Premises and Term a. Landlord, in consideration of the Rent hereinafter reserved to be paid and of the covenants, conditions and agreements to be kept and performed by Tenant, hereby leases, lets and demises to Tenant, and Tenant hereby leases and hires from Landlord, the Project. Upon the Commencement Date for Phase 1, Tenant shall be entitled to the exclusive use and occupancy of Phase 1 and that portion of the Parking Area allocated for Phase 1 plus such spaces in addition to the spaces allocated for Phase 1, if any, that may be constructed by Landlord at the time, so long as Tenant’s use of such spaces in addition to the spaces allocated for Phase 1 does not interfere with the construction of the remainder of the Project by Landlord. Upon the Commencement Date for Phase 2, Tenant shall be entitled to the exclusive use and occupancy of Phase 2 and the entire Parking Area, and at which time Tenant will have the exclusive use and occupancy of the entire Project.
b. Promptly after the actual Commencement Date for each Phase, the parties shall execute an instrument in which the Commencement Date and expiration date for such Phase will be specified, as well as any adjustments to the Rentable Area of the Premises as described above and any corresponding adjustments to the Base Rent.
c. Notwithstanding anything to the contrary contained in this Lease, although Landlord has estimated a completion date for Phase 1 of October 1, 1999, the parties agree that if Landlord has not achieved Substantial Completion of Phase 1 on or before November 1, 1999 (the “Phase 1 Completion Date”) (subject to any Tenant Delays and Force Majeure events, as hereinafter defined), then, commencing on November 1, 1999, Tenant shall receive a credit against the Base Rent to become due under this Lease in connection with Phase 1, such credit to be equal to one (1) day’s Base Rent for Phase 1 for each day of Landlord’s delay beyond the Phase 1 Completion Date that Landlord has not achieved Substantial Completion, subject to the limitations thereon pursuant to subsection (m), below.
d. If Landlord has not achieved Substantial Completion of Phase 1 on or before November 15, 1999 (the “Phase 1 Extended Completion Date”) (subject to any Tenant Delays and Force Majeure events), then, commencing on November 16, 1999, the Base Rent credit available to Tenant for Phase 1 shall be increased to two (2) days’ Base Rent for each day of Landlord’s delay beyond the Phase 1 Extended Completion Date that Landlord has not achieved Substantial Completion, subject to the limitations thereon pursuant to subsection (m), below.
e. If Landlord has not achieved Substantial Completion of Phase 1 on or before December 17, 1999 (the “Phase 1 Second Extended Completion Date”) (subject to any Tenant Delays and Force Majeure events), then, commencing on December 18, 1999, (x) the Base Rent credit available to Tenant for Phase 1 shall be decreased back to one (1) day’s Base Rent for each day of Landlord’s delay beyond the Phase 1 Second Extended Completion Date that Landlord has not achieved Substantial Completion, plus (y) Tenant shall be entitled to receive, as liquidated damages and not as a penalty, the sum of Ten Thousand and No/100 ($10,000.00) Dollars per day, subject to the limitations thereon pursuant to subsection (m), below.
f. If Landlord has not achieved Substantial Completion of Phase 1 on or before January 17, 2000 (the “Phase 1 Outside Completion Date”) (subject to any Tenant Delays and Force Majeure events), then Tenant shall have the right to terminate this Lease by written notice to Landlord delivered within ten (10) days after the Phase 1 Outside Completion Date, whereupon (i) Landlord shall return to Tenant the Prepaid Rent and Security Deposit, and (ii) Landlord shall pay to Tenant liquidated damages equal to (x) the total of the Base Rent abatements for Phase 1 accrued to the date of Tenant’s termination notice, plus (y) the total of the $10,000.00 per day damages for Phase 1 accrued to the date of Tenant’s termination notice, plus (z) the actual, reasonable out-of-pocket costs incurred by Tenant directly in connection with this Lease, subject to the limitations thereon pursuant to subsection (m), below, and thereupon both parties shall be relieved of all further obligations hereunder; provided, however, that if Landlord achieves Substantial Completion of Phase 1 within fifteen (15) days after receipt of Tenant’s termination notice, then the termination notice will be deemed to be void and rescinded, and the Lease shall continue in full force and effect.
g. If Tenant does not elect to terminate the Lease as provided above, and Landlord has not achieved Substantial Completion of Phase 1 on or before May 17, 2000 (the “Phase 1 Extended Outside Completion Date”) (subject to any Tenant Delays but regardless of Force Majeure events), then Tenant shall have the right to terminate this Lease by written notice to Landlord delivered within ten (10) days after the Phase 1 Extended Outside Completion Date, whereupon (i) Landlord shall return to Tenant the Prepaid Rent and Security Deposit, and (ii) Landlord shall pay to Tenant liquidated damages equal to (x) the total of the Base Rent abatements for Phase 1 accrued to the date of Tenant’s termination notice, plus (y) the total of the $10,000.00 per day damages for Phase 1 accrued to the date of Tenant’s termination notice, plus (z) the actual, reasonable out-of-pocket costs incurred by Tenant directly in connection with this Lease, subject to the limitations thereon pursuant to subsection (m), below, and thereupon both parties shall be relieved of all further obligations hereunder. If Tenant intends to exercise its termination right under this paragraph, then Tenant will use its best efforts to notify Landlord in writing between April 1, 2000 and May 1, 2000 of such intent, but Tenant’s failure to so notify Landlord shall not constitute a waiver of Tenant’s termination right.
h. Although Landlord has estimated a completion date for Phase 2 of October 1, 2001, the parties agree that if Landlord has not achieved Substantial Completion of Phase 2 on or before November 1, 2001 (the “Phase 2 Completion Date”) (subject to any Tenant Delays and Force Majeure events, as hereinafter defined), then, commencing on November 1, 2001, Tenant shall receive a credit against the Base Rent to become due under this Lease in connection with Phase 2, such credit to be equal to one (1) day’s Base Rent for Phase 2 for each day of Landlord’s delay beyond the Phase 2 Completion Date that Landlord has not achieved Substantial Completion, subject to the limitations thereon pursuant to subsection (m), below.
i. If Landlord has not achieved Substantial Completion of Phase 2 on or before November 15, 2001 (the “Phase 2 Extended Completion Date”) (subject to any Tenant Delays and Force Majeure events), then, commencing on November 16, 2001, the Base Rent credit available to Tenant for Phase 2 shall be increased to two (2) days’ Base Rent for Phase 2 for each day of Landlord’s delay beyond the Phase 2 Extended Completion Date that Landlord has not achieved Substantial Completion, subject to the limitations thereon pursuant to subsection (m), below.
j. If Landlord has not achieved Substantial Completion of Phase 2 on or before December 17, 2001 (the “Phase 2 Second Extended Completion Date”) (subject to any Tenant Delays and Force Majeure events), then, commencing on December 18, 2001, (x) the Base Rent credit available to Tenant shall be decreased back to one (1) day’s Base Rent for Phase 2 for each day of Landlord’s delay beyond the Phase 2 Second Extended Completion Date that Landlord has not achieved Substantial Completion, plus (y) Tenant shall be entitled to receive, as liquidated damages and not as a penalty, the sum of Ten Thousand and No/100 ($10,000.00) Dollars per day, subject to the limitations thereon pursuant to subsection (m), below.
k. If Landlord has not achieved Substantial Completion of Phase 2 on or before January 17, 2002 (the “Phase 2 Outside Completion Date”) (subject to any Tenant Delays and Force Majeure events), then Tenant shall have the right to terminate this Lease by written notice to Landlord delivered within ten (10) days after the Phase 2 Outside Completion Date, whereupon (i) Tenant shall vacate and surrender the Premises to Landlord in the manner required by this Lease, (ii) Landlord shall return to Tenant the Security Deposit, (iii) Landlord shall pay to Tenant liquidated damages equal to (x) the total of the Base Rent abatements for Phase 2 accrued to the date of Tenant’s termination notice, plus (y) the total of the $10,000.00 per day damages for Phase 2 accrued to the date of Tenant’s termination notice, plus (z) the actual, reasonable out-of-pocket costs incurred by Tenant directly in connection with this Lease between the Commencement Date for Phase 1 and the date of Tenant’s termination notice, subject to the limitations thereon pursuant to subsection (m), below, and thereupon both parties shall be relieved of all further obligations hereunder; provided, however, that if Landlord achieves Substantial Completion of Phase 2 within fifteen (15) days after receipt of Tenant’s termination notice, then the termination notice will be deemed to be void and rescinded, and the Lease shall continue in full force and effect. Within ninety (90) days after Tenant’s termination notice, Tenant shall notify Landlord of the exact date that Tenant will vacate and surrender Phase 1, which date shall be (a) no earlier than ninety (90) days after the date of Tenant’s notification of such exact date, and (b) no later than one (1) year after the date of Tenant’s termination notice. Rent for Phase 1 shall be prorated through the date that Tenant so vacates and surrenders Phase 1 to Landlord.
l. If Tenant does not elect to terminate the Lease as provided above, and Landlord has not achieved Substantial Completion of Phase 2 on or before May 17, 2002 (the “Phase 2 Extended Outside Completion Date”) (subject to any Tenant Delays but regardless of Force Majeure events), then Tenant shall have the right to terminate this Lease by written notice to Landlord delivered within ten (10) days after the Phase 2 Extended Outside Completion Date, whereupon (i) Tenant shall vacate and surrender the Premises to Landlord in the manner required by this Lease, (ii) Landlord shall return to Tenant the Security Deposit, (iii) Landlord shall pay to Tenant liquidated damages equal to (x) the total of the Base Rent abatements for Phase 2 accrued to the date of Tenant’s termination notice, plus (y) the total of the $10,000.00 per day damages for Phase 2 accrued to the date of Tenant’s termination notice, plus (z) the actual, reasonable out-of-pocket costs incurred by Tenant directly in connection with this Lease between the Commencement Date for Phase 1 and the date of Tenant’s termination notice, subject to the limitations thereon pursuant to subsection (m), below, and thereupon both parties shall be relieved of all further obligations hereunder. Within ninety (90) days after Tenant’s termination notice, Tenant shall notify Landlord of the exact date that Tenant will vacate and surrender Phase 1, which date shall be (a) no earlier than ninety (90) days after the date of Tenant’s notification of such exact date, and (b) no later than one (1) year after the date of Tenant’s termination notice. Rent for Phase 1 shall be prorated through the date that Tenant so vacates and surrenders Phase 1 to Landlord. If Tenant intends to exercise its termination right under this paragraph, then Tenant will use its best efforts to notify Landlord in writing between April 1, 2002 and May 1, 2002 of such intent, but Tenant’s failure to so notify Landlord shall not constitute a waiver of Tenant’s termination right.
m. The abatements, liquidated damages and termination rights in favor of Tenant as described above shall be Tenant’s sole and exclusive remedies in the event of any late delivery of the Buildings by Landlord, and notwithstanding anything to the contrary contained in this Lease, in no event shall the entire liability of Landlord in connection with the total aggregate amounts of the Base Rent credits, plus the $10,000.00 per day damages, plus the out-of-pocket costs incurred by Tenant exceed a total amount of Seven Hundred Fifty Thousand and No/100 ($750,000.00) Dollars in the aggregate, regardless of the length of time such rent credits, and/or liquidated damages and/or out-of-pocket costs actually accrue and regardless of whether Tenant terminates this Lease.
n. Although the completion date for Phase 2 is intended to be October 1, 2001, Tenant may notify Landlord in writing of Tenant’s election to have the Commencement Date for Phase 2 be on October 1, 2000. Tenant must provide such notice no later than April 1, 1999. If Tenant timely provides such notice, then the anticipated Commencement Date for Phase 2 will be deemed to be October 1, 2000, and subparagraphs 2.h through 2.I above will be deemed to be modified as follows: All references to the year “2001” in such subparagraphs will be deemed to be “2000,” and all references to the year “2002” in such subparagraphs will be deemed to be “2001.”
Commencement and Term This Agreement shall commence upon the Effective Date and continue for the Agreement Term.
Access to Premises Section 14.1 Tenant shall permit Landlord, Landlord’s agents and public utilities servicing the Building to erect, use and maintain concealed ducts, pipes and conduits in and through the Premises, provided that Landlord will not thereby reduce the rentable area of the Premises, other than to a de minimis extent. Landlord or Landlord’s agents shall have the right to enter the Premises at all reasonable times upon reasonable prior notice (except no such prior notice shall be required in case of emergency), which notice may be oral, to examine the same, to show them to prospective purchasers, Mortgagees, Lessors or lessees of the Building and their respective agents and representatives or prospective tenants of the Premises, and to make such repairs, alterations, improvements or additions (a) as Landlord may deem necessary or desirable to the Premises or to any other portion of the Building, or (b) which Landlord may elect to perform following Tenant’s failure to make repairs or perform any work which Tenant is obligated to make or perform under this Lease, or (c) for the purpose of complying with Legal Requirements, and Landlord shall be allowed to take all material into and upon the Premises that may be required therefor without the same constituting an eviction or constructive eviction of Tenant in whole or in part and Fixed Rent and Additional Rent will not be abated while said repairs, alterations, improvements or additions are being made, by reason of loss or interruption of business of Tenant, or otherwise.
Section 14.2 If Tenant shall not be present when for any reason entry into the Premises shall be necessary or permissible, Landlord or Landlord’s agents may enter the same without rendering Landlord or such agents liable therefor (if during such entry Landlord or Landlord’s agents shall accord reasonable care to Tenant’s property), and without in any manner affecting this Lease. Nothing herein contained, however, shall be deemed or construed to impose upon Landlord any obligation, responsibility or liability whatsoever for the care, supervision or repair of the Building or any part thereof, other than as herein provided.
Section 14.3 Landlord shall have the right from time to time to alter the Building and, without the same constituting an actual or constructive eviction and without incurring any liability to Tenant therefor, to change the arrangement or location of entrances or passageways, doors and doorways, and corridors, elevators, stairs, toilets, or other public parts of the Building and to change the name, number or designation by which the Building is commonly known; provided, however, that Landlord shall not make any permanent alterations which will deny or substantially interfere with Tenant’s access to the Premises from the public areas of the Building. All parts (except surfaces facing the interior of the Premises) of all walls, windows and doors bounding the Premises (including exterior Building walls, exterior core corridor walls, exterior doors and entrances other than doors and entrances solely servicing the Premises), all balconies, terraces and roofs adjacent to the Premises, all space in or adjacent to the Premises used for shafts, stacks, stairways, chutes, pipes, conduits, ducts, fan rooms, heating, air cooling, plumbing and other mechanical facilities, service closets and other Building facilities are not part of the Premises, and Landlord shall have the use thereof, as well as access thereto through the Premises for the purposes of operation, maintenance, alteration and repair. Landlord shall use reasonable efforts to minimize interference with Tenant’s access to and use and occupancy of the Premises in connection with any actions by Landlord permitted under this Section 14.3; provided, however, that Landlord shall have no obligation to employ contractors or labor at overtime or other premium pay rates or to incur any other overtime costs or additional expenses whatsoever.
Restoration of Premises Lessee shall conduct all operations on the Leased Premises in such a manner as not to unreasonably damage the portion of the Leased Premises where there will be no mining operations. Lessee shall conduct all operations in such a manner as to observe and comply with all Laws applicable to the Leased Premises and all Laws applicable to the conduct of Lessee’s operations. Lessee expressly agrees to dispose of all tailings and other mining wastes in accordance with all applicable Laws and shall reclaim all of disturbed perimeter portions of any lakes created by mining such that those perimeter portions shall be left at a slope no steeper than four feet horizontal to one foot vertical within three (3) months of termination of the Lease Agreement. By the expiration or earlier termination of the term of this Lease Agreement, Lessee shall grade that portion of the Leased Premises which has been excavated by Lessee or on which Lessee has conducted operations so as to eliminate all unreasonable irregularities therein and so that such portion of the Leased Premises which has been excavated by Lessee conforms to the drawing set forth on Exhibit C attached hereto. Upon completion of the required grading, Lessee shall cover such area with sand, clay, or topsoil, or a mixture of any of the foregoing, from the resources then existing on the Leased Premises, and shall thereafter reseed the surface with a seed mixture approved by Lessor. Notwithstanding the foregoing, in no event shall Lessee be required to import any Materials, including but not limited to, sand, clay, or topsoil from off-site for purposes of complying with its restoration obligations in this Section 15. Should this obligation not be met by the end of the term of this Lease Agreement, it shall nevertheless survive and continue beyond the term of this Lease Agreement and shall be an obligation owed by Lessee to Lessor. This obligation is owed by Lessee in addition to any other obligation imposed upon Lessee by this Lease Agreement.
LANDLORD'S ACCESS TO PREMISES Landlord reserves and shall at any time upon reasonable notice and in compliance with Tenant’s reasonable security measures have the right to enter the Premises to inspect the same, to supply any service to be provided by Landlord to Tenant hereunder to service and repair HVAC units, water pipes and sprinkler mains, and electrical and telephone risers servicing other parts of the Building, to show said Premises to prospective purchasers or tenants, to alter or repair the Premises or any portion of the Building, and to place “for sale” or “for rent” signs on the Building, all without being deemed guilty of an eviction of Tenant and without abatement of Rent, provided that the business of Tenant shall be interfered with as little as is reasonably practicable. Tenant hereby waives any claim for damages or any inconvenience to or interference with Tenant’s business, any loss of quiet enjoyment of the Premises and any other loss occasioned thereby. For each of the aforesaid purposes, Landlord shall at all times have and retain a key with which to unlock the main door to the Premises but not Tenant’s vaults and safes, and Landlord shall have the right to use any and all means which Landlord may deem proper to open said door in an emergency in order to obtain entry to the Premises, and any entry to the Premises obtained by Landlord by any of said means shall not under any circumstances be construed or deemed to be a forcible or unlawful entry into, or a detainer of the Premises, or any eviction of Tenant from the Premises or any portion thereof. No provision of this Lease shall be construed as obligating Landlord to perform any repairs, alterations or decoration except as otherwise expressly agreed to be performed by Landlord.
Commencement and Completion of Construction Subject to Unavoidable Delays, Developer shall cause construction of the Minimum Improvements to be undertaken and completed: (i) by no later than June 1, 2020; or (ii) by such other date as the parties shall mutually agree upon in writing. Time lost as a result of Unavoidable Delays shall be added to extend this date by a number of days equal to the number of days lost as a result of Unavoidable Delays. All work with respect to the Minimum Improvements shall be in conformity with the Construction Plans approved by the building official or any amendments thereto as may be approved by the building official. Developer agrees that it shall permit designated representatives of the City, upon reasonable notice (which does not have to be written), to enter upon the Development Property during the construction of the Minimum Improvements to inspect such construction and the progress thereof.
Condition of Premises Lessor makes no warranty or representation as to the Premises. Lessee acknowledges and agrees that it has occupied and familiarized itself with the Premises and has had adequate opportunity to investigate and inspect the condition of the Premises, and enters into this Lease upon the basis of its own review, and is leasing the Premises in their “AS IS, WHERE IS” CONDITION WITH ALL FAULTS, WHETHER PREVIOUSLY EXISTING OR ARISING FROM OR PERTAINING TO ANY CONSTRUCTION, RENOVATION, RELOCATION OR IMPROVEMENT OF ANY PORTION OF THE PREMISES PERFORMED BY LESSOR OR OTHERS, INCLUDING BUT NOT LIMITED TO BOTH LATENT AND PATENT DEFECTS. EXCEPT AS EXPRESSLY SET FORTH TO THE CONTRARY IN THIS LEASE, NO WARRANTIES, EXPRESS OR IMPLIED, ARE MADE BY LESSOR OR ANY OF ITS AFFILIATES CONCERNING SUCH ITEMS, INCLUDING BUT NOT LIMITED TO, WARRANTIES OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE. LESSEE HEREBY WAIVES AND DISCLAIMS ANY WARRANTIES THAT MAY ARISE BY OPERATION OF LAW. Lessee further acknowledges and agrees that it has had an opportunity to review and to discuss with various agents and/or representatives of Lessor the environmental condition of the Premises. Lessee has investigated and has knowledge of operative or proposed governmental laws and regulations including, without limitation, environmental laws and regulations to which the Premises are or may be subject and enters into this Lease upon the basis of its review and determination of the applicability and effect of such laws and regulations. Lessee acknowledges that Lessor expressly disclaims any representations or warranties of any kind or nature, express or implied, as to the condition (financial or otherwise), value or quality of the products, assets or properties of the Premises. Lessee hereby accepts the Premises in their condition existing as of the date hereof, subject to all applicable zoning, municipal, county and state laws, ordinances and regulations governing and regulating the use of the Premises, and accepts this Lease subject thereto and to all matters disclosed thereby and by any exhibits attached hereto. Lessee hereby agrees that all furniture, equipment, machinery and all other personal property, excepting any computers, that are located on or in the Premises as of the date hereof shall remain on the Premises as and when Lessee evacuates the Premises on the Termination Date or any extension thereof.
COMMENCEMENT AND TERMINATION 10.1 This Agreement shall be effective as of the date hereof and shall continue in force until terminated in accordance with the provisions herein.
10.2 This Agreement shall terminate without penalty:
a. As to any Participating Fund, at the option of Insurance Company or the Participating Fund at any time from the date hereof upon 180 days' notice, unless a shorter time is agreed to by the respective Participating Fund and Insurance Company;
b. As to any Participating Fund, at the option of Insurance Company, if shares of that Participating Fund are not reasonably available to meet the requirements of the Contracts as determined by Insurance Company. Prompt notice of election to terminate shall be furnished by Insurance Company, said termination to be effective ten days after receipt of notice unless the Participating Fund makes available a sufficient number of shares to meet the requirements of the Contracts within said ten-day period;
c. As to a Participating Fund, at the option of Insurance Company, upon the institution of formal proceedings against that Participating Fund by the Commission, National Association of Securities Dealers or any other regulatory body, the expected or anticipated ruling, judgment or outcome of which would, in Insurance Company's reasonable judgment, materially impair that Participating Fund's ability to meet and perform the Participating Fund's obligations and duties hereunder. Prompt notice of election to terminate shall be furnished by Insurance Company with said termination to be effective upon receipt of notice;
d. As to a Participating Fund, at the option of each Participating Fund, upon the institution of formal proceedings against Insurance Company by the Commission, National Association of Securities Dealers or any other regulatory body, the expected or anticipated ruling, judgment or outcome of which would, in the Participating Fund's reasonable judgment, materially impair Insurance Company's ability to meet and perform Insurance Company's obligations and duties hereunder. Prompt notice of election to terminate shall be furnished by such Participating Fund with said termination to be effective upon receipt of notice;
e. As to a Participating Fund, at the option of that Participating Fund, if the Participating Fund shall determine, in its sole judgment reasonably exercised in good faith, that Insurance Company has suffered a material adverse change in its business or financial condition or is the subject of material adverse publicity and such material adverse change or material adverse publicity is likely to have a material adverse impact upon the business and operation of that Participating Fund or Dreyfus, such Participating Fund shall notify Insurance Company in writing of such determination and its intent to terminate this Agreement, and after considering the actions taken by Insurance Company and any other changes in circumstances since the giving of such notice, such determination of the Participating Fund shall continue to apply on the sixtieth (60th) day following the giving of such notice, which sixtieth day shall be the effective date of termination;
f. As to a Participating Fund, upon termination of the Investment Advisory Agreement between that Participating Fund and Dreyfus or its successors unless Insurance Company specifically approves the selection of a new Participating Fund investment adviser. Such Participating Fund shall promptly furnish notice of such termination to Insurance Company;
g. As to a Participating Fund, in the event that Participating Fund's shares are not registered, issued or sold in accordance with applicable federal law, or such law precludes the use of such shares as the underlying investment medium of Contracts issued or to be issued by Insurance Company. Termination shall be effective immediately as to that Participating Fund only upon such occurrence without notice;
h. At the option of a Participating Fund upon a determination by its Board in good faith that it is no longer advisable and in the best interests of shareholders of that Participating Fund to continue to operate pursuant to this Agreement. Termination pursuant to this Subsection (h) shall be effective upon notice by such Participating Fund to Insurance Company of such termination;
i. At the option of a Participating Fund if the Contracts cease to qualify as annuity contracts or life insurance policies, as applicable, under the Code, or if such Participating Fund reasonably believes that the Contracts may fail to so qualify;
j. At the option of any party to this Agreement, upon another party's breach of any material provision of this Agreement;
k. At the option of a Participating Fund, if the Contracts are not registered, issued or sold in accordance with applicable federal and/or state law; or
l. Upon assignment of this Agreement, unless made with the written consent of every other non-assigning party. Any such termination pursuant to Section 10.2a, 10.2d, 10.2e, 10.2f or 10.2k herein shall not affect the operation of Article V of this Agreement. Any termination of this Agreement shall not affect the operation of Article IX of this Agreement.
10.3 Notwithstanding any termination of this Agreement pursuant to Section 10.2 hereof, each Participating Fund and Dreyfus may, at the option of the Participating Fund, continue to make available additional shares of that Participating Fund for as long as the Participating Fund desires pursuant to the terms and conditions of this Agreement as provided below, for all Contracts in effect on the effective date of termination of this Agreement (hereinafter referred to as "Existing Contracts"). Specifically, without limitation, if that Participating Fund and Dreyfus so elect to make additional Participating Fund shares available, the owners of the Existing Contracts or Insurance Company, whichever shall have legal authority to do so, shall be permitted to reallocate investments in that Participating Fund, redeem investments in that Participating Fund and/or invest in that Participating Fund upon the making of additional purchase payments under the Existing Contracts. In the event of a termination of this Agreement pursuant to Section 10.2 hereof, such Participating Fund and Dreyfus, as promptly as is practicable under the circumstances, shall notify Insurance Company whether Dreyfus and that Participating Fund will continue to make that Participating Fund's shares available after such termination. If such Participating Fund shares continue to be made available after such termination, the provisions of this Agreement shall remain in effect and thereafter either of that Participating Fund or Insurance Company may terminate the Agreement as to that Participating Fund, as so continued pursuant to this Section 10.3, upon prior written notice to the other party, such notice to be for a period that is reasonable under the circumstances but, if given by the Participating Fund, need not be for more than six months.
10.4 Termination of this Agreement as to any one Participating Fund shall not be deemed a termination as to any other Participating Fund unless Insurance Company or such other Participating Fund, as the case may be, terminates this Agreement as to such other Participating Fund in accordance with this Article X.
Repair of Damage to Premises by Landlord Tenant shall promptly notify Landlord of any damage to the Premises resulting from fire or any other casualty. If the Premises or any Common Areas serving or providing access to the Premises shall be damaged by fire or other casualty, Landlord shall promptly and diligently, subject to reasonable delays for insurance adjustment or other matters beyond Landlord's reasonable control, and subject to all other terms of this Article 1 1, restore the Base Building and such Common Areas. Such restoration shall be to substantially the same condition of the Base Building and the Common Areas prior to the casualty, except for modifications required by zoning and building codes and other laws or by the holder of a mortgage on the Building or Project or any other modifications to the Common Areas deemed desirable by Landlord, which are consistent with the character of the Project, provided that access to the Premises and any common restrooms serving the Premises shall not be materially impaired. Landlord shall repair any injury or damage to the improvements which exist in the Premises as of the Lease Commencement Date (the "Original Improvements") and shall return such Original Improvements to their original condition. Prior to the commencement of construction, Tenant shall submit to Landlord, for Landlord's review and approval, all plans, specifications and working drawings relating thereto, and Landlord shall select the contractors to perform such improvement work. Landlord shall not be liable for any inconvenience or annoyance to Tenant or its visitors, or injury to Tenant's business resulting in any way from such damage or the repair thereof; provided however, that if such fire or other casualty shall have damaged the Premises or Common Areas necessary to Tenant's occupancy, and the Premises are not occupied by Tenant as a result thereof, then during the time and to the extent the Premises are unfit for occupancy, the Rent shall be abated in proportion to the ratio that the amount of rentable square feet of the Premises which is unfit for occupancy for the purposes permitted under this Lease bears to the total rentable square feet of the Premises, provided that if the Premises are so damaged that it is not reasonably practicable for Tenant to continue its business operations from any portion of the Premises, then the Rent shall be fully abated during such time.
Union Activity on Premises and/or Access to Premises The Union agrees that neither it, nor its officers, agents, representatives and members will engage in the solicitation of members, holding of meetings or any other Union activities on Hospital premises or on Hospital time without the prior approval of the Hospital, except as specifically provided for in this Agreement. Such approval will not be unreasonably denied.
