Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
System for Award Management (XXX) Requirement Alongside a signed copy of this Agreement, Grantee will provide Florida Housing with a XXX.xxx proof of registration and Commercial and Government Entity (CAGE) number. Grantee will continue to maintain an active XXX registration with current information at all times during which it has an active award under this Agreement.
Operating Requirements Any operating and technical requirements that may be applicable due to Regional Transmission Organization, Independent System Operator, control area, or the Connecting Transmission Owner’s requirements, including those set forth in the Small Generator Interconnection Agreement. Operating Requirements shall include Applicable Reliability Standards.
Compliance with Xxxxx-Xxxxx and Related Act requirements All rulings and interpretations of the Xxxxx-Xxxxx and Related Acts contained in 29 CFR parts 1, 3, and 5 are herein incorporated by reference in this contract.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Licensing Requirements (a) Employer and Employee hereby covenant and agree that this Agreement and/or Employee’s employment may be subject to the approval of one or more gaming regulatory authorities (the “Authorities”) pursuant to the provisions of the relevant gaming regulatory statutes (the “Gaming Acts”) and the regulations promulgated thereunder (the “Gaming Regulations”). Employer and Employee hereby covenant and agree to use their best efforts to obtain any and all approvals required by the Gaming Acts and/or Gaming Regulations. In the event that (i) an approval of this Agreement or Employee’s employment by the Authorities is required for Employee to carry out Employee’s duties and responsibilities set forth in Section 3 of this Agreement, (ii) Employer and Employee have used their best efforts to obtain such approval, and (iii) this Agreement or Employee’s employment is not so approved by the Authorities, then this Agreement shall immediately terminate and shall be null and void, thus extinguishing any and all obligations of either party, subject to any surviving obligations of Employee under Sections 9, 10 and 21.
(b) If applicable, Employer and Employee hereby covenant and agree that, in order for Employee to discharge the duties required under this Agreement, Employee must apply for or hold a license, registration, permit or other approval (the “License”) as issued by the Authorities pursuant to the terms of the relevant Gaming Act and as otherwise required by this Agreement. In the event Employee fails to apply for and secure, or the Authorities refuse to issue or renew Employee’s License, Employee, at Employer’s sole cost and expense, shall promptly defend such action and shall take such reasonable steps as may be required to either remove the objections or secure or reinstate the Authorities’ approval, respectively. The foregoing notwithstanding, if the source of the objections or the Authorities’ refusal to renew or maintain Employee’s License arise as a result of any of the acts, omissions or events described in Section 1(c) of this Agreement, then Employer’s obligations under this Section 8 also shall not be operative and Employee shall promptly reimburse Employer upon demand for any expenses incurred by Employer pursuant to this Section 8.
(c) Employer and Employee hereby covenant and agree that the provisions of this Section 8 shall apply in the event Employee’s duties require that Employee also be licensed by governmental agencies other than the Authorities.
COMPLIANCE WITH LICENSING REQUIREMENTS CONTRACTOR shall comply with all necessary licensing requirements and shall obtain appropriate licenses and display the same in a location that is reasonably conspicuous, as well as file copies of same with the County Executive Office.
Performance Requirements A. There is no guaranteed minimum amount of work which will be ordered under this Contract.
B. The total Contract amount will not exceed $4,900,000.
C. This is a Contract for work specified in individual Job Orders. Work ordered prior to but not completed by the expiration of the Contract period, and any additional work required as a result of unforeseen conditions encountered during construction up to six (6) months after the contract expiration date, will be completed with all provisions of this Contract still in force. Performance time for each Job Order issued under this Contract will be determined in accordance with the Contract. This performance time will be determined and agreed upon by both Parties for each individual Job Order. Contractor must self-perform 20% of the Work under this Contract for ‘A’ and ‘B’ licenses. Contractor must self-perform 75% of the Work under this Contract, unless otherwise approved by the County, for ‘C’ licenses.
D. This is an indefinite-quantity Contract for the supplies or services specified and effective for the period stated. Work or performance shall be made only as authorized by Job Orders issued in accordance with the ordering procedures clause. The Contractor agrees to furnish to the County when and if ordered, the supplies or services specified in the Contract up to and including the quantity designated in the Job Orders issued as the maximum designated in the Contract.
Post-Closing Requirements Borrowers shall complete each of the post-closing obligations and/or provide to Agent each of the documents, instruments, agreements and information listed on Schedule 7.4 attached hereto on or before the date set forth for each such item thereon, each of which shall be completed or provided in form and substance satisfactory to Agent.
RIGHT OF ALLOTTEE TO USE COMMON AREAS AND FACILITIES SUBJECT TO PAYMENT OF TOTAL MAINTENANCE CHARGES The Allottee hereby agrees to purchase the [Apartment/Plot] on the specific understanding that is/her right to the use of Common Areas shall be subject to timely payment of total maintenance charges, as determined and thereafter billed by the maintenance agency appointed or the association of allottees (or the maintenance agency appointed by it) and performance by the Allottee of all his/her obligations in respect of the terms and conditions specified by the maintenance agency or the association of allottees from time to time.
