Retain Existing Irrigation Controller Sample Clauses

Retain Existing Irrigation Controller. Alternative 3 was proposed to reduce labor and material cost associ- ated with replacing existing irrigation controller while improving sustain- ability by reusing the existing irrigation controllers. The initial cost saving of alternative 3 is approximately $250,000 with no change in construc- tion schedule. The overall performance will be reduced by 9.8% with 36.3% reduction in value. In the PDT meeting, the Landscape team expressed that the existing landscape location requires the replacement of a large amount of PVC pipes. The conventional irrigation system requires a separate wired connection to each controller, which will increase the amount of cop- per wires and the cost for repair and maintenance. The two-wired sys- tem will reduce material costs such as copper and controllers. Further- more, the two-wired system will create ease of expansion by splicing two wires into decoders to create new zones that can create multiple path support. Lastly, the two-wired system would reach remote valve locations and give more irrigation design options. Therefore, the con- clusion was to reject alternative 3 to retain existing irrigation controllers. A final value analysis study report was provided on December 20th, 2021 to summarize and highlights the study and final disposition. See Attachment J for Final Value Analysis Study Report.
Sample 1Sample 2
AutoNDA by SimpleDocs

Related to Retain Existing Irrigation Controller

  • CERTIFICATION REGARDING BOYCOTTING CERTAIN ENERGY COMPANIES (Texas law as of September 1, 2021) By submitting a proposal to this Solicitation, you certify that you agree, when it is applicable, to the following required by Texas law as of September 1, 2021: If (a) company is not a sole proprietorship; (b) company has ten (10) or more full-time employees; and (c) this contract has a value of $100,000 or more that is to be paid wholly or partly from public funds, the following certification shall apply; otherwise, this certification is not required. Pursuant to Tex. Gov’t Code Ch. 2274 of SB 13 (87th session), the company hereby certifies and verifies that the company, or any wholly owned subsidiary, majority-owned subsidiary, parent company, or affiliate of these entities or business associations, if any, does not boycott energy companies and will not boycott energy companies during the term of the contract. For purposes of this contract, the term “company” shall mean an organization, association, corporation, partnership, joint venture, limited partnership, limited liability partnership, or limited liability company, that exists to make a profit. The term “boycott energy company” shall mean “without an ordinary business purpose, refusing to deal with, terminating business activities with, or otherwise taking any action intended to penalize, inflict economic harm on, or limit commercial relations with a company because the company (a) engages in the exploration, production, utilization, transportation, sale, or manufacturing of fossil fuel-based energy and does not commit or pledge to meet environmental standards beyond applicable federal and state law, or (b) does business with a company described by paragraph (a).” See Tex. Gov’t Code § 809.001(1).

  • Opinion of General Counsel of the Company The General Counsel of the Company, shall have furnished to the Representatives, at the request of the Company, a written opinion, dated the Closing Date and addressed to the Underwriters, in form and substance reasonably satisfactory to the Representatives and substantially in the form previously agreed by the parties hereto.

  • Preservation of Corporate Existence, Etc Preserve and maintain, and cause each of its Subsidiaries to preserve and maintain, its corporate existence, rights (charter and statutory) and franchises; provided, however, that the Borrower and its Subsidiaries may consummate any merger or consolidation permitted under Section 5.02(b) and provided further that neither the Borrower nor any of its Subsidiaries shall be required to preserve any right or franchise if the Board of Directors of the Borrower or such Subsidiary shall determine that the preservation thereof is no longer desirable in the conduct of the business of the Borrower or such Subsidiary, as the case may be, and that the loss thereof is not disadvantageous in any material respect to the Borrower, such Subsidiary or the Lenders.

  • Information Systems Acquisition Development and Maintenance a. Client Data – Client Data will only be used by State Street for the purposes specified in this Agreement.

  • Preservation of Corporate Existence and Related Matters Except as permitted by Section 10.4, preserve and maintain its legal existence and all material rights, franchises, licenses and privileges and qualify and remain qualified as a foreign corporation and authorized to do business in each jurisdiction in which the failure to so qualify could reasonably be expected to have a Material Adverse Effect.

  • Opinion of General Counsel for the Company The General Counsel of the Company shall have furnished to the Representatives, at the request of the Company, his written opinion, dated the Closing Date and addressed to the Underwriters, in form and substance reasonably satisfactory to the Representatives, to the effect set forth in Annex A-2 hereto.

  • Maintain Existence It will preserve and maintain its existence, rights, franchises and privileges in the jurisdiction of its formation, and qualify and remain qualified in good standing as a foreign trust or limited liability company in each jurisdiction where its business is conducted, and will obtain and maintain all requisite authority to conduct its business in each jurisdiction in which its business requires such authority.

  • Performing Agency’s Pre-existing Works A. To the extent that Performing Agency incorporates into the Work Product any works of Performing Agency that were created by Performing Agency or that Performing Agency acquired rights in prior to the Effective Date of this Contract (“Incorporated Pre-existing Works”), Performing Agency retains ownership of such Incorporated Pre-existing Works. B. Performing Agency hereby grants to System Agency an irrevocable, perpetual, non- exclusive, royalty-free, transferable, worldwide right and license, with the right to sublicense, to use, reproduce, modify, copy, create derivative works of, publish, publicly perform and display, sell, offer to sell, make and have made, the Incorporated Pre-existing Works, in any medium, with or without the associated Work Product. C. Performing Agency represents, warrants, and covenants to System Agency that Performing Agency has all necessary right and authority to grant the foregoing license in the Incorporated Pre-existing Works to System Agency.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Covenant to Provide Financial Information and Maintain Sufficient Capital The Administrator shall obtain and maintain the necessary capital to fulfill its obligations under this Agreement and shall remain solvent. The Administrator will report to the Issuer on a semi-annual basis its current and total assets, current and total liabilities, and total equity and the Company intends to include such amounts in its SEC reports.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!