Verification of Dimensions Sample Clauses

Verification of Dimensions. Contractor shall verify all dimensions before laying out and performing any particular portion of the Work and shall be responsible for any errors which might have been avoided thereby. Contractor shall promptly notify Owner of any such errors by using a Request for Information Form (“RFI”). Dimensions of Work as indicated on Drawings are not guaranteed to be as built dimensions. No measurements shall be scaled from Drawings and used as definite dimensions for layout or fitting Work in place. Dimensions for items to be fitted into constructed conditions or improvements at the Project Site shall be taken at the Project Site. Whenever a stock size, manufactured item or piece of equipment is specified by its nominal size or dimensions, Contractor shall be responsible to verify measurements thereof and assure proper incorporation into the Work.
Sample 1Sample 2
AutoNDA by SimpleDocs
Verification of Dimensions. The contractor is required to certify via a certificate of compliance that all dimensions, threads, angles, and finishes comply with drawing or specification requirements. All approved deviation/waivers shall be listed as part of the certificate of compliance.
Sample 1
Verification of Dimensions. The Construction Manager shall verify all dimensions before laying out and performing any particular portion of the Work and shall be responsible for any errors, which might have been avoided thereby. Dimensions of Work as indicated on Drawings are not guaranteed to be as built dimensions. No measurements shall be scaled from Drawings and used as definite dimensions for layout or fitting Work in place. Whenever inaccuracies or discrepancies are found, the Construction Manager shall inform the Owner and the Architect and obtain clarification prior to any construction or demolition. Should any dimensions be missing, Construction Manager shall consult with the Owner and the Architect and shall obtain such dimensions prior to execution of the Work. Dimensions for items to be fitted into constructed conditions at the Site will be taken at the Site. Whenever a stock size, manufactured item or piece of equipment is specified by its nominal size, it is the responsibility of the Construction Manager to determine the actual space requirements for setting or entrance to the setting space. No extension of the Completion Date(s) or Milestone Dates or increase in the GMP or Separate GMP, as applicable, will be allowed by reason of Work requiring adjustments in order to accommodate the particular item of equipment.
Sample 1
Verification of Dimensions. The Employer’s drawings include a general arrangement of pipe routes and structural support systems. The Contractor shall verify all dimensions on site and confirm the actual length of pipework and closure pieces prior to fabrication, structural support system dimensions and positions on a case by case basis. b)
Sample 1
Verification of Dimensions. The Contractor shall visit the job site to thoroughly familiarize himself with all the details of the work and working conditions. The Contractor shall also verify all dimensions in the field and shall advise the Contracting Officer of any discrepancy before performing any work. The Contractor shall be specifically responsible for the coordination and proper relation of his work to the building, structure, phasing and ensure the safety of employees and workmen.
Sample 1

Related to Verification of Dimensions

  • Verification Bank may, from time to time, verify directly with the respective Account Debtors the validity, amount and other matters relating to the Accounts, either in the name of Borrower or Bank or such other name as Bank may choose.

  • Inspection and Verification The Secured Parties and such persons as the Secured Parties may reasonably designate shall have the right to inspect the Collateral, all records related thereto (and to make extracts and copies from such records) and the premises upon which any of the Collateral is located, to discuss the Grantor’s affairs with the officers of the Grantor and its independent accountants and to verify under reasonable procedures the validity, amount, quality, quantity, value, condition and status of, or any other matter relating to, the Collateral, including, in the case of collateral in the possession of any third Person, by contacting any account debtor or third Person possessing such Collateral for the purpose of making such a verification. Out-of-pocket expenses in connection with any inspections by representatives of the Secured Parties shall be (a) the obligations of the Grantor with respect to any inspection after the Secured Parties’ demand payment of the Notes or (b) the obligation of the Secured Parties in any other case.

  • Complete Copies of Materials The Company has delivered or made available true and complete copies of each document (or summaries of same) that has been requested by Parent or its counsel.

  • Provision of copies and translation of documents The Borrower will supply the Agent with a sufficient number of copies of the documents referred to above to provide 1 copy for each Creditor Party; and if the Agent so requires in respect of any of those documents, the Borrower will provide a certified English translation prepared by a translator approved by the Agent.

  • Verification of Accounts Any of Lender's officers, employees, or agents shall have the right, at any time or times hereafter, in the name of Lender, any designee of Lender or in the name of the Borrowers, to verify the validity, amount or any other matter relating to any Accounts by mail, telephone, telegraph, or otherwise.

  • Account Verification Whether or not a Default or Event of Default exists, Agent shall have the right at any time, in the name of Agent, any designee of Agent or any Borrower, to verify the validity, amount or any other matter relating to any Accounts of Borrowers by mail, telephone or otherwise. Borrowers shall cooperate fully with Agent in an effort to facilitate and promptly conclude any such verification process.

  • Tests 7.7.1 If the Contract Documents, laws, ordinances, rules, regulations or orders of any public authority having jurisdiction require any portion of the Work to be inspected, tested or approved, the Contractor shall give the Architect timely notice of its readiness so the Architect may observe such inspection, testing or approval. The Contractor shall bear all costs of such inspections, tests or approvals conducted by public authorities.

  • Check and complete if Transferee will take delivery of a beneficial interest in the IAI Global Note or a Restricted Definitive Note pursuant to any provision of the Securities Act other than Rule 144A or Regulation S. The Transfer is being effected in compliance with the transfer restrictions applicable to beneficial interests in Restricted Global Notes and Restricted Definitive Notes and pursuant to and in accordance with the Securities Act and any applicable blue sky securities laws of any state of the United States, and accordingly the Transferor hereby further certifies that (check one):

  • Review of Materials During the term of this Agreement, Client shall ensure that all prospectuses, statements of additional information, registration statements, proxy statements, reports to shareholders, advertising and sales literature or other materials prepared for distribution to Fund shareholders or the public, which refer to the Subadviser in any way, prepared by employees or agents of Client or its affiliates are consistent with information previously provided by Subadviser. Subadviser shall promptly notify the Client of any changes to information pertaining to the Subadviser and stated in the materials described in this Section 6(g).

  • Inspection and Testing Each Constructing Entity shall cause inspection and testing of the Interconnection Facilities that it constructs in accordance with the provisions of this section. The Construction Parties acknowledge and agree that inspection and testing of facilities may be undertaken as facilities are completed and need not await completion of all of the facilities that a Constructing Entity is building.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!