Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Packaging Materials and Containers for Retail Sale 1. When packaging materials and containers in which a good is packaged for retail sales are classified in the Harmonized System with the good, they shall not be taken into account in determining whether all non-originating materials used in the production of the good undergo the applicable change in tariff classification set out in Annex 4.03.
2. When the good is subject to a requirement of regional value content, the value of these packaging materials and containers shall be taken into account as originating or non-originating materials, as the case may be, in calculating the regional value content of the good.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
SERVICE REQUIREMENTS FOR REFERRED CLIENTS A. Agent agrees to respond to any communications from a Referred Client within two (2) hours after receipt if such communication is received between 9:00am to 5:00pm local time. For communications received outside of these hours, Agent agrees to respond by 10:00am the next day.
B. Agent agrees to update XXXX.xxx with status updates within 48 hours after initial communication with a Referred Client and upon every significant status change until closing or abandoned. Updates shall be made by Agent via email to xxxxxxxxxxxx@xxxx.xxx.
C. Vacations or extended absences shall be reported, with length of pause, to XXXX.xxx via email to
D. Agent will not add Referred Client to any email list or calling list without the express permission of Referred Client.
E. Agent agrees XXXX.xxx has the right to survey the Referred Client at any time.
F. If Agent is contacted by a Referred Client that Agent is unwilling or unable to assist, Agent shall direct such Referred Client back to XXXX.xxx for assistance and notify XXXX.xxx at xxxxxxxxxxxx@xxxx.xxx.
G. Agent agrees that XXXX.xxx has no obligation to provide Agent with any number of referrals and that prospective clients are free to select the agent they wish to work with for any particular real estate transaction.
Particular Methods of Procurement of Goods and Works International Competitive Bidding. Goods and works shall be procured under contracts awarded on the basis of International Competitive Bidding.
Venue Limitation for TIPS Sales Vendor agrees that if any "Venue" provision is included in any TIPS Sale Agreement/contract between Vendor and a TIPS Member, that clause must provide that the "Venue" for any litigation or alternative dispute resolution shall be in the state and county where the TIPS Member operates unless the TIPS Member expressly agrees otherwise. Any TIPS Sale Supplemental Agreement containing a “Venue” clause that conflicts with these terms is rendered void and unenforceable.
Additional Requirements for Sleeping Rooms The Contractor shall provide departing Attendees a secured area for storing belongings.
Benchmarks for Measuring Accessibility For the purposes of this Agreement, the accessibility of online content and functionality will be measured according to the W3C’s Web Content Accessibility Guidelines (WCAG) 2.0 Level AA and the Web Accessibility Initiative Accessible Rich Internet Applications Suite (WAI-ARIA) 1.0 for web content, which are incorporated by reference.
Particular Methods of Procurement of Goods Works and Services (other than Consultants’ Services)
