes, and that, but for the excusable cause, Contractor’s progress and performance would have met the terms of the contract, the delivery schedule shall be revised accordingly, subject to the rights of the State under the clause entitled (in fixed-price contracts, “Termination for Convenience,” in cost-reimbursement contracts, “Termination”). (As used in this Paragraph of this clause, the term “subcontractor” means subcontractor at any tier).
Excuse from performance of obligations If the Affected Party is rendered wholly or partially unable to perform its obligations under this Agreement because of a Force Majeure Event, it shall be excused from performance of such of its obligations to the extent it is unable to perform on account of such Force Majeure Event; provided that:
(a) the suspension of performance shall be of no greater scope and of no longer duration than is reasonably required by the Force Majeure Event;
(b) the Affected Party shall make all reasonable efforts to mitigate or limit damage to the other Party arising out of or as a result of the existence or occurrence of such Force Majeure Event and to cure the same with due diligence; and
(c) when the Affected Party is able to resume performance of its obligations under this Agreement, it shall give to the other Party notice to that effect and shall promptly resume performance of its obligations hereunder.
Prevention or Delay of Performance by the Company or the Depositary Neither the Depositary nor the Company nor any of their respective directors, employees, agents or affiliates shall incur any liability to any Owner or Holder:
(i) if by reason of (A) any provision of any present or future law or regulation or other act of the government of the United States, any State of the United States or any other state or jurisdiction, or of any governmental or regulatory authority or stock exchange; (B) (in the case of the Depositary only) any provision, present or future, of the articles of association or similar document of the Company, or any provision of any securities issued or distributed by the Company, or any offering or distribution thereof; or (C) any event or circumstance, whether natural or caused by a person or persons, that is beyond the ability of the Depositary or the Company, as the case may be, to prevent or counteract by reasonable care or effort (including, but not limited to, earthquakes, floods, severe storms, fires, explosions, war, terrorism, civil unrest, labor disputes, criminal acts or outbreaks of infectious disease; interruptions or malfunctions of utility services, Internet or other communications lines or systems; unauthorized access to or attacks on computer systems or websites; or other failures or malfunctions of computer hardware or software or other systems or equipment), the Depositary or the Company is, directly or indirectly, prevented from, forbidden to or delayed in, or could be subject to any civil or criminal penalty on account of doing or performing and therefore does not do or perform, any act or thing that, by the terms of this Deposit Agreement or the Deposited Securities, it is provided shall be done or performed;
(ii) for any exercise of, or failure to exercise, any discretion provided for in this Deposit Agreement (including any determination by the Depositary to take, or not take, any action that this Deposit Agreement provides the Depositary may take);
(iii) for the inability of any Owner or Holder to benefit from any distribution, offering, right or other benefit that is made available to holders of Deposited Securities but is not, under the terms of this Deposit Agreement, made available to Owners or Holders; or
(iv) for any special, consequential or punitive damages for any breach of the terms of this Deposit Agreement. Where, by the terms of a distribution to which Section 4.1, 4.2 or 4.3 applies, or an offering to which Section 4.4 applies, or for any other reason, that distribution or offering may not be made available to Owners, and the Depositary may not dispose of that distribution or offering on behalf of Owners and make the net proceeds available to Owners, then the Depositary shall not make that distribution or offering available to Owners, and shall allow any rights, if applicable, to lapse.
Contractor’s Performance Warranties Contractor represents and warrants to the State that:
(i) Each and all of the services shall be performed in a timely, diligent, professional and skillful manner, in accordance with the highest professional or technical standards applicable to such services, by qualified persons with the technical skills, training and experience to perform such services in the planned environment.
(ii) Any time software is delivered to the State, whether delivered via electronic media or the internet, no portion of such software or the media upon which it is stored or delivered will have any type of software routine or other element which is designed to facilitate unauthorized access to or intrusion upon; or unrequested disabling or erasure of; or unauthorized interference with the operation of any hardware, software, data or peripheral equipment of or utilized by the State. Without limiting the generality of the foregoing, if the State believes that harmful code may be present in any software delivered hereunder, Contractor will, upon State’s request, provide a new or clean install of the software. Notwithstanding the foregoing, Contractor assumes no responsibility for the State’s negligence or failure to protect data from viruses, or any unintended modification, destruction or disclosure.
(iii) To the extent Contractor resells commercial hardware or software it purchased from a third party, Contractor will, to the extent it is legally able to do so, pass through any such third party warranties to the State and will reasonably cooperate in enforcing them. Such warranty pass-through will not relieve the Contractor from Contractor’s warranty obligations set forth herein.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
REMEDIES, CHARACTERIZATION, OTHER OBLIGATIONS, BREACHES AND INJUNCTIVE RELIEF The remedies provided in this Warrant shall be cumulative and in addition to all other remedies available under this Warrant and the other Transaction Documents, at law or in equity (including a decree of specific performance and/or other injunctive relief), and nothing herein shall limit the right of the Holder to pursue actual damages for any failure by the Company to comply with the terms of this Warrant. The Company covenants to the Holder that there shall be no characterization concerning this instrument other than as expressly provided herein. Amounts set forth or provided for herein with respect to payments, exercises and the like (and the computation thereof) shall be the amounts to be received by the Holder and shall not, except as expressly provided herein, be subject to any other obligation of the Company (or the performance thereof). The Company acknowledges that a breach by it of its obligations hereunder will cause irreparable harm to the Holder and that the remedy at law for any such breach may be inadequate. The Company therefore agrees that, in the event of any such breach or threatened breach, the holder of this Warrant shall be entitled, in addition to all other available remedies, to an injunction restraining any breach, without the necessity of showing economic loss and without any bond or other security being required. The Company shall provide all information and documentation to the Holder that is requested by the Holder to enable the Holder to confirm the Company’s compliance with the terms and conditions of this Warrant (including, without limitation, compliance with Section 2 hereof). The issuance of shares and certificates for shares as contemplated hereby upon the exercise of this Warrant shall be made without charge to the Holder or such shares for any issuance tax or other costs in respect thereof, provided that the Company shall not be required to pay any tax which may be payable in respect of any transfer involved in the issuance and delivery of any certificate in a name other than the Holder or its agent on its behalf.
Excused Performance 6.1 Notwithstanding the occurrence of a Force Majeure Event, in which case Clause 17 will govern, BT will not be liable for any failure or delay to perform any of its obligations under this Agreement (including any of its obligations to meet any Service Levels) to the extent that BT’s failure or delay in performing arises as a result of:
6.1.1 any failure or delay by the Customer to perform any of the Customer’s obligations under this Agreement;
6.1.2 any act or omission other than on the part of a BT Affiliate or a subcontractor or supplier appointed by it unless that BT Affiliate, subcontractor or supplier has invoked their force majeure rights under their contract with BT; or
6.1.3 Applicable Law, a court order, an application for interlocutory relief or injunction restricting or preventing BT from supplying a Service.
Prevention or Delay in Performance by the Depositary or the Company Neither the Depositary nor the Company nor any of their respective directors, employees, agents or affiliates shall incur any liability to any Owner or Holder (i) if by reason of any provision of any present or future law or regulation of the United States or any other country, or of any governmental or regulatory authority or stock exchange, or by reason of any provision, present or future, of the articles of association or similar document of the Company, or by reason of any provision of any securities issued or distributed by the Company, or any offering or distribution thereof, or by reason of any act of God or war or terrorism or other circumstances beyond its control, the Depositary or the Company shall be prevented, delayed or forbidden from, or be subject to any civil or criminal penalty on account of, doing or performing any act or thing which by the terms of this Deposit Agreement or the Deposited Securities it is provided shall be done or performed, (ii) by reason of any non-performance or delay, caused as aforesaid, in the performance of any act or thing which by the terms of this Deposit Agreement it is provided shall or may be done or performed, (iii) by reason of any exercise of, or failure to exercise, any discretion provided for in this Deposit Agreement, (iv) for the inability of any Owner or holder to benefit from any distribution, offering, right or other benefit which is made available to holders of Deposited Securities but is not, under the terms of this Deposit Agreement, made available to Owners or holders, or (v) for any special, consequential or punitive damages for any breach of the terms of this Deposit Agreement. Where, by the terms of a distribution pursuant to Section 4.01, 4.02 or 4.03, or an offering or distribution pursuant to Section 4.04, or for any other reason, such distribution or offering may not be made available to Owners, and the Depositary may not dispose of such distribution or offering on behalf of such Owners and make the net proceeds available to such Owners, then the Depositary shall not make such distribution or offering, and shall allow any rights, if applicable, to lapse.
Standard of Care; Performance of Employees Consultant shall perform all Services under this Agreement in a skillful and competent manner, consistent with the standards generally recognized as being employed by professionals in the same discipline in the State of California. Consultant represents and maintains that it is skilled in the professional calling necessary to perform the Services. Consultant agrees that all employees and subconsultants shall have sufficient skill and experience to perform the Services assigned to them. Finally, Consultant represents that it, its employees and subconsultants shall have all licenses, permits, qualifications and approvals of whatever nature that are legally required to perform the Services, including a City Business License, and that such licenses and approvals shall be maintained throughout the Term of this Agreement. As provided for in the indemnification provisions of this Agreement, Consultant shall perform, at its own cost and expense and without reimbursement from the City, any services necessary to correct errors or omissions which are caused by the Consultant’s failure to comply with the standard of care provided for herein. Any employee of the Consultant or its sub-consultants who is determined by the City to be uncooperative, incompetent, a threat to the adequate or timely completion of the Project, a threat to the safety of persons or property, or any employee who fails or refuses to perform the Services in a manner acceptable to the City, shall be promptly removed from the Project by the Consultant and shall not be re-employed to perform any of the Services or to work on the Project.
Remedies, Characterizations, Other Obligations, Breaches and Injunctive Relief The remedies provided in this Note shall be cumulative and in addition to all other remedies available under this Note and any of the other Transaction Documents at law or in equity (including a decree of specific performance and/or other injunctive relief), and nothing herein shall limit the Holder’s right to pursue actual and consequential damages for any failure by the Company to comply with the terms of this Note. The Company covenants to the Holder that there shall be no characterization concerning this instrument other than as expressly provided herein. Amounts set forth or provided for herein with respect to payments, conversion and the like (and the computation thereof) shall be the amounts to be received by the Holder and shall not, except as expressly provided herein, be subject to any other obligation of the Company (or the performance thereof). The Company acknowledges that a breach by it of its obligations hereunder will cause irreparable harm to the Holder and that the remedy at law for any such breach may be inadequate. The Company therefore agrees that, in the event of any such breach or threatened breach, the Holder shall be entitled, in addition to all other available remedies, to an injunction restraining any such breach or any such threatened breach, without the necessity of showing economic loss and without any bond or other security being required. The Company shall provide all information and documentation to the Holder that is requested by the Holder to enable the Holder to confirm the Company’s compliance with the terms and conditions of this Note.
