Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Repairs Tenant shall, at Tenant’s own expense, keep the Premises, including all improvements, fixtures, furnishings, and systems and equipment to the extent located therein (including plumbing fixtures and equipment such as dishwashers, garbage disposals, refrigerators, coffee makers and Insta Hot and similar dispensers), and the portion of the floor or floors of the Building on which the Premises are located, in good order, repair and condition at all times during the Lease Term. In addition, Tenant shall, at Tenant’s own expense, but under the supervision and subject to the prior approval of Landlord, and within any reasonable period of time specified by Landlord, promptly and adequately repair all damage to the Premises and replace or repair all damaged, broken, or worn fixtures and appurtenances, except for damage caused by ordinary wear and tear or beyond the reasonable control of Tenant; provided however, that, at Landlord’s option, or if Tenant fails to make such repairs, Landlord may, but need not, make such repairs and replacements, and Tenant shall pay Landlord the cost thereof, including a fifteen percent (15%) supervisory fee forthwith upon being billed therefor. Notwithstanding the foregoing, Landlord shall be responsible for repairs to the exterior walls, foundation and roof of the Building, the structural portions of the floors of the Building, and the base building systems and equipment of the Building, except to the extent that such repairs are required due to the negligence or willful misconduct of Tenant; provided, however, that if such repairs are due to the negligence or willful misconduct of Tenant, Landlord shall nevertheless make such repairs at Tenant’s expense, or, if covered by Landlord’s insurance, Tenant shall only be obligated to pay any deductible in connection therewith. Landlord may, but shall not be required to, enter the Premises at all reasonable times to make such repairs, alterations, improvements or additions to the Premises or to the Project or to any equipment located in the Project as Landlord shall desire or deem necessary or as Landlord may be required to do by governmental or quasi-governmental authority or court order or decree. Tenant hereby waives any and all rights under and benefits of subsection 1 of Section 1932 and Sections 1941 and 1942 of the California Civil Code or under any similar law, statute, or ordinance now or hereafter in effect.
Base Building Work Landlord shall construct the Base Building Work as further set forth on Exhibit 10.03, attached.
Unavoidable Delays Delays due to acts of God, acts of public agencies, labor disputes, strikes, fires, freight embargoes, inability (despite the exercise of due diligence) to obtain supplies, materials, fuels or permits, or other causes or contingencies (excluding financial inability) beyond the reasonable control of Landlord or Tenant, as applicable. Landlord shall use commercially reasonable efforts to provide Tenant with prompt notice of any Unavoidable Delays.
Maintenance Repairs and Alterations Landlord hereby covenants that the Premises shall be in reasonably good and usable condition as of the effective date of this Agreement. Replacements made by Landlord, if any, shall belong to it. Landlord shall keep access to the Premises free and clear of any and all obstructions including snow and ice. ** Portions of this agreement have been omitted and filed separately with the SEC pursuant to a confidential treatment request CONFIDENTIAL EXECUTION VERSION In the event of an emergency, Tenant shall have the right to perform any obligation of Landlord under this Agreement and recover from Landlord any reasonable amounts so expended by Tenant within thirty (30) days of the date of demand or, in the alternative, to offset amounts so expended against Rent. Landlord shall, at its sole expense, make structural repairs and replacements to the footings, foundation and structural elements of walls and roofs of the Premises and also shall be responsible for maintenance, repairs and replacements, at its sole expense, of heating, ventilating, air conditioning systems, plumbing systems, and electrical systems, provided, however, that Tenant, at its sole expense, shall be responsible for maintenance, repairs and replacements regarding the irrigation system on the Premises as well as Tenant's occupancy costs as described above in Section 4 of this Agreement and shall also be responsible for maintenance, repairs or replacements necessitated by Tenant's actions. Contact information for the Landlord in case of any maintenance, repair or replacement issues is as follows: [**]1 Additions, improvements and alterations made by Tenant, whether temporary or permanent in nature, shall be subject to the prior approval of Landlord and upon completion shall belong to Tenant, provided that removal may be made without damage to the Premises at the expiration of the Agreement term. If removal of the improvements or alterations would cause damage to the Premises, said improvements and alterations shall automatically become the property of Landlord. Tenant, at its sole expense, shall be responsible for maintenance, repairs and replacements of any additions, improvements or alterations made by Tenant on, in or to the Premises. Tenant shall keep the Premises in good order, repair and condition at all times during the Agreement term, except for ordinary wear and tear.
Tenant’s Repairs Subject to Section 13 hereof, Tenant, at its expense, shall repair, replace and maintain in good condition all portions of the Premises, including, without limitation, entries, doors, ceilings, interior windows, interior walls, and the interior side of demising walls. Such repair and replacement may include capital expenditures and repairs whose benefit may extend beyond the Term. Should Tenant fail to make any such repair or replacement or fail to maintain the Premises, Landlord shall give Tenant notice of such failure. If Tenant fails to commence cure of such failure within 10 days of Landlord’s notice, and thereafter diligently prosecute such cure to completion, Landlord may perform such work and shall be reimbursed by Tenant within 10 days after demand therefor; provided, however, that if such failure by Tenant creates or could create an emergency, Landlord may immediately commence cure of such failure and shall thereafter be entitled to recover the costs of such cure from Tenant. Subject to Sections 17 and 18, Tenant shall bear the full uninsured cost of any repair or replacement to any part of the Project that results from damage caused by Tenant or any Tenant Party and any repair that benefits only the Premises.
Construction of the Tenant Improvements Landlord shall construct the Tenant Improvements in accordance with this exhibit and the construction contract to be executed by Landlord and its contractor(s). The construction contract for constructing the Tenant Improvements and the contractor(s) to perform the work shall be approved and/or selected, as the case may be, by Landlord at its sole and absolute discretion without the consent of Tenant.
Tenant Delay If the Substantial Completion of the Tenant Improvement Work is delayed (a “Tenant Delay”) as a result of (a) any failure of Tenant to approve the Construction Pricing Proposal pursuant to Section 2.6 above on or before Tenant’s Approval Deadline; (b) Tenant’s failure to timely approve any matter requiring Tenant’s approval; (c) any breach by Tenant of this Work Letter or the Lease; (d) any request by Tenant for a revision to the Approved Construction Drawings (except to the extent such delay results from any failure of Landlord to perform its obligations under Section 2.7 above); (e) Tenant’s requirement for materials, components, finishes or improvements that are not available in a commercially reasonable time given the anticipated date of Substantial Completion of the Tenant Improvement Work as set forth in this Agreement; (f) any change to the base, shell or core of the Premises or Building required by the Approved Construction Drawings; or (g) any other act or omission of Tenant or any of its agents, employees or representatives, then, notwithstanding any contrary provision of this Agreement, and regardless of when the Tenant Improvement Work is actually Substantially Completed, the Tenant Improvement Work shall be deemed to be Substantially Completed on the date on which the Tenant Improvement Work would have been Substantially Completed if no such Tenant Delay had occurred.
Tenant’s Repair Obligations During the Lease Term, Tenant shall promptly make all repairs, perform all maintenance, and make all replacements in and to the Premises (provided however, that with respect to the Roof Terrace, Tenant shall only be required to make such maintenance or repairs (i) required to be made to any Alterations to the Roof Terrace or Tenant’s Property on the Roof Terrace made or installed by Tenant, (ii) required by reason of any such Alterations or Tenant’s Property, and (iii) required by reason of Tenant’s or any of its Invitees damage, regardless if caused by such party’s negligence or intentional misconduct) that are necessary or desirable to keep the Premises in good condition and repair, in a clean, safe and tenantable condition, and otherwise in accordance with all Requirements and the requirements of this Lease applicable to Tenant. Tenant shall maintain all fixtures, furnishings and equipment and lighting fixtures and bulbs located in, or exclusively serving, the Premises in clean, safe and sanitary condition, shall take good care thereof and make all required repairs and replacements thereto. Tenant shall give Landlord prompt written notice upon Tenant obtaining actual knowledge of any defects or damage to the structure of, or equipment or fixtures in, the Building or any part thereof. Tenant shall suffer no waste or injury to any part of the Premises and shall, at the expiration or earlier termination of the Lease Term, surrender the Premises broom clean in an order and condition at least equal to the order and condition on applicable date that each such portion of the Premises was delivered to Tenant (and with respect to any Must Take Expansion Premises, as of the date Tenant first commences business operating within such Must Take Expansion Premises), subject to subsequent Alterations, ordinary wear and tear and as otherwise provided in Article XVII (Damage or Destruction). Except as otherwise provided in Article XVII (Damage or Destruction), all injury, breakage and damage to the Premises and to any other part of the Building or the Land caused by any act or omission of any Invitees or Tenant, shall be repaired by and at Tenant’s expense, except that Landlord shall have the right at Landlord’s option to make any such repair and to charge Tenant for all costs and expenses incurred in connection therewith.
