PROGRESS OF THE WORK. Notwithstanding any other provision of the Contract Documents, if Contractor fails or refuses, for any reason and at any time, to furnish adequate materials, labor, equipment, tools and/or services to maintain the progress of the Work, District may, in its sole discretion, after seventy-two (72) hours’ advance written notice of same from District to Contractor, direct, instruct, and authorize a separate contractor selected by District to furnish such materials, labor, equipment, tools and/or services necessary to maintain progress of the Work. District may in its discretion deduct the amount of any and all costs, expenses, and/or other charges incurred thereby from the Contract Price then or thereafter due Contractor.
PROGRESS OF THE WORK. 2.2.1 The Contractor shall at all times carry out and complete the Work in accordance with any Work Plan and/or time schedule for the Work specified in the Work Order (s) or if none is specified such other work plan and/or time schedule as may be agreed between the Parties (the “Work Plan”).
2.2.2 As soon as possible, but within 3 (Three) working days of receipt of a Work Order, the Contractor shall submit a Work Plan showing the ‘Time and Progress Chart’ for each milestone within the Time for Completion. The Officer in Charge may within 7 (seven) working days thereafter, if required modify and communicate the Work Plan approved to the Contractor, failing which the Work Plan submitted by the Contractor shall be deemed to be approved by the Officer in Charge.
2.2.3 In case of non-submission of Work Plan by the Contractor, the Work Plan as may be issued by the Officer in Charge shall be deemed to be final. The issuance of and/or deemed approval of such Work Plan by the Officer in Charge shall not relieve the Contractor of any of the obligations under the Contract.
2.2.4 The Contractor shall submit the Work Plan including the ‘Time & Progress Chart’ and Progress Report using the mutually agreed software or in other format decided by Corporation for the work done during previous month to the Corporation on or before 5th day of each month, failing which a recovery as per Appendix-7 to be decided by the Corporation, shall be made on per week or part basis in case of delay in submission of the monthly progress report.
2.2.5 The Contractor shall use the Work Plan as the basis for progress reporting, scheduling, forecasting and controlling performance of the Work. If at any time the progress of the Work does not comply with the Work Plan, the Contractor shall immediately inform the Corporation and shall take all necessary action to re-establish progress in accordance with the Work Plan.
PROGRESS OF THE WORK. A. Contractor shall perform all work during the hours of 7:00 a.m. to 3:30 p.m., Monday through Friday unless otherwise specified in the Special Provisions or authorized by the City in writing. If the Contractor wishes to work during any other hours or on weekends, written permission must be received from the City. The request must be received at least two (2) working days in advance of any work. No work will be allowed on legal holidays except in the case of an emergency. A listing of holidays observed by City is on file in the office of the Administrator. If Contractor requests overtime work in which the City will incur costs, Contractor shall be responsible for payment of the City’s costs incurred in connection with the overtime work. The City will invoice the Contractor at time and one half to cover the costs incurred. If Contractor does not pay the invoice within ten days, the City may deduct the amount billed from other payments due or to become due to Contractor under the Contract.
B. The Administrator or Administrator’s designee shall have the authority to suspend the Work, wholly or in part, for such a period as the Administrator may deem necessary.
PROGRESS OF THE WORK. The Contractor shall provide sufficient labor, materials, facilities, and equipment and shall work such hours, including night shifts, overtime operations, Saturdays, Sundays and holidays, as may be necessary to insure the prosecution and completion of the Work or separable portions thereof, in accordance with the Guaranteed Project Schedule. If the progress of the Work falls behind or fails to proceed in accordance with the Guaranteed Project Schedule, or it becomes apparent to the Owner from the current schedule that the Work will not be substantially complete within the Contract Time (as adjusted by Owner approved Change Orders), in addition to the other requirements of the Contract and remedies available to the Owner, the Contractor agrees to take the following actions at no additional cost to the Owner to correct such tardiness:
i. Increase manpower in such quantities and crafts as will substantially eliminate, in the judgment of the Owner, the backlog of Work;
ii. Increase the number of working hours per shift, shifts per working day, working days per week, the amount of equipment, or any combination of the foregoing, sufficient to substantially eliminate, in the judgment of the Owner, the backlog of Work; and,
iii. Reschedule activities to achieve maximum practical concurrence of accomplishment of activities. The failure of the Contractor to comply with the requirements of this Section or to remedy the tardiness shall be grounds for a determination by the Owner that the Contractor is failing to diligently prosecute the Work, in which case the Owner may, after the notice of the breach has been provided to the Contractor pursuant to Section 10.01 (Definition of Breach) of the Contract, without prejudice to other remedies the Owner may have and regardless of whether the Contractor has taken or is taking corrective action, immediately correct the Contractor’s failure at the Contractor’s expense by exercising the right to perform and carry out the work as provided in Section 10.05 (Owner’s Right to Carry Out the Work) including the use of the Owner’s work forces, to award separate contracts, to supplement the Contractor’s work forces, to prepare or have prepared schedules which shall be used to determine the provisions of the Contract to withhold actual and anticipated liquidated damages, and any other means the Owner deems appropriate.
PROGRESS OF THE WORK. If for any reason whatsoever other than those specified in clause 13 below the contractor’s preparation for the commencement of the work or any portion of it, or his subsequent rate of progress be so slow, that in the opinion of the Inspecting Authority whose decision shall be final, the contractor shall be unable to complete the work as agreed upon or should the contractor fail to deliver the vehicles in conformity with the contract in any respect fail to perform the contract except for any reason other than those specified in clause 13 below, or should be adjusted insolvent, or have receiving order made against him or made or enter into any arrangement or composition with his creditors, or suspend payment or being a company is wound up (either compulsory or voluntary), the President of India shall have the power to terminate the contract by notice in writing, in which case the contractor shall be held liable for liquidated damages for delay and for any expense, loss or damage which the President of India may be put to incur or sustain by reason of the termination mentioned above. 14 days notice shall be given to the contractor if the contract is terminated before the expiry of the stipulated date of delivery or the extension thereof.
PROGRESS OF THE WORK. Contractor shall keep Company fully informed on a timely basis of the progress of operations and results obtained during the course of the Work hereunder and shall consult with Company’s Representative(s) concerning planning of the Work and the seismic data collected. Progress reports shall be furnished by Contractor as provided in Clause 6 below.
PROGRESS OF THE WORK. The Contractor shall furnish to the College an itemized breakdown of the Contractor’s Work operations together with duration time for each in order to meet the schedule set forth in Section 3.01 above. The Contractor shall cooperate with the College in working out the proper sequence of operations between the Work of the Contractor and that of other trades on the site, if any. The Contractor’s schedule for the Work, when approved by the College, shall determine the time and sequence of performance by the Contractor.
PROGRESS OF THE WORK. The XXXX shall cooperate with the Owner in order to maintain the progress of the Work in accordance with the GMP schedule. or as modified by a GMP Modification. If the Owner determines that the XXXX is failing to maintain the progress of the Work, through no fault of the Owner, the XXXX must, within seventy-two (72) hours of written request of the Owner, submit a written response detailing the XXXX’x plan of action to recover lost time in order to maintain the progress of the Work in accordance with the accepted schedule. In such event, the XXXX shall comply with the Owner's written orders to take whatever steps are necessary to recover lost time and maintain the progress of the Work. These steps may include, but are not limited to, re-sequencing the Work activities, increasing the number of shifts, workforce, supervision, work days, overtime operations, equipment resources, or expediting delivery of materials or equipment. Regardless of the manner in which the schedule is recovered, the XXXX shall not be entitled to additional compensation for actions that relate to the recovery of the schedule.
PROGRESS OF THE WORK. Unless otherwise approved, Owner and Construction Manager will perform their respective obligations under the Contract as expeditiously as is consistent with reasonable skill and care and the orderly progress of the Work.
PROGRESS OF THE WORK. Sub-contractor agrees to commence work on the jobsite within forty-eight (48) hours after notice from contractor to commence work and to complete all required no later than calendar days after notice to commence work.
