See Your Right to Reject Arbitration For this section, you and us includes any corporate parents, subsidiaries, affiliates or related persons or entities. Claim means any current or future claim, dispute or controversy relating to your Account(s), this Agreement, or any agreement or relationship you have or had with us, except for the validity, enforceability or scope of the Arbitration provision. Claim includes but is not limited to: (1) initial claims, counterclaims, crossclaims and third-party claims;
Time of the Essence; Computation of Time Time is of the essence for each and every provision of this Agreement. Whenever the last day for the exercise of any privilege or the discharge or any duty hereunder shall fall upon a Saturday, Sunday, or any date on which banks in New York, New York are authorized to be closed, the party having such privilege or duty may exercise such privilege or discharge such duty on the next succeeding day which is a regular business day.
Your Right to Reject Arbitration You may reject this Arbitration provision by sending a written rejection notice to us at: American Express, P.O. Box 981556, El Paso, TX 79998. Go to xxxxxxxxxxxxxxx.xxx/xxxxxx for a sample rejection notice. Your rejection notice must be mailed within 45 days after your first card purchase. Your rejection notice must state that you reject the Arbitration provision and include your name, address, Account number and personal signature. No one else may sign the rejection notice. If your rejection notice complies with these requirements, this Arbitration provision and any other arbitration provisions in the cardmember agreements for any other currently open American Express accounts you have will not apply to you, except for Corporate Card accounts and any claims subject to pending litigation or arbitration at the time you send your rejection notice. Rejection of this Arbitration provision will not affect your other rights or responsibilities under this Claims Resolution section or the Agreement. Rejecting this Arbitration provision will not affect your ability to use your card or any other benefit, product or service you may have with your Account.
Release Time for Negotiations CSEA shall have the right to designate a maximum of six (6) employees, who shall be given reasonable release time to participate in negotiations.
Response to Demand Letter Within 10 days after the receipt of the Demand Letter, RMC shall either: (a) cure the breach to OIG’s satisfaction and pay the applicable Stipulated Penalties or (b) request a hearing before an HHS administrative law judge (ALJ) to dispute OIG’s determination of noncompliance, pursuant to the agreed upon provisions set forth below in Section X.E. In the event RMC elects to request an ALJ hearing, the Stipulated Penalties shall continue to accrue until RMC cures, to OIG’s satisfaction, the alleged breach in dispute. Failure to respond to the Demand Letter in one of these two manners within the allowed time period shall be considered a material breach of this CIA and shall be grounds for exclusion under Section X.D.
Notice and Right to Cure If the Contractor breaches the Contract, and Huron Valley Schools, in its sole discretion, determines that the breach is curable, Huron Valley Schools will provide the Contractor notice of the breach and a period of at least 30 days to cure the breach. Huron Valley Schools does not need to provide notice or an opportunity to cure for successive or repeated breaches or if Huron Valley Schools determines, in its sole discretion, that a breach poses a serious and imminent threat to the health or safety of any person or the imminent loss, damage, or destruction of any real or tangible personal property.
COMPLETION OF MEET AND NEGOTIATION 24.1 During the term of this Agreement, the Association expressly waives and relinquishes the right to meet and negotiate and agrees that the District shall not be obligated to meet and negotiate with respect to any subject or matter whether referred to or covered in this Agreement or not, even though each subject or matters may not have been within the knowledge or contemplation of either or both the District or the Association at the time they met and negotiated on and executed this Agreement, and even though such subjects or matters were proposed and later withdrawn.
Notice to Allow Exercise by Xxxxxx If (A) the Company shall declare a dividend (or any other distribution in whatever form) on the Common Stock, (B) the Company shall declare a special nonrecurring cash dividend on or a redemption of the Common Stock, (C) the Company shall authorize the granting to all holders of the Common Stock rights or warrants to subscribe for or purchase any shares of capital stock of any class or of any rights, (D) the approval of any stockholders of the Company shall be required in connection with any reclassification of the Common Stock, any consolidation or merger to which the Company is a party, any sale or transfer of all or substantially all of the assets of the Company, or any compulsory share exchange whereby the Common Stock is converted into other securities, cash or property, or (E) the Company shall authorize the voluntary or involuntary dissolution, liquidation or winding up of the affairs of the Company, then, in each case, the Company shall cause to be delivered by facsimile or email to the Holder at its last facsimile number or email address as it shall appear upon the Warrant Register of the Company, at least 20 calendar days prior to the applicable record or effective date hereinafter specified, a notice stating (x) the date on which a record is to be taken for the purpose of such dividend, distribution, redemption, rights or warrants, or if a record is not to be taken, the date as of which the holders of the Common Stock of record to be entitled to such dividend, distributions, redemption, rights or warrants are to be determined or (y) the date on which such reclassification, consolidation, merger, sale, transfer or share exchange is expected to become effective or close, and the date as of which it is expected that holders of the Common Stock of record shall be entitled to exchange their shares of the Common Stock for securities, cash or other property deliverable upon such reclassification, consolidation, merger, sale, transfer or share exchange; provided that the failure to deliver such notice or any defect therein or in the delivery thereof shall not affect the validity of the corporate action required to be specified in such notice. To the extent that any notice provided in this Warrant constitutes, or contains, material, non-public information regarding the Company or any of the Subsidiaries, the Company shall simultaneously file such notice with the Commission pursuant to a Current Report on Form 8-K. The Holder shall remain entitled to exercise this Warrant during the period commencing on the date of such notice to the effective date of the event triggering such notice except as may otherwise be expressly set forth herein.
Extension of time for completion (i) Without prejudice to any other provision of this Agreement for and in respect of extension of time, the Contractor shall be entitled to extension of time in the Project Completion Schedule (the “Time Extension”) to the extent that completion of any Project Milestone is or will be delayed by any of the following, namely:
(a) delay in providing the Right of Way of Construction Zone, environmental clearances or approval of railway authorities, specified in Clause 3.1 (iv);
(b) Change of Scope (unless an adjustment to the Scheduled Completion Date has been agreed under Article 13);
(c) occurrence of a Force Majeure Event;
(d) any delay, impediment or prevention caused by or attributable to the Authority, the Authority's personnel or the Authority's other contractors on the Site; and
(e) any other cause or delay which entitles the Contractor to Time Extension in accordance with the provisions of this Agreement.
(ii) The Contractor shall, no later than 15 (fifteen) business days from the occurrence of an event or circumstance specified in Clause 10.5 (i), inform the Authority’s Engineer by notice in writing, with a copy to the Authority, stating in reasonable detail with supporting particulars, the event or circumstances giving rise to the claim for Time Extension in accordance with the provisions of this Agreement. Provided that the period of 15 (fifteen) business days shall be calculated from the date on which the Contractor became aware, or should have become aware, of the occurrence of such an event or circumstance. Provided further that notwithstanding anything to the contrary contained in this Agreement, Time Extension shall be due and applicable only for the Works which are affected by the aforesaid events or circumstances and shall not in any manner affect the Project Completion Schedule for and in respect of the Works which are not affected hereunder.
(iii) On the failure of the Contractor to issue to the Authority’s Engineer a notice in accordance with the provisions of Clause 10.5 (ii) within the time specified therein, the Contractor shall not be entitled to any Time Extension and shall forfeit its right for any such claims in future. For the avoidance of doubt, in the event of failure of the Contractor to issue notice as specified in this clause 10.5 (iii), the Authority shall be discharged from all liability in connection with the claim.
(iv) The Authority’s Engineer shall, on receipt of the claim in accordance with the provisions of Clause 10.5 (ii), examine the claim expeditiously within the time frame specified herein. In the event the Authority’s Engineer requires any clarifications to examine the claim, the Authority’s Engineer shall seek the same within 15 (fifteen) days from the date of receiving the claim. The Contractor shall, on receipt of the communication of the Authority’s Engineer requesting for clarification, furnish the same to the Authority’s Engineer within 10 (ten) days thereof. The Authority’s Engineer shall, within a period of 30 (thirty) days from the date of receipt of such clarifications, forward in writing to the Contractor its determination of Time Extension. Provided that when determining each extension of time under this Clause 10.5, the Authority’s Engineer shall review previous determinations and may increase, but shall not decrease, the total Time Extension.
(v) If the event or circumstance giving rise to the notice has a continuing effect:
(a) a fully detailed claim shall be considered as interim;
(b) the Contractor shall, no later than 10 (ten) days after the close of each month, send further interim claims specifying the accumulated delay, the extension of time claimed, and such further particulars as the Authority’s Engineer may reasonably require; and
(c) the Contractor shall send a final claim within 30 (thirty) days after the effect of the event or the circumstance ceases. Upon receipt of the claim hereunder, the Authority’s Engineer shall examine the same in accordance with the provisions of Clause 10.5 (iv) within a period of 30 (thirty) days of the receipt thereof
Object and Scope of the Agreement The competent authorities of the Contracting Parties shall provide assistance through exchange of information that is foreseeably relevant to the administration and enforcement of the domestic laws of the Contracting Parties concerning taxes covered by this Agreement. Such information shall include information that is foreseeably relevant to the determination, assessment and collection of such taxes, the recovery and enforcement of tax claims, or the investigation or prosecution of tax matters. Information shall be exchanged in accordance with the provisions of this Agreement and shall be treated as confidential in the manner provided in Article 8. The rights and safeguards secured to persons by the laws or administrative practice of the requested Party remain applicable to the extent that they do not unduly prevent or delay effective exchange of information.
