Responsibility for Property Except as expressly set forth in Section 3.25, Contractor shall limit its operations to the Stage 2 Site. Contractor shall plan and conduct its operations so that neither Contractor nor any of its Subcontractors or Sub-subcontractors shall (i) enter upon lands (other than the Stage 2 Site and Off-Site Rights of Way and Easements) or waterbodies in their natural state unless authorized by the appropriate owner or entity; (ii) close or obstruct any utility installation, highway, waterway, harbor, road or other property unless Permits are obtained and authorized by the appropriate entity or authority; or (iii) disrupt or otherwise interfere with the operation of any portion of any pipeline, telephone, conduit or electric transmission line, ditch, navigational aid, dock or structure unless otherwise specifically authorized by the appropriate entity or authority. The foregoing includes damage arising from performance of the Work through operation of Construction Equipment or stockpiling of materials. If damage occurs to Subproject 1 or Subproject 2 prior to substantial completion of such applicable Subproject 1 or Subproject 2, liability for such damage shall be governed by the Stage 1 EPC Agreement.
Responsibility for Equipment City shall not be responsible for any damage to persons or property as a result of the use, misuse or failure of any equipment used by Contractor, or by any of its employees, even though such equipment be furnished, rented or loaned to Contractor by City.
ARCHITECT’S RESPONSIBILITIES § 2.1 The Architect shall provide professional services as set forth in this Agreement. The Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the services required by this Agreement, or shall cause such services to be performed by appropriately licensed design professionals.
§ 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project.
§ 2.3 The Architect shall identify a representative authorized to act on behalf of the Architect with respect to the Project.
§ 2.4 Except with the Owner’s knowledge and consent, the Architect shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Architect’s professional judgment with respect to this Project.
§ 2.5 The Architect shall maintain the following insurance until termination of this Agreement. If any of the requirements set forth below are in addition to the types and limits the Architect normally maintains, the Owner shall pay the Architect as set forth in Section 11.9.
§ 2.5.1 Commercial General Liability with policy limits of not less than « » ($ « » ) for each occurrence and « » ($ « » ) in the aggregate for bodily injury and property damage.
§ 2.5.2 Automobile Liability covering vehicles owned, and non-owned vehicles used, by the Architect with policy limits of not less than « » ($ « » ) per accident for bodily injury, death of any person, and property damage arising out of the ownership, maintenance and use of those motor vehicles, along with any other statutorily required automobile coverage.
§ 2.5.3 The Architect may achieve the required limits and coverage for Commercial General Liability and Automobile Liability through a combination of primary and excess or umbrella liability insurance, provided such primary and excess or umbrella liability insurance policies result in the same or greater coverage as the coverages
Tenant’s Responsibility (a) Except to the extent contributed to by a Landlord Party and except for those matters listed in Section 9.5(a) for which the Landlord shall be responsible, the Tenant shall be solely responsible and liable for any work required by any governmental authority having jurisdiction with respect to any Contaminants on, in or under the Premises during the Term of the Lease. Except (i) as caused by or contributed to by a Landlord Party, and (ii) for those matters listed in Section 9.5(a), the Tenant shall indemnify, defend (utilizing counsel satisfactory to the Landlord) and hold harmless the Landlord and the Landlord’s respective officers, directors, beneficiaries, shareholders, partners, agents and employees from all Claims arising out of or in any way connected with any Release of any Contaminants that occurs during the Term of this Lease, at, in, on, from, under, or about the Premises or the Building, or which arises at any time from the Tenant’s use or occupancy of the Premises, or from the Tenant’s failure to provide all information, make all submissions, and take steps required by all authorities under Environmental Law.
(b) Upon the occurrence of any material Release of a Contaminant at the Premises and upon the Tenant becoming aware of such Release, the Tenant shall immediately give written notice to the Landlord. In any event, the Tenant shall immediately take all steps required by Environmental Law to remedy or otherwise address the situation giving rise to any Release.
(c) If any work is required in accordance with this section 9.2 the Tenant shall prepare all necessary studies, plans and proposals and submit them to the Landlord for approval, which approved shall not be unreasonably withheld, provide all bonds and other security required by any lawful governmental authorities and carry out the work required. In carrying out such work, the Tenant shall keep the Landlord fully informed of the progress of the work. If the Landlord has reasonable grounds for believing that the Tenant will not promptly or properly carry out such work, the Landlord may, in its sole discretion, elect to carry out all such work, or any part of it, and if the Landlord does so, the Tenant shall pay for all costs in connection therewith, within thirty (30) days after the Landlord has incurred the costs and made written demand to the Tenant.
(d) The Tenant covenants, acknowledges and agrees that its obligations and liabilities under this Section shall survive the expiration or earlier termination of this Lease.
Tenant’s Responsibilities Except as expressly provided in Paragraph 10.1 above, Tenant shall, at its sole cost, maintain the entire Premises and every part thereof, including without limitation, windows, skylights, window frames, plate glass, freight docks, doors and related hardware, interior walls and partitions, and the electrical, plumbing, lighting, heating and air conditioning systems in good order, condition and repair. Tenant shall deliver to Landlord, every six (6) months during the Lease Term, a certificate of maintenance or its equivalent, signed by a licensed HVAC repair and maintenance contractor and stating that the heating and air conditioning systems servicing the Premises have been inspected, serviced and are in good order, condition and repair. Tenant's failure to deliver said certificate or its equivalent within thirty (30) days following written notice from Landlord that said certificate is past due shall be a Default by Tenant. If Tenant fails to make repairs or perform maintenance work required of Tenant hereunder within fifteen (15) days after notice from Landlord specifying the need for such repairs or maintenance work, Landlord or Landlord's agents may, in addition to all other rights and remedies available hereunder or by law and without waiving any alternative remedies, enter into the Premises and make such repairs and/or perform such maintenance work. If Landlord makes such repairs and/or performs such maintenance work, Tenant shall reimburse Landlord upon demand and as Additional Rent, for the cost of such repairs and/or maintenance work. Landlord shall have no liability to Tenant for any damage, inconvenience or interference with the use of the Premises by Tenant or Tenant's agents as a result of Landlord performing any such repairs or maintenance (unless such damage, inconvenience or interference is caused by the gross negligence or willful misconduct of Landlord or its agents, employees or contractors); provided, however, under no circumstances shall Landlord be liable to Tenant for claims of lost profits, loss of business or lost income. Tenant shall reimburse Landlord, on demand and as Additional Rent, for the cost of damage to the Premises and/or Common Area caused by Tenant or Tenant's agents, employees or contractors. Tenant expressly waives the benefits of any statute now or hereafter in effect (including without limitation the provisions of subsection 1 of Section 1932, Section 1941 and Section 1942 of the California Civil Code and any similar law, statute or ordinance now or hereafter in effect) which would otherwise afford Tenant the right to make repairs at Landlord's expense (or to deduct the cost of such repairs from Rentals due hereunder) or to terminate this Lease because of Landlord's failure to keep the Premises in good and sanitary order.
Review Systems; Personnel It will maintain business process management and/or other systems necessary to ensure that it can perform each Test and, on execution of this Agreement, will load each Test into these systems. The Asset Representations Reviewer will ensure that these systems allow for each Review Receivable and the related Review Materials to be individually tracked and stored as contemplated by this Agreement. The Asset Representations Reviewer will maintain adequate staff that is properly trained to conduct Reviews as required by this Agreement.
Responsibility For Use (a) The Company alone will be responsible for furnishing, or arranging for a third party to furnish, all data and information required by the Documentation and the specifications therein for the Licensed System to function and perform in accordance with the Documentation, other than the data and information residing in the Licensed System in connection with BNYM’s performance of the Core Services. BNYM shall have no liability or responsibility for any Loss caused in whole or in part by the Company’s or a Permitted User’s exercise of the Licensed Rights or use of the Licensed System or by data or information of any nature inputted into the Licensed System by or under the direction or authorization of Company or a Permitted User; provided, however, this Section 2.5 shall not relieve BNYM of its obligation to act in accordance with its obligations under the Main Agreement. Company shall be responsible and solely liable for the cost or expense of regenerating any output or other remedial action if the Company, a Permitted User or an agent of either shall have failed to transmit properly and in the correct format any data or information, shall have transmitted erroneous or incorrect information or data, or shall have failed to timely verify or reconcile any such data or information when it is generated by the Licensed System (“Data Faults”).
Landlord’s Responsibility During the term of this Lease, Landlord shall maintain in good condition and repair, and replace as necessary, the roof, exterior walls, foundation and structural frame of the Building and the parking and landscaped areas, the costs of which shall be included in Operating Expenses; provided, however, that to the extent any of the foregoing items require repair because of the negligence, misuse, or default of Tenant, its employees, agents, customers or invitees, Landlord shall make such repairs solely at Tenant's expense.
Landlord’s Responsibilities (a) Landlord shall correct, repair or replace, at Landlord's sole cost and expense and not as a Project Cost, any non-compliance of the Building exterior and the Common Areas with all applicable building permits and codes in effect as of the Commencement Date, including, without limitation, the provisions of Title III of the Americans With Disabilities Act ("ADA") in effect as of the Commencement Date. Said costs of compliance shall be Landlord's sole cost and shall not be part of Project Costs. Landlord shall correct, repair or replace any non-compliance of the Building exterior and the Common Areas with any revisions or amendments to the ADA in effect after the Commencement Date, provided that the amortized cost of such repairs or replacements (amortized over the useful life thereof using a market cost of funds reasonably determined by Landlord) shall be included as Project Costs payable by Tenant. All other ADA compliance issues which pertain to the Premises, including, without limitation, in connection with Tenant's construction of any alterations or other improvements in the Premises (and any resulting ADA compliance requirements in the Common Areas), the Tenant Improvements and the operation of Tenant's business and employment practices in the Premises, shall be the responsibility of Tenant at its sole cost and expense. Landlord shall, during the initial Lease Term, correct, repair or replace, at Landlord's sole cost and expense and not as a Project Cost, any failure of the structural components of the roof, foundations, footings and load-bearing walls of the Building. The repairs, corrections or replacements required of Landlord or of Tenant under the foregoing provisions of this Section 2.4 shall be made promptly following notice of non-compliance from any applicable governmental agency.
(b) Landlord warrants to Tenant that the Shell Building Improvements as defined in the Discovery Outline Specifications (as defined in the Work Letter) and the Tenant Improvements to be completed pursuant to the Work Letter shall be free from defects in workmanship or materials for a period of twelve (12) months from the Commencement Date. Landlord shall promptly rectify any non-compliance at its sole cost and expense after receipt of written notice from Tenant within such time setting forth the nature and extent of any such non-compliance. Landlord shall obtain customary warranties and guaranties from the contractor(s) performing the Tenant Improvement work and/or the manufacturers of equipment installed but shall be under no obligation to incur additional expense in order to obtain or extend such warranties. If after expiration of the initial twelve (12) months of the Lease Term, Tenant is required to make repairs to any component of the Premises or any of its systems for which Landlord may have obtained a warranty, Landlord shall, upon request by Tenant, use its good faith efforts to pursue its rights under any such warranties for the benefit of Tenant. Landlord shall be under no obligation to incur any expense in connection with asserting rights under such warranties or guaranties against either the contractor or the manufacturer, but shall use reasonable good faith efforts to enforce such warranties and guaranties for Tenant's benefit.
(c) Notwithstanding the provisions of Section 7.2 of this Lease, Landlord agrees to maintain and repair, at its sole cost and expense and not as an Operating Expense the structural components of the roof and Building, including floor/ceiling slabs, columns, beams, walls and the foundations and footings of the Building during the initial Lease Term. If a non-compliance with the foregoing warranty exists, Landlord shall, promptly after receipt of the written notice from Tenant setting forth the nature and extent of such non-compliance, rectify same at Landlord's sole cost and expense.
Tenant Responsibility Good housekeeping is expected of everyone. Tenant agrees to keep quarters clean and in a sanitary condition. The Tenants agree not to permit any deterioration or destruction to occur while they are occupying the property.
