ADDITIONS AND DELETIONS The author of this document has added information needed for its completion. The author may also have revised the text of the original AIA standard form. An Additions and Deletions Report that notes added information as well as revisions to the standard form text is available from the author and should be reviewed. A vertical line in the left margin of this document indicates where the author has added necessary information and where the author has added to or deleted from the original AIA text. This document has important legal consequences. Consultation with an attorney is encouraged with respect to its completion or modification.
Alterations, Modifications and Additions Company will, or will cause a Permitted Lessee to, make (or cause to be made) such alterations and modifications in and additions to the Airframe and the Engines as are required from time to time to meet the applicable requirements of the FAA or any applicable government of any other jurisdiction in which the Aircraft is then registered; except for (i) immaterial and non-recurring violations with respect to which corrective measures are being taken promptly by Company (or, if a Lease is then in effect, any Permitted Lessee) upon discovery thereof and (ii) any law, rule, regulation or order the validity or application of which is being contested in good faith by Company (or, if a Lease is then in effect, any Permitted Lessee) in any manner which does not involve any material risk of sale, loss or forfeiture of the Aircraft and does not materially adversely affect Loan Trustee’s interest in the Aircraft. In addition, Company (or any Permitted Lessee), at its own expense, may from time to time add further parts or accessories and make or cause to be made such alterations and modifications in and additions to the Airframe or any Engine as Company (or any Permitted Lessee) deems desirable in the proper conduct of its business, including, without limitation, removal (without replacement) of Parts; provided that no such alteration, modification or addition shall materially diminish the value or utility of the Airframe or such Engine below its value or utility immediately prior to such alteration, modification or addition, assuming that the Airframe or such Engine was then in the condition required to be maintained by the terms of this Indenture, except that the value (but not the utility) of the Airframe or any Engine may be reduced by the value of any such Parts that are removed that Company (or such Permitted Lessee) deems obsolete or no longer suitable or appropriate for use on the Airframe or any Engine. For the avoidance of doubt, Company may make alterations in the passenger configuration of the Aircraft and such alterations shall not be subject to the immediately preceding sentence. All Parts incorporated or installed in or attached or added to the Airframe or any Engine as the result of such alteration, modification or addition shall, without further act, be subject to the Lien of this Indenture. Notwithstanding the foregoing, Company (or any Permitted Lessee) may, at any time, remove any Part from the Airframe or any Engine if such Part: (i) is in addition to, and not in replacement of or substitution for, any Part originally incorporated or installed in or attached to the Airframe or such Engine at the time of delivery thereof to Company or any Part in replacement of, or substitution for, any such Part, (ii) is not required to be incorporated or installed in or attached or added to the Airframe or such Engine pursuant to the first sentence of this Section 7.04(c) and (iii) can be removed from the Airframe or such Engine without materially diminishing the value or utility required to be maintained by the terms of this Indenture that the Airframe or such Engine would have had had such Part never been installed on the Airframe or such Engine. Upon the removal by Company (or any Permitted Lessee) of any Part as permitted by this Section 7.04(c), such removed Part shall, without further act, be free and clear of all rights and interests of Loan Trustee and the Lien of this Indenture and shall no longer be deemed a Part hereunder. Upon request of Company from time to time, Loan Trustee shall execute and deliver to Company instruments reasonably requested by Company confirming the release of any such removed Part from the Lien of this Indenture. Loan Trustee acknowledges that it has no interest in the Excluded Equipment. Notwithstanding the provisions of this Section 7.04(c) or any other term or condition of this Indenture, Company (or any Permitted Lessee) may from time to time install on, and remove from, the Aircraft equipment that is owned by, leased to or conditionally sold to Company (or any Permitted Lessee) (and title to such equipment shall remain vested in Company, such Permitted Lessee, or the lessor or the conditional vendor thereof) if (1) such equipment is Excluded Equipment and (2) the location affected by any such removal, if damaged, is repaired prior to return, in a workmanlike manner, to a condition suitable for commercial passenger service; provided that all costs of installation, removal and replacement shall be the responsibility of Company.
Description of Goods or Services and Additional Terms and Conditions The Contractor shall perform as set forth in Exhibit A. For purposes of this Contract, to perform and the performance in Exhibit A is referred to as “Perform” and the “Performance.”
Alterations and Amendments This Agreement, applicable fees and service charges may be altered or amended from time-to-time. In such event, we will provide notice to you. Any use of the Service after we provide you a notice of change will constitute your agreement to such change(s). Further, we may, from time to time, revise or update the applications, services, and/or related material, which may render all such prior versions obsolete. Consequently, we reserve the right to terminate this Agreement as to all such prior versions of the applications, services, and/or related material and limit access to only the Service's more recent revisions and updates.
ALTERATIONS AND ADDITIONS Tenant shall not make, or suffer to be made, any alteration or addition to the Premises, or any part thereof, without the written consent of Landlord first had and obtained by Tenant, but at the cost of Tenant, and any addition to, or alteration of, the Premises, except moveable furniture and trade fixtures, shall at once become a part of the Premises and belong to Landlord. If Landlord consents to the making of any alteration, addition, or improvement to or of the Premises by Tenant, the same shall be made by Landlord at Tenant’s sole cost and expense. Any modifications to the building or building systems required by governmental code or otherwise as a result of Tenant’s alterations, additions or improvements shall be made at Tenant’s sole cost and expense. Tenant shall retain title to all moveable furniture and trade fixtures placed in the Premises. All heating, lighting, electrical, air conditioning, partitioning, drapery, carpeting and floor installations made by Tenant, together with all property that has become an integral part of the Premises, shall not be deemed trade fixtures. Tenant agrees that it will not proceed to make any alterations or additions, without having obtained consent from Landlord to do so, and until five (5) days from the receipt of such consent, in order that Landlord may post appropriate notices to avoid any liability to contractors or material suppliers for payment for Tenant’s improvements. Tenant will at all times permit such notices to be posted and to remain posted until the completion of work. Tenant shall, if required by Landlord, secure at Tenant’s own cost and expense, a completion and lien indemnity bond, satisfactory to Landlord, for such work. Tenant further covenants and agrees that any mechanic’s lien filed against the Premises or against the Complex for work claimed to have been done for, or materials claimed to have been furnished to Tenant, will be discharged by Tenant, by bond or otherwise, within ten (10) days after the filing thereof, at the cost and expense of Tenant. Any exceptions to the foregoing must be made in writing and executed by both Landlord and Tenant. Pursuant to California Civil Code Section 1938, Landlord hereby notifies Tenant that as of the Effective Date, the Premises and Building have not undergone inspection by a “Certified Access Specialist” to determine whether the Premises meets all applicable construction related accessibility standards under California Civil Code Section 55.53
Definitions and Other Provisions of General Application SECTION 101.
Amounts and Terms of the Advances and Letters of Credit SECTION 2.01. The Advances and Letters of Credit.
Modifications and Amendments The terms and provisions of this Agreement may be modified or amended only by written agreement executed by all parties hereto.
SUPERVISION AND CONSTRUCTION PROCEDURES 4.3.1 The Contractor shall supervise and direct the Work, using his / her best skill and attention. The Contractor shall be solely responsible for all construction means, methods, techniques, sequences and procedures and for coordinating all portions of the Work under the Contract. All aspects of the Project shall be subject to the inspection and approval of the State. Contractor guarantees to repair, replace, re-execute or otherwise correct any defect in workmanship, materials, or the like that fails to conform to the requirements of this Contract or that appears during the progress of the Work or within one year of final acceptance by the State.
4.3.2 The Contractor shall be responsible to the State for the acts and omissions of his / her employees, Subcontractors and their agents and employees, and other persons performing any of the Work under a contract with the Contractor.
4.3.3 The Contractor shall not be relieved from his / her obligations to perform the Work in accordance with the Contract Documents either by the activities or duties of the Architect in his / her administration of the Contract, or by inspections, tests or approvals required or performed under Paragraph 7.7 by persons other than the Contractor.
4.3.4 The Contractor shall acquaint himself (herself / itself) with the limits of the property or right- of-way of the State and shall not trespass on other property. The Contractor shall adequately protect the project, adjacent property and the public, and shall be responsible for any damage or injury due to the Contractor’s act or neglect, and shall save the State harmless in respect thereto.
4.3.5 All work shall be done in such a manner as not to interfere with the State’s operating functions. Contractor and his employees shall familiarize themselves and comply with all rules and regulations applicable to the project.
4.3.6 The Contractor shall keep the premises free from liens arising out of or from the Project. Contractor shall obtain and submit waivers of liens with a request for a progress or final payment.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
