SERVICES INTERRUPTION. 16.1 Without prejudice to any other right or remedy of the Company, the parties acknowledge that from time to time a Services Interruption Event may occur and, in that case, such occurrence will delay the Works and will entitle the Company to immediately cease the performance of all or any part of the Works until the Services Interruption Event ends or is remedied (as the case may be). The Customer acknowledges that there may be an Additional Expenses Charge relating to recommencement of the Works after the occurrence of a Services Interruption Event. The Customer agrees to pay the Additional Expenses Charge upon rendering of an invoice by the Company.
SERVICES INTERRUPTION. It is understood that Landlord does not warrant that any of the services referred to above, or any other services which Landlord may supply, will be free from interruption. Tenant acknowledges that any one or more such services may be suspended or reduced by reason of accident or repairs, alterations, or improvements necessary to be made, by strikes or accident or by any cause beyond the reasonable control of Landlord, or by orders or regulations of any federal, state, county, or municipal authority.
a. Any such interruption or suspension of services shall never be deemed an eviction of or disturbance to Tenant's use and possession of the Leased Premises or any part thereof, or render Landlord liable to Tenant for damages by abatement of rent, or otherwise relieve Tenant of performance of Tenant's obligation under this Lease Agreement. Landlord will use commercially reasonable efforts to restore service to full operations, and in the event of a strike to secure parties not involved in the labor dispute to provide minimum services.
SERVICES INTERRUPTION. 14.1. Without prejudice to any other right or remedy of the Company, the parties acknowledge that from time to time a Services Interruption Event may occur and, in that case, such occurrence will delay the Works and will entitle the Company to immediately cease the performance of all or any part of the Works until the Services Interruption Event ends or is remedied (as the case may be).
14.2. The Customer acknowledges that the Company may charge for any costs of recommencing the Works after the occurrence of a Services Interruption Event.
SERVICES INTERRUPTION. An interruption begins when MCI reports a trouble on any one or more Circuits to Provider in accordance with Exhibit G. Provider will provide diagnostics and perform corrective action as necessary to timely restore the affected Circuit(s) in accordance with the Specifications. Upon correction of the trouble, Provider will contact XXX and advise of the action taken to correct the problem. MCI will consult with XXX's Customer regarding acceptability of the Circuits and upon Xxxxxxxx's confirmation that the Circuits are acceptable, Provider will be so notified and the trouble will be considered as having been cleared at the time that Provider last reported clearance of same, immediately prior to Customer's confirmation. If, during the testing of the affected Circuit(s), it is determined that the Circuit(s) is operating normally and within the parameters of the Specifications and the same is confirmed by Customer through MCI then such interruption shall not be considered a Services Interruption for credit purposes.
SERVICES INTERRUPTION. PLPT TELECOM is not responsible for matters of Force Majeure, discussed below, which may cause interruption of Services and are beyond PLPT TELECOM’s control, such as those caused by fire, flood, hail, wind, earthquake, war, terrorism, destruction, extended power disruption, electromagnetic pulse, or other natural or manmade disaster or emergency. Customer may contact PLPT TELECOM under Section 2c above to seek credit for interruption of Services, which are the sole fault of PLPT TELECOM, and PLPT TELECOM may or may not issue a credit at the sole discretion of PLPT TELECOM.
SERVICES INTERRUPTION. (a) Except as expressly provided in this Lease, no cessation or discontinuance of any of Landlord Services, or failure by Landlord to provide any of the Landlord Services in accordance with the standards of this Lease (a "Services Interruption") shall render Landlord liable in any respect for damages to either person or property, nor be construed as an eviction of Tenant, nor relieve Tenant from fulfillment of any covenant or agreement hereof, nor work an abatement of Rent. In the event of any Services Interruption, Landlord covenants and agrees to use its best efforts to cure the cause thereof and to restore such Landlord Services as soon as reasonably possible.
(b) In the event of a Services Interruption which results from the malfunction or obsolescence of Building equipment or machinery, or from any other cause which is reasonably within the control of Landlord (a "Services Interruption Within Landlord's Control") which (i) is not attributable in whole or in part to the negligence or willful misconduct of Tenant or its employees, agents or contractors (to the extent such employees, agents or contractors are acting within their scope of employment, agency or contract), (ii) renders all or any portion of the Leased Premises untenantable, and (iii) continues for three (3) consecutive business days or for any seven (7) out of ten (10) consecutive business days after Landlord's receipt of notice thereof, Rent with respect to the affected portion(s) of the Leased Premises shall be abated from the date Landlord receives such notice until the Services Interruption ceases or the affected portion(s)) of the Leased Premises are otherwise restored to a tenantable condition. The Leased Premises or a portion thereof shall be considered "untenantable" hereunder when the Leased Premises, or such portion thereof, are not reasonably usable for the conduct of Tenant's business. Notwithstanding anything else contained in this Section 3.02
SERVICES INTERRUPTION. (a) Ruralwave may interrupt the Services to the Subscriber at any time for any duration of time, without any notice or liability, in order to install, inspect, repair, replace or to perform necessary maintenance on the telecommunications equipment, facilities or network, or for other technical reasons as may be required. Ruralwave telecommunications service is provided to the Subscriber on a bestefforts basis. Subscriber acknowledges that Ruralwave phone VoIP service requires highspeed internet connectivity. Poor or lack of internet connectivity, power failure, computer viruses and the like (Connectivity Issues) will cause service interruption and or failure of the service to function. It is the responsibility of the Subscriber to remedy these Connectivity Issues.
(b) Ruralwave is not liable for:
(i) any disruption or unavailability of the Services;
(ii) any act or omission of any third party (including any other local telephone company, any connecting carrier or underlying carrier or other provider of connections, facilities, or Services);
(iii) Subscriber's conduct, acts or omissions, or the operation or failure of Subscriber's equipment or facilities;(iv) any event beyond the reasonable control of Ruralwave including acts of God, inclement weather including lightning, labour disputes, riots or civil disputes, war or armed conflict, any law, governmental order, decision or regulation, or order of any court of competent jurisdiction; and (v) its failure, for any reason, to activate the Services on the activation date Subscriber requested;(vi) any charges by third parties including other telephone companies or wireless carriers for services they may have rendered in lieu of Ruralwave service. Subscriber agrees to indemnify and hold harmless Ruralwave against all claims, including fees and expenses of counsel, resulting from Subscriber's use (or the use by others with Subscriber's explicit or implicit consent) of the Services, Subscriber's codes, facilities or equipment, which causes direct or indirect damage or harm to another party or to the property of another.
SERVICES INTERRUPTION. 15 42. Subordination to Mortgages.....................................16 43.
SERVICES INTERRUPTION. For the purpose of ensuring the highest possible quality of Services, Xxxxxx retains the right to stop the Services for maintenance, system upgrades, or any other modifications. Otsene may elect to stop or discontinue the Services entirely, subject to applicable laws. The Services will not be accessible owing to circumstances beyond the reasonable control of Xxxxxx, such as "force majeure" events (e.g. labor actions, infrastructural breakdowns or blackouts etc.).
SERVICES INTERRUPTION. In the event of Hardware, System Software, LAN, Desktop Computers or WAN malfunctions, CGI shall notify the list of designated Kanawha employees identified in the Operational Framework of the nature and expected duration of the malfunction. Until such time as the Operational Framework has been implemented and designated Kanawha employees have been identified, CGI shall use the notification processes currently in use by Kanawha as of the Effective Date. CGI shall coordinate the repair services and keep Kanawha informed until all services are restored. CGI shall use Commercially Reasonable efforts to promptly resolve all service interruptions and to perform any and all actions that are necessary to restore normal service operations.
