Acceptance of Leased Premises On or before the Possession Date, Tenant and Landlord shall each execute the letter agreement in the form attached hereto as Exhibit E (the “Letter Agreement”). By its execution of the Letter Agreement or occupancy of the Leased Premises, Tenant shall be deemed to represent and certify that it has examined the Leased Premises and that it thereby accepts the Leased Premises in its condition at the time, except for the list of defects and/or omissions identified in writing prior to the Possession Date (the “Punch-List”) and latent defects, but subject, in all cases, to Landlord’s repair, maintenance and replacement obligations set forth in this Lease and to the warranty related to the Tenant Improvements, as provided in the Work Letter Agreement. After the notice provided in Section 3.03 and prior to the Possession Date, the parties shall meet in the Leased Premises to establish the Punch-List. Landlord shall review the Punch-List items with Tenant and correct all undisputed Punch- List items within a reasonable time, not to exceed thirty (30) days after receipt of the Punch- List; provided that, if any Punch-List items cannot be corrected within such thirty (30) day period despite reasonable diligence by Landlord, then, so long as Landlord commences correction of such Punch-List items within such thirty (30) day period and diligently pursues such correction to completion, no default by Landlord shall be deemed to have occurred. Punch-List items for completion taking longer than six (6) months to complete (and not otherwise the result of Force Majeure, Tenant Delay, or the COVID-19 Condition) shall trigger a day for day prorated Minimum Monthly Rent abatement. The Tenant Improvements shall be subject to a two (2) year warranty, from the Possession Date, with regard to materials, design and workmanship, as provided in more detail in the Work Letter Agreement. Tenant shall reasonably cooperate with Landlord in providing required information as needed for Landlord to pursue vendor warranties on a timely basis, as requested in writing by Landlord. Landlord will pursue any valid warranty claims against its contractor beyond the two (2) year warranty provided that any expenses incurred and/or any recovery obtained shall be treated as either additional Operating Costs or an offset to Operating Costs under Section 5.03(a).
Inspection of Premises Landlord and Landlord's agents shall have the right at all reasonable times during the term of this Agreement and any renewal thereof to enter the Premises for the purpose of inspecting the Premises and all buildings and improvements thereon. And for the purposes of making any repairs, additions or alterations as may be deemed appropriate by Landlord for the preservation of the Premises or the building. Landlord and its agents shall further have the right to exhibit the Premises and to display the usual "for sale", "for rent" or "vacancy" signs on the Premises at any time within forty-five (45) days before the expiration of this Lease. The right of entry shall likewise exist for the purpose of removing placards, signs, fixtures, alterations or additions, that do not conform to this Agreement or to any restrictions, rules or regulations affecting the Premises.
POSSESSION OF PREMISES Tenant shall not be entitled to possession of the premises designated for lease until the security deposit and first month’s rent (or prorated portion thereof), less any applicable promotional discount, is paid in full and the premises designated for lease is vacated by the prior tenant.
Delivery of Premises If the Landlord shall be unable to give possession of the Premises, exclusively the Suite 200 Premises and the Suite 246 Premises, on the Fourth Expansion Premises Commencement Date by reason of (i) the Landlord work is not substantially complete, (ii) the holding over or retention of possession of any tenant, tenants or occupants, or (iii) for any other reason, then Landlord shall not be subject to any liability for the failure to give possession on said date. Under such circumstances the Base Rent to be paid herein shall not commence until the Premises (exclusively the Suite 200 Premises and the Suite 246 Premises) are made available to Tenant by Landlord, and no such failure to give possession on the Fourth Expansion Premises Commencement Date shall affect the validity of this Sixth Amendment to Office Building Lease or the obligations of the Tenant hereunder. The Base Rents due hereunder will be adjusted at the time that any or all of the Fourth Expansion Premises are delivered to Tenant substantially complete to reflect the same underlying effective rent of the rent structure specific to each suite with the lease expiration dates to remain unchanged. Notwithstanding the foregoing, if the Fourth Expansion Premises Commencement Date for the Suite 200 Premises together with the Suite 246 Premises has not occurred within ninety (90) days after the Fourth Expansion Premises Commencement Date, the Tenant, by written notice to the Landlord given within ten (10) days after the expiration of such ninety (90) day period, may terminate the Sixth Amendment to Office Building Lease without any liability to the Landlord. Separately, if the Fourth Expansion Premises Commencement Date-Suite 240 Premises has not occurred within ninety (90) days after the Fourth Expansion Premises Commencement Date-Suite 240 Premises, the Tenant, by written notice to the Landlord given within ten (10) days after the expiration of such ninety (90) day period, may terminate the terms of lease for the Suite 240 Premises in the Sixth Amendment to Office Building Lease for the Suite 240 Premises not delivered in said time frame without any liability to the Landlord. If Landlord’s failure to complete Tenant’s improvements within ninety (90) days after the Fourth Expansion Premises Commencement Date and/or Fourth Expansion Premises Commencement Date-Suite 240 Premises is result of Tenant Delay, Tenant shall not have the option to terminate the Sixth Amendment to Office Building Lease or the terms of lease for the Suite 240 Premises in the Sixth Amendment to Office Building Lease.
DESCRIPTION OF LEASED PREMISES The Lessor agrees to lease to the Lessee the following described square feet (SF) of Additional Description: Hereinafter known as the “Premises”.
CONSTRUCTION OF PREMISES A. Lessor agrees that it will supply, at its own expense, its standard office space, as more particularly described and set forth on Exhibit “B” annexed hereto and made a part hereof (“Lessor’s Work”). /s/ Lessor /s/ Lessee
B. Lessee agrees to perform, at its own cost and expense, all work other than Lessor’s Work, including without limitation that work, as particularly described in Exhibit “E” annexed hereto (“Lessee’s Work”), which is necessary to make the Premises conform with Lessee’s plans as approved by Lessor. Within thirty (30) days after the execution of this Lease, Lessee shall furnish to Lessor, for Lessor’s written approval, plans and specifications for the Lessee’s Work, showing a layout, lighting plan, fixturing plan, interior finish and material samples, and any work or equipment to be done or installed by Lessee affecting any structural, mechanical or electrical part of the Premises or the Building. Failure to provide same within said thirty (30) day period shall constitute a default by Lessee under this Lease. Lessor’s failure to disapprove of Lessee’s plans within fifteen (15) days of receipt shall constitute acceptance by Lessor of such plans. Design elements as aforesaid will be displayed in color renderings in such detail as may be sufficient for Lessor’s needs. It is the purpose of this requirement that Lessee’s Premises be fixtured, designed and laid out so as not to be a detriment to the other tenants in the Building and that Lessee’s Work shall not be detrimental to the Building or other tenants therein, and Lessor’s approval of the plans and specifications as aforesaid for Lessee’s Work shall be at the Lessor’s sole discretion. Lessee agrees and acknowledges that all Lessee’s Work, improvements, alterations or additions performed by Lessee (hereinafter collectively “Alterations”) whether pursuant to this Section or otherwise, shall be carried out in compliance with all Requirements and is performed and accomplished solely for the benefit and convenience of Lessee, and not for the benefit of Lessor, such Alterations being nevertheless subject to each and every of the provisions of this Lease,.
Delivery of Possession Landlord shall be deemed to have delivered possession of the Premises to Tenant on the Commencement Date, as it may be adjusted pursuant to the Workletter. Landlord shall construct or install in the Premises the improvements to be constructed or installed by Landlord according to the Workletter. If no Workletter is attached to this Lease, it shall be deemed that Landlord delivered to Tenant possession of the Premises "as is" in its present condition on the Commencement Date. Tenant acknowledges that neither Landlord nor its agents or employees have made any representations or warranties as to the suitability or fitness of the Premises for the conduct of Tenant's business or for any other purpose, nor has Landlord or its agents or employees agreed to undertake any alterations or construct any Tenant improvements to the Premises except as expressly provided in this Lease and the Workletter. If for any reason Landlord cannot deliver possession of the Premises to Tenant on the Commencement Date, this Lease will not be void or voidable, Landlord will not be liable to Tenant for any resulting loss or damage and the Term of this Lease shall not be extended by a delayed delivery of possession. The preceding sentence notwithstanding, if Landlord fails to deliver possession to Tenant within sixty (60) days after the Commencement Date for any reason other than a Delay Caused by Tenant, as defined in the Workletter, Tenant, as its sole remedy, shall have the right to terminate this Lease and receive a refund of all prepaid Rent and Security Deposits provided Tenant gives written notice of termination to Landlord within three (3) days after that date. Tenant will execute the Commencement Date Certificate attached to this Lease as Exhibit E, appropriately completed, within fifteen (15) days of Landlord's request.
Condition of Leased Premises Tenant hereby acknowledges that Xxxxxx has examined the leased premises prior to the signing of this Lease, or knowingly waived said examination. Tenant acknowledges that Tenant has not relied on any representations made by Landlord or Landlord’s agents regarding the condition of the leased premises and that Tenant takes premises in its AS-IS condition with no express or implied warranties or representations beyond those contained herein or required by applicable Georgia law. Xxxxxx agrees not to damage the premises through any act or omission, and to be responsible for any damages sustained through the acts or omissions of Tenant, Xxxxxx’s family or Xxxxxx’s invitees, licensees, and/or guests. If such damages are incurred, Tenant is required to pay for any resulting repairs at the same time and in addition to the next month’s rent payment, with consequences for non-payment identical to those for non- payment of rent described herein. At the expiration or termination of the Lease, Tenant shall return the leased premises in as good condition as when taken by Tenant at the commencement of the lease, with only normal wear-and-tear excepted. Any modification of this lease shall not be binding upon Landlord unless in writing and signed by Landlord or Landlord’s authorized agent. No oral representation shall be effective to modify this Lease. If, as per the terms of this paragraph, any provision of this lease is newly added, modified, or stricken out, the remainder of this Lease shall remain in full force and effect.
Landlord’s Option to Repair Notwithstanding the terms of Section 11.1 of this Lease, Landlord may elect not to rebuild and/or restore the Premises, Building and/or Project, in which event this Lease shall terminate, by notifying Tenant in writing of such termination within sixty (60) days after the date of discovery of the damage, such notice will include a termination date giving Tenant sixty (60) days to vacate the Premises, but this Lease may be so terminated Landlord may so elect only if the Building or Project shall be damaged by fire or other casualty or cause, whether or not the Premises are affected, and one or more of the following conditions is present: (i) in Landlord’s reasonable judgment, repairs cannot reasonably be completed within one hundred eighty (180) days after the date of discovery of the damage (when such repairs are made without the payment of overtime or other premiums); (ii) the holder of any mortgage on the Building or Project or ground lessor with respect to the Building or Project shall require that the insurance proceeds or any portion thereof be used to retire the mortgage debt, or shall terminate the ground lease, as the case may be; (iii) the damage is not fully covered by Landlord’s insurance policies or that portion of the proceeds from Landlord’s insurance policies allocable to the Building or the Project, as the case may be; (iv) Landlord decides to rebuild the Building or Common Areas so that they will be substantially different structurally or architecturally; (v) the damage occurs during the last twelve (12) months of the Lease Term; or (vi) any owner of any other portion of the Project, other than Landlord, does not intend to repair the damage to such portion of the Project; provided, however, that if such fire or other casualty shall have damaged the Premises or a portion thereof or Common Areas necessary to Tenant’s occupancy and as a result of such damage the Premises are unfit for occupancy, and provided that Landlord does not elect to terminate this Lease pursuant to Landlord’s termination right as provided above, and either (a) the repairs cannot, in the reasonable opinion of Landlord’s contractor, be completed within two hundred seventy (270) days after being commenced, or (b) the damage occurs during the last twelve months of the Lease Term and will reasonably require in excess of ninety (90) days to repair, Tenant may elect, no earlier than sixty (60) days after the date of the damage and not later than ninety (90) days after the date of such damage, to terminate this Lease by written notice to Landlord effective as of the date specified in the notice, which date shall not be less than thirty (30) days nor more than sixty (60) days after the date such notice is given by Tenant.
NON-DELIVERY OF POSSESSION In the event Landlord cannot deliver possession of the Premises to Tenant upon the commencement of the Lease term, through no fault of Landlord or its agents, then Landlord or its agents shall have no liability, but the rental herein provided shall xxxxx until possession is given. Landlord or its agents shall have thirty (30) days in which to give possession, and if possession is tendered within such time, Tenant agrees to accept the demised Premises and pay the rental herein provided from that date. In the event possession cannot be delivered within such time, through no fault of Landlord or its agents, then this Agreement and all rights hereunder shall terminate.
