USE AND POSSESSION PRIOR TO COMPLETION Sample Clauses

USE AND POSSESSION PRIOR TO COMPLETION. (a) Company shall have the right to take possession of or use any completed or partially completed part of the work. Before taking possession of or using any work, Company shall furnish Seller a list of items of work remaining to be performed or corrected on those portions of the work that Company intends to take possession of or use. However, failure of Company to list any item of work shall not relieve Seller of responsibility for complying with the terms of this Agreement. Company's possession or use shall not be deemed an acceptance of any work under this Agreement. (b) While Company has such possession or use, Seller shall be relieved of the responsibility for the loss of or damage to the work resulting from Company's possession or use. If prior possession or use by Company delays the progress of the work or causes additional expense to Seller, an equitable adjustment shall be made in the price or the time of completion, and the Agreement shall be modified in writing accordingly.
AutoNDA by SimpleDocs
USE AND POSSESSION PRIOR TO COMPLETION. (MAR 2019)
USE AND POSSESSION PRIOR TO COMPLETION. The Exchange shall have the right to take possession of or use any completed or partially completed part of the work. Prior to such possession or use, the contracting officer shall furnish the contractor an itemized list of work remaining to be performed or corrected on such portions of the project as are to be possessed or used by the Exchange, provided that failure to list any item of work shall not relieve the contractor of responsibility for compliance with the terms of the contract. Such possession or use shall not be deemed an acceptance of any work under the contract.
USE AND POSSESSION PRIOR TO COMPLETION. Princeton University shall have the right to take possession of or use any completed or partially completed part of the Work. Princeton University’s possession or use shall not be deemed an acceptance of any Work under the Contract.
USE AND POSSESSION PRIOR TO COMPLETION. A. HISD shall have the right to take possession of or use any completed or partially completed part of the Work. Before taking possession of or using any Work, the HISD Issuing Authority shall furnish the Contractor a list of items of Work remaining to be performed or corrected on those portions of the Work that HISD intends to take possession of or use. However, failure of the HISD Issuing Authority to list any item of Work shall not relieve the Contractor of responsibility for complying with the terms of this Contract. HISD’s possession or use shall not be deemed an acceptance of any Work under this Contract. B. While HISD has such possession or use, the Contractor shall be relieved of the responsibility for the loss of or damage to the Work resulting solely from HISD’s possession or use, notwithstanding the terms of the Article in this Contract entitled “Permits and Responsibilities”. If prior possession or use by HISD delays the progress of the Work or causes additional expense to the Contractor, an equitable adjustment may be made in the Job Order price or the time of completion, and the Job Order may be modified in writing accordingly.
USE AND POSSESSION PRIOR TO COMPLETION. Yakama Nation shall have the right to take possession of or use any completed or partially completed part of the work call for by this Agreement. Before taking possession of or using any work, Yakama Nation shall furnish Contractor a list of items of work remaining to be performed or corrected on those portions of the work that Yakama Nation intends to take possession of or use. However, failure of Yakama Nation to list any item of work shall not relieve Contractor of responsibility for complying with the terms of this Agreement. Yakama Nation’s possession or use shall not be deemed an acceptance of any work under this Agreement.
USE AND POSSESSION PRIOR TO COMPLETION. 29.1 Owner shall have the right to take possession of or use any completed or partially completed part of the Work. Before taking possession of or using any work, Owner shall furnish Job Order Contractor a list of items of work remaining to be performed or corrected on those portions of the Work that Owner intends to take possession of or use. However, failure of Owner to list any item of work shall not relieve Job Order Contractor of responsibility for complying with the terms of this Agreement. Owner possession or use shall not be deemed an acceptance of any work under this Agreement. 29.2 While Owner has such possession or use, Job Order Contractor shall be relieved of the responsibility for the loss of or damage to the Work resulting from Owner’s possession or use, notwithstanding the terms of Article 6. If prior possession or use by Owner delays the progress of the Work or causes additional expense to Job Order Contractor, an equitable adjustment shall be made in the Job Order price or the period of performance, and the Job Order shall be modified in writing accordingly.
AutoNDA by SimpleDocs
USE AND POSSESSION PRIOR TO COMPLETION. (a) The PHA shall have the right to take possession of or use any completed or partially completed part of the work. Before taking possession of or using any work, the Contracting Officer shall furnish the Contractor a list of items of work remaining to be performed or corrected on those portions of the work that the PHA intends to take possession of or use. However, failure of the Contracting Officer to list any item of work shall not relieve the Contractor of responsibility for complying with the terms of the contract. The PHA’s possession or use shall not be deemed an acceptance of any work under the contract. (b) While the PHA has such possession or use, the Contractor shall be relieved of the responsibility for (1) the loss of or damage to the work resulting from the PHA’s possession or use, notwithstanding the terms of the clause entitled Permits and Codes herein; (2) all maintenance costs on the areas occupied; and, (3) furnishing heat, light, power, and water used in the areas occupied without proper remuneration therefore. If prior possession or use by the PHA delays the progress of the
USE AND POSSESSION PRIOR TO COMPLETION. The Authority shall have the right to take possession of or use any completed or partially completed part of the Work. Before taking possession of or using any Work, the Authority shall furnish the Contractor a list of items of Work remaining to be performed or corrected on those portions of the Work that the Authority intends to take possession of or use. However, failure of the Authority to list any item of Work shall not relieve the Contractor of responsibility for complying with the terms of the Contract. The Authority's possession or use shall not be deemed an acceptance of any Work under the Contract. While the Authority has such possession or use, the Contractor shall be relieved of the responsibility for the loss of or damage to the Work resulting from the Authority's possession or use, notwithstanding the terms of the Contract terms relating to the “Risk of Loss; Protection of Existing Site” clause (Section 7.8.7) of the General Provisions.
USE AND POSSESSION PRIOR TO COMPLETION. (HUD)35 (a) The PHA shall have the right to take possession of or use any completed or partially completed part of the work. Before taking possession of or using any work, the Contracting Officer shall furnish the Contractor a list of items of work remaining to be performed or corrected on those portions of the work that the PHA intends to take possession of or use. However, failure of the Contracting Officer to list any item of work shall not relieve the Contractor of responsibility for complying with the terms of the contract. The PHA’s possession or use shall not be deemed an acceptance of any work under the contract. (b) While the PHA has such possession or use, the Contractor shall be relieved of the responsibility for (1) the loss of or damage to the work resulting from the PHA’s possession or use, notwithstanding the terms of the clause entitled Permits and Codes herein; (2) all maintenance costs on the areas occupied; and, (3) furnishing heat, light, power, and water used in the areas occupied without proper remuneration therefore. If prior possession or use by the PHA delays the progress of the work or causes additional expense to the Contractor, an equitable adjustment shall be made in the contract price or the time of completion, and the contract shall be modified in writing accordingly.
Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!